Site Lands or areas indicated in the Contract Documents as being furnished by the Owner upon which the Work is to be performed, including rights-of-way and easements for access thereto, and such other lands furnished by the Owner that are designated for the use of the Contractor. Also referred to as Project Site, Job Site and Premises.
Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever.
(ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties.
(iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority.
(iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i).
(v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party.
(vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway.
(vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.
Contractor’s Project Manager and Key Personnel Contractor shall appoint a Project Manager to direct the Contractor’s efforts in fulfilling Contractor’s obligations under this Contract. This Project Manager shall be subject to approval by the County and shall not be changed without the written consent of the County’s Project Manager, which consent shall not be unreasonably withheld. The Contractor’s Project Manager shall be assigned to this project for the duration of the Contract and shall diligently pursue all work and services to meet the project time lines. The County’s Project Manager shall have the right to require the removal and replacement of the Contractor’s Project Manager from providing services to the County under this Contract. The County’s Project manager shall notify the Contractor in writing of such action. The Contractor shall accomplish the removal within five (5) business days after written notice by the County’s Project Manager. The County’s Project Manager shall review and approve the appointment of the replacement for the Contractor’s Project Manager. The County is not required to provide any additional information, reason or rationale in the event it The County is not required to provide any additional information, reason or rationale in the event it requires the removal of Contractor’s Project Manager from providing further services under the Contract.
HHSC and Contractor Agreements HHSC and Contractor hereby agree:
A. That in the event any provision of this Contract becomes unenforceable or void all other provisions of this Contract will remain ineffect.
B. That the Contractor may not transfer or assign this Contract without the express prior written approval of HHSC.
C. That this Contract may be assigned to a state agency or agencies.
D. That HHSC may amend this Contract by written notice to the Contractor. HHSC reserves the right to amend this Contract through execution of a unilateral amendment signed by an HHSC person with delegated signature authority and provided to the Contractor under the following circumstances:
1. to correct an obvious clerical error in the Contract;
2. to incorporate new or revised federal or state statutes, rules or policies;
3. to comply with a court order or judgment; and
4. to change the name of the Contractor to reflect the Contractor's name as recorded by the Texas Secretary of State.
E. That nothing in this Contract or any conduct by a representative of HHSC relating to this Contract shall be construed as a waiver of the state's sovereign immunity to suit.
F. That neither party to this Contract waives its right to enforce a right under this Contract by failing to enforce or delaying the enforcement of any other right under this Contract.
G. That the Contractor is an independent contractor and not an employee of HHSC for any purpose. The Contractor and HHSC agreethat:
1. HHSC will not withhold or pay on behalf of the Contractor any sums for income tax, unemployment insurance, Social Security or any other withholding, or make available to the Contractor any of the benefits, including workers' compensation insurance coverage and health and retirement benefits, afforded to HHSC employees; and
2. the Contractor must indemnify HHSC from any liability, including attorneys' fees and legal expenses, incurred by HHSC with respect to claims that HHSC should have been withholding or making payments on behalf of the Contractor or providing benefits to the Contractor's employees.
H. That nothing in this Contract is intended to create a joint venture, a partnership or a principal-agent relationship.
I. That the Contractor assigns to HHSC all claims for overcharges associated with this Contract arising under the anti-trust laws of the United States, 15 U.S.C. §§ 1-38, or the anti-trust laws of the state of Texas, Tex. Bus. & Com. Code, §§ 15.01-.40.
J. That HHSC has authority to monitor and conduct fiscal and program compliance reviews of the Contractor and its subcontractor(s) to the extent of services provided under the terms of this Contract. The Contractor will grant on-site access at reasonable times to all records relating to services provided and payments received under the terms of this Contract to state and federal auditing agencies and personnel and representatives of HHSC and HHS when it is deemed necessary by such agencies for purposes of inspection, monitoring, auditing or evaluating Contractor's performance under this Contract and compliance with applicable state and federal laws, rules and regulations; the applicable HHSC provider handbook or manual; and this Contract. That for Title XX programs, HHSC shall, by Form 2029, Information Worksheet – POS Contract, set the rate or maximum amount of funds or both available to be paid to Contractor by HHSC. Form 2029 is incorporated into and made a part of this Contract and is effective for the time stated on the form. Form 2029 may be amended by HHSC as necessary to comply with state and federal laws and regulations or renewed by HHSC by a new Form 2029 and incorporated into and made part of this Contract.
