Notice Requirements All notices required or permitted by this Lease shall be in writing and may be delivered in person (by hand or by messenger or courier service) or may be sent by regular, certified or registered mail or U.S. Postal Service Express Mail, with postage prepaid, or by facsimile transmission during normal business hours, and shall be deemed sufficiently given if served in a manner specified in this Paragraph 23. The addresses noted adjacent to a Party's signature on this Lease shall be that Party's address for delivery or mailing of notice purposes. Either Party may by written notice to the other specify a different address for notice purposes, except that upon Lessee's taking possession of the Premises, the Premises shall constitute Lessee's address for the purpose of mailing or delivering notices to Lessee. A copy of all notices required or permitted to be given to Lessor hereunder shall be concurrently transmitted to such party or parties at such addresses as Lessor may from time to time hereafter designate by written notice to Lessee.
Invoice Requirements Contractor hereby waives the right to enforce any term which contradicts or modifies any term of the solicitation or any Contract that may result, including subsequent amendments to the Contract, or would result in an unencumbered expense if enforced against the state. Contract quote and invoice must contain, at a minimum: o Customer name o State Purchase Order number field o Item/service description o Item quantity
Notice Requirement No termination of this Agreement shall be effective unless and until the party terminating this Agreement gives prior written notice to all other parties of its intent to terminate, which notice shall set forth the basis for the termination. Furthermore,
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Schedule Requirements The Contractor shall submit an electronic and a paper copy of the initial Work Progress Schedule reflecting accurate and reliable representations of the planned progress of the Work, the Work to date if any, and of the Contractor’s actual plans for its completion. The Contractor shall organize and provide adequate detail so the Work Progress Schedule is capable of measuring and forecasting the effect of delaying events on completed and uncompleted activities.
Records Requirements Records of expenses pertaining to Additional Services and services performed on the basis of a Worker Wage Rate or Monthly Salary Rate shall be kept on the basis of generally accepted accounting principles and in accordance with cost accounting standards promulgated by the Federal Office of Management and Budget Cost Accounting Standards Board and shall be available for audit by Owner or Owner’s authorized representative on reasonable notice.
Signature Requirements If the Assignment of Partnership Interest is signed by the registered holder of the Units and payment is to be made directly to that holder, then no signature guarantee is required on the Assignment of Partnership Interest. Similarly, if the Units are tendered for the account of a member firm of a registered national securities exchange, a member of the National Association of Securities Dealers, Inc. or a commercial bank, savings bank, credit union, savings and loan association or trust company having an office, branch or agency in the United States (each an "Eligible Institution"), no signature guarantee is required on the Assignment of Partnership Interest. HOWEVER, IN ALL OTHER CASES, ALL SIGNATURES ON THE ASSIGNMENT OF PARTNERSHIP INTEREST MUST BE GUARANTEED BY AN ELIGIBLE INSTITUTION. Please contact the Information Agent for assistance in obtaining a signature guarantee.
Time Requirements The Independent Contractor will not be required to follow or establish a regular or daily work schedule, but shall devote during the term of this Agreement the time, energy and skill as necessary to perform the services of this engagement and shall, periodically or at any time upon the request of the Company, submit information as to the amount of time worked and scope of work performed.
Minimum Insurance Requirements Contractor shall procure and maintain for the duration of the contract insurance against claims for injuries or death to persons or damages to property which may arise from or in connection with the performance of the work hereunder and the results of that work by the Contractor, his agents, representatives, employees or sub-contractors. Coverage - Coverage shall be at least as broad as the following:
Overtime requirements No contractor or subcontractor contracting for any part of the contract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek.
