Audit and Inspection of Plants, Places of Business and Records (a) The State and its agents, including, but not limited to, the Connecticut Auditors of Public Accounts, Attorney General and State’s Attorney and their respective agents, may, at reasonable hours, inspect and examine all of the parts of the Contractor’s and Contractor Parties’ plants and places of business which, in any way, are related to, or involved in, the performance of this Contract.
(b) The Contractor shall maintain, and shall require each of the Contractor Parties to maintain, accurate and complete Records. The Contractor shall make all of its and the Contractor Parties’ Records available at all reasonable hours for audit and inspection by the State and its agents.
(c) The State shall make all requests for any audit or inspection in writing and shall provide the Contractor with at least twenty-four (24) hours’ notice prior to the requested audit and inspection date. If the State suspects fraud or other abuse, or in the event of an emergency, the State is not obligated to provide any prior notice.
(d) The Contractor will pay for all costs and expenses of any audit or inspection which reveals information that, in the sole determination of the State, is sufficient to constitute a breach by the Contractor under this Contract. The Contractor will remit full payment to the State for such audit or inspection no later than 30 days after receiving an invoice from the State. If the State does not receive payment within such time, the State may setoff the amount from any moneys which the State would otherwise be obligated to pay the Contractor in accordance with this Contract's Setoff provision.
(e) The Contractor shall keep and preserve or cause to be kept and preserved all of its and Contractor Parties’ Records until three (3) years after the latter of (i) final payment under this Contract, or (ii) the expiration or earlier termination of this Contract, as the same may be modified for any reason. The State may request an audit or inspection at any time during this period. If any Claim or audit is started before the expiration of this period, the Contractor shall retain or cause to be retained all Records until all Claims or audit findings have been resolved.
(f) The Contractor shall cooperate fully with the State and its agents in connection with an audit or inspection. Following any audit or inspection, the State may conduct and the Contractor shall cooperate with an exit conference.
(g) The Contractor shall incorporate this entire Section verbatim into any contract or other agreement that it enters into with any Contractor Party.
Payment of Checks, Drafts and Orders Subject to Section 9.5, the Assuming Institution agrees to pay all properly drawn checks, drafts and withdrawal orders of depositors of the Failed Bank presented for payment, whether drawn on the check or draft forms provided by the Failed Bank or by the Assuming Institution, to the extent that the Deposit balances to the credit of the respective makers or drawers assumed by the Assuming Institution under this Agreement are sufficient to permit the payment thereof, and in all other respects to discharge, in the usual course of conducting a banking business, the duties and obligations of the Failed Bank with respect to the Deposit balances due and owing to the depositors of the Failed Bank assumed by the Assuming Institution under this Agreement.
Audit Rights Period for Construction-Related Accounts and Records Accounts and records related to the design, engineering, procurement, and construction of Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades shall be subject to audit for a period of twenty-four months following Connecting Transmission Owner’s issuance of a final invoice in accordance with Article 12.2 of this Agreement.
Performance and Compliance with Contracts and Credit and Collection Policy The Seller shall (and shall cause the Servicer to), at its expense, timely and fully perform and comply with all material provisions, covenants and other promises required to be observed by it under the Contracts related to the Receivables, and timely and fully comply in all material respects with the applicable Credit and Collection Policies with regard to each Receivable and the related Contract.
PROHIBITION ON CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES OR EQUIPMENT To the extent applicable, Supplier certifies that during the term of this Contract it will comply with applicable requirements of 2 C.F.R. § 200.216.
Solicitations for Subcontracts, Including Procurements of Materials and Equipment In all solicitations either by competitive bidding or negotiation made by the Engineer for work to be performed under a subcontract, including procurements of materials or leases of equipment, each potential subcontractor or supplier shall be notified by the Engineer of the Engineer's obligations under this contract and the Regulations relative to nondiscrimination on the grounds of race, color, or national origin.