K. That in compliance with §2262.003, Texas Government Code:
1. the state auditor may conduct an audit or investigation of any entity receiving funds from the state directly under the Contract or indirectly through a subcontract under the Contract;
2. acceptance of funds directly under the Contract or indirectly through a subcontract under the Contract acts as acceptance of the authority of the state auditor, under the direction of the legislative audit committee, to conduct an audit or investigation in connection with those funds; and
3. under the direction of the legislative audit committee, an entity that is the subject of an audit or investigation by the state auditor must provide the state auditor with access to any information the state auditor considers relevant to the investigation or audit.
L. That this Contract shall continue subject to the availability of appropriated funds or until the federal or state governments or both cease to participate in the program.
M. That any breach or violation of any of the provisions of this Contract or state or federal regulations shall make this entire Contract, at HHSC's option, subject to termination.
N. That if HHSC does not renew the Contractor's contract due to the Contractor's noncompliance with applicable federal or Texas statutes or rules, the Contractor cannot enter into another contract for a Community Services program until the application denial period established by HHSC expires.
O. That the venue for any lawsuit between HHSC and the Contractor shall be Travis County, Texas.
P. That this Contract may be terminated by:
Contractor Personnel Contractor's staff is expected to present a professional appearance. All personnel of the Contractor will be neat, well groomed, properly uniformed in industry standard uniforms and are expected to conduct themselves at all times in a responsible and courteous manner while performing any work under this Agreement and/or whenever they are on District property. The following code of conduct will be adhered to by the Contractor, his agent(s) and/or his employees. If Contractor fails to ensure that its employees or other agents comply with these requirements, then Contractor may be terminated for cause under this Agreement:
A. All employees of the Contractor shall wear a recognizable uniform. No hats will be worn inside the building. All of Contractor’s employees and agents performing work must carry a government-issued photo ID. Contractor’s employees and agents will present ID to District Staff upon request. This provision will be strictly enforced.
B. The use of tobacco or tobacco products on Board property is prohibited by State law.
C. The Contractor will not be permitted to utilize Day Labor or Temporary Workers to provide any services at any District facility. This includes any employees or agents that are hired prior to contract award. Failure to comply with this requirement could result in immediate termination of contract with the Contractor liable for any breach, including liquidated damages for delay damages and/or forfeiture of Performance Bond.
D. The Contractor or employees or agents of the Contractor are not permitted to play loud music, to make unnecessary noises, or to use vulgar or inappropriate language that causes offense to others.
E. The employment of unauthorized or illegal aliens by the Contractor is considered a violation of Section 247A (e) of the Immigration and Naturalization Act. If the Contractor knowingly employs unauthorized aliens, such a violation shall also be cause for termination of this Agreement.
F. Possession of firearms will not be tolerated on Board property. No person who has a firearm in their vehicle will be permitted to park on District property. Any employee of the Contractor found in violation of this policy will be immediately asked to leave, and will not be allowed to return to perform further work without the consent of the District.
G. The Contractor certifies that he/she will not engage in the unlawful manufacture, sale distribution, dispensation, possession, or use of a controlled substance or drug during the performance of the contract and that a drug-free workplace will be provided for the Contractor’s employees or agents during the performance of the contract. The Contractor also certifies that he will secure from any subcontractor who works on the contract, written certification of the same drug free workplace requirements. False certification or violation by failing to carry out requirements of O.C.G.A. § 50-24-3 may cause suspension, termination of contract, or debarment of such bidder Please Note: If any employee or agent of the Contractor or Sub-contractor is found to have brought a firearm on District property, the Contractor or Sub-contractor shall prohibit them from continuing to perform any work on District property. If the Contractor or Sub-contractor fails to do so, then the District may terminate this Agreement for cause as set forth below.
Sub-Contractors Transfer Agent may, without further consent on the part of Customer, subcontract with other subcontractors for telephone and mailing services as may be required from time to time; provided, however, that the Transfer Agent shall be as fully responsible to the Customer for the acts and omissions of any subcontractor as it is for its own acts and omissions.
Quality Management System Supplier hereby undertakes, warrants and confirms, and will ensue same for its subcontractors, to remain certified in accordance with ISO 9001 standard or equivalent. At any time during the term of this Agreement, the Supplier shall, if so instructed by ISR, provide evidence of such certifications. In any event, Supplier must notify ISR, in writing, in the event said certification is suspended and/or canceled and/or not continued.
