Ocean Cargo and Marine Delay in Startup / Business Interruption Sample Clauses

Ocean Cargo and Marine Delay in Startup / Business Interruption. To the extent an exposure exists, the Borrower shall maintain, or cause to be maintained, ocean cargo insurance on an all-risk basis (Institutes Cargo Clauses (A) 1/109 or equivalent), subject to standard policy conditions, at any time in which the Borrower has risk of loss or responsibility for the placement of such insurance during shipment of equipment or materials to the Project Site and such insurance is not already provided under Section 1.1.1 or Section 1.13 above (as applicable), or under the applicable manufacturer’s, supplier’s, or contractor’s insurance policies for physical loss or damage to such equipment or materials in an amount not less than the replacement cost value of each shipment. Such insurance shall (i) include coverage for war and strikes (subject to a 7-day or 48-hour notice of cancellation as applicable), terrorism, theft, pilferage, non-delivery, charges of general average sacrifice or contribution, salvage expenses, temporary storage in route, consolidation, repackaging, refused and returned shipments, (ii) 50/50 clause, difference in conditions for C.I.F. shipments, unintentional errors and omissions clause, import duty clause, non-vitiation clause (subject only to the survey warranty clause) and (iii) insure for the replacement cost value of the largest single shipment, plus freight and insurance if coverage is purchased by the Borrower. The Administrative Agent shall reevaluate the need for marine delay in startup / business interruption insurance (i.e., if the loss of such property being shipped is expected to cause a material interruption of normal business operations) with a limit and associated indemnity period equivalent to the estimated loss of gross revenues (including production tax credits (grossed up for taxes), if any, or other financial incentives, as applicable), less non-continuing expenses for the longest period of interruption reasonably expected to occur, to the extent available on commercially reasonable terms and required by the Administrative Agent. All such policies may have per occurrence deductibles of not greater than: (a) $1,000,000 for physical damage and (b) sixty (60) (in the aggregate for delay in startup), except seventy-five (75) days (in the aggregate for delay in startup) for damage to wind turbine generators days and ninety (90) days (in the aggregate for delay in startup) for damage to electrical service platform, export cables and named windstorm (including storm surge) for marine delay in ...
Sample 1
AutoNDA by SimpleDocs

Related to Ocean Cargo and Marine Delay in Startup / Business Interruption

  • Mail Service Interruption If by reason of any interruption of mail service, actual or threatened, any notice to be given to the Trustee would reasonably be unlikely to reach its destination by the time notice by mail is deemed to have been given pursuant to Section 14.3, such notice shall be valid and effective only if delivered at the appropriate address in accordance with Section 14.3.

  • Business Interruption Plan ALPS shall maintain in effect a business interruption plan, and enter into any agreements necessary with appropriate parties making reasonable provisions for emergency use of electronic data processing equipment customary in the industry. In the event of equipment failures, ALPS shall, at no additional expense to the Fund, take commercially reasonable steps to minimize service interruptions.

  • Service Interruption Landlord shall not be liable in damages for any failure or interruption of any utility service to the Premises, except to the extent that any failure or interruption arises from the gross negligence or willful misconduct of Landlord. No failure or interruption of utility service for any reason shall entitle Tenant to terminate this Lease; provided, however, that if the failure or interruption of any Service to be repaired or maintained by Landlord and not the service provider continues for a period of forty-eight (48) hours or more, Tenant shall be entitled to an equitable abatement of Minimum Rent. Landlord shall not be obligated to provide any service or maintenance or to make any repairs pursuant to this Lease when such service, maintenance or repair is made necessary because of any wrongful act or misuse of any utility service by Tenant, Tenant's agents, employees, servants, contractors, subtenants or licensees. Landlord reserves the right to stop any Service when Landlord deems such stoppage necessary, whether by reason of accident or emergency, or for repairs or improvements or otherwise, provided, that any such period of stoppage shall be only so long as is reasonably required to effect any necessary repairs or maintenance. Landlord shall not be obligated to inspect the Premises and shall not be obligated to make any repairs or perform any maintenance hereunder unless first notified of the need thereof in writing or, in an emergency, verbally, followed by a written confirmation, by Tenant. Upon receipt of any such notice, Landlord shall commence any required repair work of an emergency nature as soon as possible and work as expeditiously as possible to complete such work. All other work of a non-emergency nature shall be performed as promptly as possible. If Landlord shall fail to commence emergency repairs or maintenance to be performed by Landlord and not the service provider within twenty-four (24) hours after said notice, or non-emergency repairs or maintenance within five (5) days after said notice, then Tenant shall be entitled to an equitable abatement of Minimum Rent for so long as such failure continues and an extension of the Lease Term for a period equal to the period of rent abatement.

  • Business Interruption Lessee shall obtain and maintain loss of income and extra expense insurance in amounts as will reimburse Lessee for direct or indirect loss of earnings attributable to all perils commonly insured against by prudent lessees in the business of Lessee or attributable to prevention of access to the Premises as a result of such perils.

