Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.
Obligation to Repair Except as otherwise provided in this Article 12, if any part of the Premises, or any other portion of the Project necessary for Tenant’s use and occupancy of the Premises, is damaged or destroyed by Casualty, Landlord shall, within fifteen (15) days after such damage or destruction (“Casualty Discovery Date”), notify Tenant (a “Repair Notice”) of the estimated time, in Landlord’s reasonable judgment, required to repair such damage or destruction. If Landlord estimates that the necessary repairs can be completed within one hundred eighty (180) days after the date of the damage or destruction, and if Landlord receives insurance proceeds sufficient for such purpose, then (i) Landlord shall repair the Premises, and/or the portion of the Project necessary for Tenant’s use and occupancy of the Premises, to substantially the condition existing immediately before such damage or destruction (subject to Section 12.3 below), to the extent commercially reasonable, and as permitted by and subject to then applicable Requirements; (ii) this Lease shall remain in full force and effect; and (iii) to the extent such damage or destruction did not result solely from the negligence or willful act or omission of Tenant or any other Tenant Parties, Base Rent shall xxxxx for such part of the Premises rendered unusable by Tenant in the conduct of its business during the time such part is so unusable, in the proportion that the RSF of the unusable part of the Premises bears to the total RSF of the Premises. If Landlord’s estimate of the repair and restoration time is longer than one hundred eighty (180) days after the date of the damage or destruction, or if Landlord fails to timely deliver an estimated time of repair and restoration, Tenant shall have the right to terminate this Lease upon delivery of notice thereof to Landlord within ten (10) Business Days after Landlord’s delivery of the Repair Notice or the expiration of Landlord’s deadline to deliver the Repair Notice. If Tenant terminates this Lease pursuant to the foregoing, then this Lease shall terminate as of such damage or destruction unless Tenant has continued to use all or a portion of the Premises for the Permitted Use following the date of such damage or destruction, in which case this Lease shall terminate as of the date of Landlord’s receipt of Tenant’s termination notice.
Damage or Destruction of Premises If the Premises, the Unit or the Building or any part thereof shall be damaged or destroyed by fire or other casualty (a “casualty”), or ordered to be demolished by the action of any public authority in consequence of a casualty, or taken by any exercise of the right of eminent domain, Tenant shall immediately give notice thereof to Landlord. Unless this Lease is terminated as provided herein, this Lease shall remain in full force and effect and Landlord shall proceed (or shall cause the Primary Board to proceed) with diligence to repair or cause to be repaired such damage so as to restore the Premises, the Building and access thereto, or what may remain thereof (including the Initial Tenant Work but excluding any other Tenant Work), as nearly as practicable to the condition they were in immediately prior to such damage, destruction or taking, subject to then applicable Legal Requirements and Title Matters, but neither Landlord nor the Primary Board shall be required to expend in such repair or rebuilding more than the proceeds of insurance or award of damages, if any, recovered or recoverable with respect to such damage, destruction or taking (plus, in the case of casualty, the amount of any insurance deductibles (which shall be deemed Operating Costs)), less Landlord’s (or the Primary Board’s) reasonable expenses incurred in collecting such proceeds or award, as the case may be, but in the case of damage or destruction only to the extent Landlord was carrying the insurance required to be carried pursuant to this Lease at the time of such damage or destruction. All such repairs made necessary by any negligent act or omission or any willful misconduct of Tenant shall be made by Landlord (or the Primary Board) at Tenant’s expense to the extent that the cost of such repairs is not covered by insurance proceeds available therefor (including the payment by Tenant of any applicable deductible amount). Landlord shall not be liable for delays in the making of any such repairs that are due to Force Majeure, nor shall Landlord be liable for any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting from delays in repairing such damage. All repairs to and replacements of Tenant Property and any Tenant Work other than the Initial Tenant Work shall be made by and at the expense of Tenant, which work Tenant shall promptly commence as soon as practicable and thereafter prosecute diligently to completion.
