Supervision of Contractor Personnel The Contractor must supply all necessary and sufficient supervision over the work that is being performed and will be held solely responsible for the conduct and performance of his employees or agents involved in work under the Agreement.
PROFESSIONAL GRIEVANCE PROCEDURE A. Any claim by the Association or a teacher that there has been a violation, misinterpretation, or misapplication of the terms of the Agreement or violation of any established policy shall be a grievance and shall be resolved through the procedure set forth herein.
B. In the event that a teacher, or the Association believes there is a basis for a grievance, the teacher or representative of the Association within thirty (30) working days of the time the teacher knew of the circumstances giving rise to the grievance, shall first discuss the alleged grievance with the building principal either personally or accompanied by the Association Representative. The grievance process may begin at the Superintendent’s level when the building principal is not involved with an alleged incident.
C. If, as a result of the informal discussion with the building principal, a grievance still exists, the teacher or representative of the Association may, within ten (10) working days, invoke the formal grievance procedure through the Association on the grievance report form, signed by the grievant and a representative of the Association. Said form shall be available from the Association Representative in each building. A copy of the grievance form shall be delivered to the building principal, it may be filed with the Superintendent or a representative designated by him.
D. Within five (5) working days of receipt of the grievance the principal shall meet with the Association in an effort to resolve the grievance. The principal shall indicate his/her disposition of the grievance in writing within five (5) working days of such meeting and shall furnish a copy thereof to the Association. If the Association desires to proceed to the next step, it shall do so within fifteen (15) calendar days of the principal’s disposition.
E. If the Association is not satisfied with the disposition of the grievance, or if no disposition has been made within five (5) working days of such meeting (or ten [10] working days from the date of filing, whichever shall be later) the grievance shall be transmitted to the Superintendent. Within seven (7) working days the Superintendent or his/her designee, shall meet with the Association concerning the grievance and shall indicate his/her disposition of the grievance in writing within five (5) working days of such meeting, and shall furnish a copy thereof to the Association.
F. If the Association is not satisfied with the disposition of the superintendent, or if no disposition has been received within five (5) working days of such meeting the Association may proceed to a Board Level Hearing. This grievance hearing shall be heard in closed session, so long as it does not violate the open meetings act. If the grievance is not settled at the preceding step, it may be submitted to binding arbitration. Within fifteen (15) working days of the receipt of the Superintendent’s answer, the party choosing to arbitrate must give written notice to the other party, setting forth specifically the nature of the dispute to be arbitrated. The charging party shall file a Demand for Arbitration with the American Arbitration Association within fifteen (15) days from the notification date that arbitration will be pursued. The arbitrator shall be selected by the American Arbitration Association in accordance with its rules, which shall likewise govern the arbitration proceedings.
G. The arbitrator shall have no power to rule on any of the following:
1. The termination of services of or failure to re-employ any probationary teacher.
2. Any claim or complaint for which there is another remedial procedure or forum established by law or by regulation having the force of law, including any matter subject to the procedures specified in the Teacher’s Tenure Act (Act IV Public Acts, Extra Session of 1937 of Michigan, as amended).
3. Any matter involving the content of a teacher evaluation.
H. The Board and the Association shall not be permitted to assert in such arbitration proceedings any ground or to rely on any evidence not previously disclosed to the other party. The arbitrator shall have no power to alter, add to, or subtract from the terms of this Agreement. Both parties agree to be bound by the decision of the arbitrator and agree that judgment thereon may be entered in any court of competent jurisdiction.
I. The fees and expense of the arbitrator shall be shared equally by both parties.
J. The time limits provided in this Article shall be strictly observed but may be extended by written agreement of the parties. In the event a grievance is filed after May 15 of any year and strict adherence to the time limits may result in hardship to any party, the Board shall use its best efforts to process such grievance prior to the end of the school term or as soon thereafter as possible.
Restricted Employment for Certain State Personnel Contractor acknowledges that, pursuant to Section 572.069 of the Texas Government Code, a former state officer or employee of a state agency who during the period of state service or employment participated on behalf of a state agency in a procurement or contract negotiation involving Contractor may not accept employment from Contractor before the second anniversary of the date the Contract is signed or the procurement is terminated or withdrawn.
Medical Procedures 21.01 The Board shall distribute a copy of its Operating Procedures for administration of prescribed medication to pupils in schools and Procedures for health support services to each Teacher.
21.02 In accordance with Operating Procedure Special Education Services 8, a Teacher may refuse without prejudice a request to administer medications except in life-threatening situations.
CONTRACTOR SUPERVISION Contractor shall provide competent supervision of personnel employed on the job Site, use of equipment, and quality of workmanship.
Referral Procedures Section 1. For Local Unions now having a job referral system as contained in their Collective Bargaining Agreement, the Contractor agrees to utilize such system and it shall be used exclusively by such Contractor, except as it may be modified by this Article. Referrals shall not be affected by obligations of Union membership or the lack thereof. Where airport security clearance requirements apply to work to be performed, the Contractor shall inform the Union’s hiring hall dispatcher of those requirements when requesting workers.