  • Service Interruptions When necessary by reason of accident or emergency, or for repairs, alterations, replacements or improvements which in the reasonable judgment of Landlord are desirable or necessary to be made, or by reason of event(s) of Force Majeure, Landlord reserves the right to interrupt, curtail, stop or suspend (i) the furnishing of heating, elevator, air conditioning, and cleaning services and (ii) the operation of the plumbing and electric systems. Landlord shall exercise reasonable diligence to eliminate the cause of any such interruption, curtailment, stoppage or suspension, but there shall be no diminution or abatement of rent or other compensation due from Landlord to Tenant hereunder, nor shall this Lease be affected or any of the Tenant’s obligations hereunder reduced, and the Landlord shall have no responsibility or liability for any such interruption, curtailment, stoppage, or suspension of services or systems, except as provided herein. Landlord shall schedule all non-emergency interruptions, curtailments, stops or suspensions of services or systems in advance after consultation with Tenant, and shall make commercially reasonable efforts to avoid the same interfering with Tenant’s business. Notwithstanding the foregoing, Tenant shall be entitled to a proportionate abatement of Base Rent in the event of a Landlord Service Interruption (as defined below). For the purposes hereof, a “Landlord Service Interruption” shall occur in the event (i) the Premises shall lack any service which Landlord is required to provide hereunder thereby rendering at least fifty (50%) percent of the usable area of the Premises untenantable for the entirety of the Landlord Service Interruption Cure Period (as defined below), (ii) such lack of service was not caused by the act or omission of Tenant or any Tenant Party; (iii) Tenant in fact ceases to use at least fifty (50%) percent of the Premises for the entirety of the Landlord Service Interruption Cure Period; and (iii) such interruption of service was the result of causes, events or circumstances within the Landlord’s reasonable control and the cure of such interruption is within Landlord’s reasonable control. During such Landlord Service Interruption Period, Landlord will, if reasonably practical, cooperate with Tenant to arrange for the provision of any interrupted services on an interim basis via temporary measures until final corrective measures can be accomplished and Tenant will permit Landlord the necessary access to the Premises to remedy such lack of service, subject to the provisions of Section 9.06. For the purposes hereof, the “Landlord Service Interruption Cure Period” shall be defined as seven (7) consecutive Business Days after Landlord’s receipt of written notice from Tenant of the Landlord Service Interruption. This Section 6.03 shall be Tenant’s sole and exclusive remedy on account of an interruption of services or Landlord default resulting in an interruption of services other than Tenant’s right to obtain affirmative injunctive relief. This Section 6.03 shall not apply to any interruption or failure of services required to be provided by Landlord under Section 6.02(a) or Exhibit E attached hereto, which is caused in whole or in part by any act or omission of Tenant or any Tenant Party, or by any occurrence described in Section 16.09, or by any cause whatsoever other than those set forth in the first sentence of this Section 6.03. Notwithstanding the foregoing, if either Landlord or Tenant disputes in good faith whether, or the extent to which, an event is subject to the provisions of this Section 6.03, or the amount of Tenant’s abatement of Base Rent hereunder, such dispute shall be resolved in accordance with Section 16.17 of this Lease; provided, however, that in the event that it is ultimately determined that there was a Landlord Service Interruption, then Tenant shall have the right to a retroactive equitable abatement of Base Rent for the period as set forth above, provided that, if the Term expires before Tenant’s entire retroactive abatement has been effected, then Landlord shall immediately refund to Tenant any overpayment of Rent due under the Lease not yet received on account of the retroactive abatement.

  • Utility Services The Owner represents that, to the best of its knowledge, all utility services required to construct and operate the Project (including, without limitation, public water, sewer and electricity) are currently available to the Property in the capacities required to operate the Project. No work need be performed by or on behalf of the Developer to make such utilities available to the Property for the construction or operation of the Project, except for the matters, if any, set forth on Exhibit "D". Copies of letters from the providers of such utility services confirming such availability are annexed hereto as Exhibit "G".

  • Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.

  • Interruption of Use Tenant agrees that Landlord shall not be liable for damages, by abatement of Rent or otherwise, for failure to furnish or delay in furnishing any service (including telephone and telecommunication services), or for any diminution in the quality or quantity thereof, when such failure or delay or diminution is occasioned, in whole or in part, by breakage, repairs, replacements, or improvements, by any strike, lockout or other labor trouble, by inability to secure electricity, gas, water, or other fuel at the Building or Project after reasonable effort to do so, by any riot or other dangerous condition, emergency, accident or casualty whatsoever, by act or default of Tenant or other parties, or by any other cause beyond Landlord's reasonable control; and such failures or delays or diminution shall never be deemed to constitute an eviction or disturbance of Tenant's use and possession of the Premises or relieve Tenant from paying Rent or performing any of its obligations under this Lease. Furthermore, Landlord shall not be liable under any circumstances for a loss of, or injury to, property or for injury to, or interference with, Tenant's business, including, without limitation, loss of profits, however occurring, through or in connection with or incidental to a failure to furnish any of the services or utilities as set forth in this Article 6.

  • Plant An electrical generating alternative energy resource facility developed by Producer for which IID shall provide transmission service, as specified in Exhibit(s) II, Transmission Service, and in any subsequent Plant Amendments.

  • PROJECT SERVICES Landlord shall furnish services as follows:

Time is Money Join Law Insider Premium to draft better contracts faster.