Sites 11.1 To enable Digital Origin to fulfill its obligations under any Contract:
11.1.1 the Client shall permit or procure permission for Digital Origin and any other person(s) authorised by Digital Origin to have reasonable access to the Client’s Sites, Equipment and/or Leased Equipment and any other relevant telephone system and other equipment and shall provide such reasonable assistance as Digital Origin requests.
11.1.2 Digital Origin will normally carry out work by appointment and during Normal Working Hours but may request the Client to (and the Client shall) provide access at other times. In the event that the Client cancels, reschedules or misses any pre-arranged appointment, it shall be liable to Digital Origin for any costs and expenses which Digital Origin incurs as a result of such cancellation, rescheduling and/or missed appointment.
11.2 At the Client’s request, Digital Origin may agree (at its sole discretion) to work outside Normal Working Hours and the Client shall pay Digital Origin’s reasonable charges for complying with such a request.
11.3 The Client warrants, represents and undertakes that it has adequate health and safety provisions in place at its Sites.
11.4 The Client shall procure all consents, licences and permissions necessary from landlords or other third parties for the carrying out of preparation work, installation of Equipment and/or Leased Equipment and for the provision, use and operation of the Equipment and/or Leased Equipment and/or Services at the Sites (save to the extent Digital Origin has agreed in writing to do it).
11.5 In the event that the Client is not able to procure the necessary consent to provide the Services within ninety days of the Connection Date Digital Origin will be able to terminate the Contract forthwith by giving the Client written notice without any liability. If the Client has not managed to procure the necessary consents and Digital Origin has commenced work the Client shall, on request by Digital Origin, refund to Digital Origin the cost of all such work (including, without limitation, staff costs and equipment costs) of an amount no less than £500 as Early Termination Charges.
11.6 The Client shall provide Digital Origin with the site and building plans (to include full details of all internal cabling runs) of the Sites and provide Digital Origin with full details of all other services in the vicinity of the proposed works.
11.7 The Client is responsible for making the Site good after any work undertaken by Digital Origin at a Site, including without limitation replacing and re-siting items and for re-decorating.
11.8 If the Client is moving a Site, Digital Origin must be informed as soon as is reasonably practicable so that suitable arrangements can be made to transfer the Client’s Services and Equipment and/or Leased Equipment. Unless otherwise requested, Digital Origin, in addition to moving the Service and Equipment and/or Leased Equipment, will also endeavour (but cannot guarantee that it will be able, for example where the Client moves to a different exchange) to retain the Client’s relevant existing telephone number(s). If Digital Origin can transfer the Client’s existing number(s) to the new Site the existing Contract will continue under the same terms and conditions. If Digital Origin cannot transfer the Client’s existing number(s) to the new Site, installation of a new line will be required at the new Site, or if the Client requires any additional new lines, this will attract new line connection charges and a new Contract.
11.9 If the new installation or moving Site involves the visit of an engineer to facilitate the new installation the Client will be responsible for the costs incurred by Digital Origin for the appointment together with an administration fee in respect of any additional works required to be undertaken by Digital Origin to complete the transfer of the Services and Equipment and/or Leased Equipment.
11.10 If the Client moves Sites and leaves the Equipment and/or Leased Equipment for the new owner/tenant the Client is required to inform them that the Service will be discontinued if Digital Origin is not contacted by the new owner/tenant within 72 hours for the purpose of entering into a new contract with Digital Origin for such services and subject in any event to the agreement of such a contract.
11.11 If at the new Site the Client receives services from an alternative supplier the Client is responsible for any contractual agreement the Client has with them and any liabilities the Client may incur for terminating such agreement.
UNDERGROUND LOCATIONS Prior to the Company commencing any work the Customer must advise the Company of the precise location of all underground services on the site and clearly xxxx the location. The underground mains and services the Customer must identify include, but are not limited to, telephone cables, fibre optic cables, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigations pipes, oil pumping mains and any other services that may be on site. Whilst the Company will take all care to avoid damage to any underground services the Customer agrees to indemnify the Company in respect of all any liability claims, loss, damage, cost and fines as a result of damage to services not precisely located and notified pursuant to this clause.
Site Visits The Commission may visit the School at any time and may, at its discretion, conduct site visits and monitoring. When appropriate, the Commission shall make reasonable efforts to provide notice of visits. Such site visits may include any activities reasonably related to fulfillment of the Commission’s oversight responsibilities including, but not limited to, inspection of the facilities; audit of financial books and records; inspection of records maintained by the School; interviews and observations of the principal, staff, school families, staff of an affiliated nonprofit or educational service provider and community members; and observation of classroom instruction.