Section 2. In the event that Local Unions are unable to fill any request for employees within the time specified by the local CBAs the Contractor may employ applicants from any other available source. The Contractor shall inform the Union of the name and social security number of any applicants hired from other sources and shall refer the applicant to the Local Union for dispatch to the projects prior to the commencement of work.
Section 3. There shall be no discrimination against any employee or applicant for employment because of his/her membership or non-membership in the union or based upon race, creed, color, sex, age or national origin, or any other legally protected class of such employee or applicant.
Section 4. No employee covered by this Agreement shall be required to join any Union as a condition of being employed on the project; provided, however, that an employee who is a member of the referring union at the time of the referral shall maintain that membership while employed under the Agreement. All employees shall, however, be required to comply with the union security provision of the applicable Collective Bargaining Agreement, for the period during which they are performing on-site work, except as modified by this Agreement. The Contractor agrees to deduct union dues or representation fees, whichever is applicable, from the pay of any employee who executes a voluntary authorization for such deductions and to remit the dues to the Union or Council.
Section 5. The parties agree that where a Contractor is not party to a current Collective Bargaining Agreement with the Union having jurisdiction over the affected work, the Contractor may request by name, and the Local will honor, referral of up to a maximum of five (5) persons per each contractor (“core” employees), provided that the Contractor first demonstrate that those persons possess the following qualifications:
(1) Any license required by state or federal law for the project work to be performed;
(2) Have worked a total of at least one thousand (1,000) hours in the construction craft during the prior three (3) years;
(3) Were on the Contractor’s active payroll for at least sixty (60) out of the one hundred eighty (180) calendar days prior to the contract award;
(4) Have the ability to perform the work safely. The Contractor may elect to hire its first “core” employee to be a xxxxxxx. After the contractor hires his first core employee, the Union will refer to such contractor one journeyman employee from the hiring hall out-of–work list for the affected trade or craft, then refer one of such Contractor’s “core” employees as a journeyman, and shall, alternate, one core employee and one employee from the out-of-work list, until such Contractor’s crew requirements are met or until such Contractor has hired five (5) “core” employees, whichever occurs first. Thereafter, all additional employees in the affected trade or craft shall be hired exclusively from the hiring hall out-of-work list(s). For the duration of the Contractor’s work the ratio of “core” employees to hiring hall referrals shall be maintained and when the Contractor’s workforce is reduced, employees shall be reduced in the same ratio as was applied in the initial hiring. All employees, core and union, shall be dispatched from the appropriate union. Trust benefits shall be paid on all employees, core and union.
Section 6. Upon referral or dispatch from a Union, “turnaround” or refusal of any worker by the Contractors, requires written explanation from the Contractor that shall be communicated from the Prime Contractor to the Port and affected Union within 48 hours.
Section 7. Individual seniority will not be recognized or applied to employees working on the project. This provision will not interfere with or supersede the use by individual Contractors of “call lists” maintained by such Contractor pursuant to addenda to the local Collective Bargaining Agreement between such Contractor and a Union signatory to this Agreement.
Section 8. The selection of craft foremen and/or general foremen and the number of such foremen and/or general foremen required shall be entirely the responsibility of the Contractor. Craft foremen shall be designated working foremen at the request of the Contractor. Craft workers covered by this Agreement will, in the normal day- to-day operations, take their direction and supervision from their xxxxxxx.
INDEPENDENT PERSONAL SERVICES 1. Income derived by a resident of a Contracting State in respect of professional services or other activities of an independent character shall be taxable only in that State unless he has a fixed base regularly available to him in the other Contracting State for the purpose of performing his activities. If he has such a fixed base, the income may be taxed in the other State but only so much of it as is attributable to that fixed base.
2. The term “professional services” includes especially independent scientific, literary, artistic, educational or teaching activities as well as the independent activities of physicians, lawyers, engineers, architects, dentists and accountants.
Routing for Operator Services and Directory Assistance Traffic For a Verizon Telecommunications Service dial tone line purchased by CBB for resale pursuant to the Resale Attachment, upon request by CBB, Verizon will establish an arrangement that will permit CBB to route the CBB Customer’s calls for operator and directory assistance services to a provider of operator and directory assistance services selected by CBB. Verizon will provide this routing arrangement in accordance with, but only to the extent required by, Applicable Law. Verizon will provide this routing arrangement pursuant to an appropriate written request submitted by CBB and a mutually agreed-upon schedule. This routing arrangement will be implemented at CBB's expense, with charges determined on an individual case basis. In addition to charges for initially establishing the routing arrangement, CBB will be responsible for ongoing monthly and/or usage charges for the routing arrangement. CBB shall arrange, at its own expense, the trunking and other facilities required to transport traffic to CBB’s selected provider of operator and directory assistance services.
Customer Service, Dispute Resolution If you have a question about your XOOM charges or service you may contact XOOM directly by calling 0-000-000-0000 Monday – Friday 8 (eight) a.m. to 11 (eleven)p.m.
SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action.
B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities.
C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients.
D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel.
E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation.
F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.