Restoration of Tenant's Property If Tenant is required to restore any Property as hereinabove provided, Tenant shall either (a) restore all alterations and improvements made by Tenant and Tenant’s Personal Property, or (b) replace such alterations and improvements and Tenant’s Personal Property with improvements or items of the same or better quality and utility in the operation of such Property.
Alterations and Repairs Tenant shall not erect any drywall partitions, make any alterations in or additions or changes to the Premises without the Landlord’s prior written approval in each and every instance, which consent shall not be unreasonably withheld or delayed. Unless otherwise provided by written agreement, all Tenant’s Improvements upon the Premises and any replacements therefore, including, but not limited to all air-conditioning or heating systems, decorations, partitions, electrical systems affixed to the Premises, except furniture or movable trade fixtures installed at the expense of Tenant, shall become the property of the Landlord and shall remain upon, and be surrendered with, the Premises as a part thereof and at the termination of this Lease, without compensation to Tenant; unless, however, Landlord, by notice given the Tenant, shall elect to have Tenant remove any or all such Tenant Improvements. Thereupon Tenant shall accomplish such removal at its sole cost, repair any damage caused by such removal, and restore the Premises to their former condition. If Tenant does not remove said additions, decorations, fixtures, hardware, non-trade fixtures and improvements after request to do so by Landlord, Landlord may remove the same and Tenant shall pay the cost of such removal to the Landlord upon demand. Tenant hereby agrees to hold Landlord and Landlord’s beneficiaries, their agents and employees harmless from any and all liabilities of every kind and description which may arise out of or be connected in any way with said alterations or additions. Any mechanic’s lien filed against the Premises, or the Building or the Property, for work claimed to have been furnished to Tenant shall be discharged of record by Tenant within ten (10) days thereafter, at Tenant’s expense, provided however Tenant shall have the right to contest any such lien on the posting of reasonably sufficient security.
LANDLORD'S DUTY TO RESTORE If the Premises are damaged by any peril after the Effective Date, Landlord shall restore the Premises unless the Lease is terminated by Landlord pursuant to Section 11.2 or by Tenant pursuant to Section 11.3. All insurance proceeds available from the fire and property damage insurance carried by Landlord pursuant to Section 9.2 shall be paid to and become the property of Landlord. If this Lease is terminated pursuant to either Section 11.2 or Section 11.3, then all insurance proceeds available from insurance carried by Tenant which covers loss to property that is Landlord’s property or would become Landlord’s property on expiration or termination of this Lease shall be paid to and become the property of Landlord. If this Lease is not so terminated then upon receipt of the insurance proceeds (if the loss is covered by insurance) and the issuance of all necessary governmental permits, Landlord shall commence and diligently prosecute to completion the restoration of the Premises, to the extent then allowed by Law, to substantially the same condition in which the Premises were immediately prior to such damage. Landlord’s obligation to restore shall be limited to the Premises and interior improvements constructed by Landlord as they existed as of the Commencement Date, excluding any Tenant’s Alterations, Trade Fixtures and/or personal property constructed or installed by Tenant in the Premises. Tenant shall forthwith replace or fully repair all Tenant’s Alterations and Trade Fixtures installed by Tenant and existing at the time of such damage or destruction, and all insurance proceeds received by Tenant from the insurance carried by it pursuant to Section 9.1A(2) shall be used for such purpose.
Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Materiality Of Application To Rent All representations made by Xxxxxx(s) on the Application to Rent (or like-titled document) are material to the grant of this Lease, and the Lease is granted only on condition of the truthfulness and accuracy of said representations. If a failure to disclose or lack of truthfulness is discovered on said Application, Landlord may deem Tenant to be in breach of this Lease.
Damage Destruction and Condemnation (a) If all or any part of the Property shall be damaged or destroyed, or if title to or the temporary use of the whole or any part of the Property shall be taken or condemned by a competent authority for any public or quasi-public use or purpose, subject to the terms of the Indenture, there shall be no abatement or reduction in the amounts payable by Grantor under the Indenture and Grantor shall continue to be obligated to make such payments.
Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.