Accounts and Payments in Respect of General Intangibles (a) In addition to, and not in substitution for, any similar requirement in the Credit Agreement, if required by the Collateral Agent at any time during the continuance of (A) an Event of Default under clause (a) or clause (e)(ii) of Section 9.1 of the Credit Agreement or (B) any other Event of Default in connection with the exercise of remedies by the Administrative Agent pursuant to Section 9.2 of the Credit Agreement, (i) any payment of accounts or payment in respect of general intangibles, when collected by any Grantor, shall be promptly (and, in any event, within 2 Business Days) deposited by such Grantor in the exact form received, duly indorsed by such Grantor to the Collateral Agent, in a Security Cash Collateral Account, subject to withdrawal by the Collateral Agent as provided in Section 6.4, and (ii) until so turned over, such payment shall be held by such Grantor in trust for the Collateral Agent, segregated from other funds of such Grantor. Each such deposit of proceeds of accounts and payments in respect of general intangibles shall be accompanied by a report identifying in reasonable detail the nature and source of the payments included in the deposit.
(b) At any time during the continuance of (A) an Event of Default under clause (a) or clause (e)(ii) of Section 9.1 of the Credit Agreement or (B) any other Event of Default in connection with the exercise of remedies by the Administrative Agent pursuant to Section 9.2 of the Credit Agreement:
(i) each Grantor shall, upon the Collateral Agent’s request, deliver to the Collateral Agent all original and other documents evidencing, and relating to, the Contractual Obligations and transactions that gave rise to any account or any payment in respect of general intangibles, including all original orders, invoices and shipping receipts and notify account debtors that the accounts or general intangibles have been collaterally assigned to the Collateral Agent and that payments in respect thereof shall be made directly to the Collateral Agent; and
(ii) the Collateral Agent may, without notice, limit or terminate the authority of a Grantor to collect its accounts or amounts due under general intangibles or any thereof and, in its own name or in the name of others, communicate with account debtors to verify with them to the Collateral Agent’s satisfaction the existence, amount and terms of any account or amounts due under any general intangible. In addition, the Collateral Agent may (at the direction of the Administrative Agent) at any time enforce such Grantor’s rights against such account debtors and obligors of general intangibles.
(c) At any time during the continuance of an Event of Default, each Grantor shall take all actions, deliver all documents and provide all information necessary or reasonably requested by the Collateral Agent (at the direction of the Administrative Agent) to ensure any Internet Domain Name is registered.
(d) Anything herein to the contrary notwithstanding, each Grantor shall remain liable under each account and each payment in respect of general intangibles to observe and perform all the conditions and obligations to be observed and performed by it thereunder, all in accordance with the terms of any agreement giving rise thereto. No Secured Party shall have any obligation or liability under any agreement giving rise to an account or a payment in respect of a general intangible by reason of or arising out of any Loan Document or the receipt by any Secured Party of any payment relating thereto, nor shall any Secured Party be obligated in any manner to perform any obligation of any Grantor under or pursuant to any agreement giving rise to an account or a payment in respect of a general intangible, to make any payment, to make any inquiry as to the nature or the sufficiency of any payment received by it or as to the sufficiency of any performance by any party thereunder, to present or file any claim, to take any action to enforce any performance or to collect the payment of any amounts that may have been assigned to it or to which it may be entitled at any time or times.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Direction to Account Debtors; Contracting Parties; etc Upon the occurrence and during the continuance of an Event of Default, if the Collateral Agent so directs any Assignor, such Assignor agrees (x) to cause all payments on account of the Receivables and Contracts to be made directly to one or more Cash Collateral Accounts (as the Collateral Agent shall so direct), (y) that the Collateral Agent may, at its option, directly notify the obligors with respect to any Receivables and/or under any Contracts to make payments with respect thereto as provided in the preceding clause (x), and (z) that the Collateral Agent may enforce collection of any such Receivables and Contracts and may adjust, settle or compromise the amount of payment thereof, in the same manner and to the same extent as such Assignor. Without notice to or assent by any Assignor, the Collateral Agent may, upon the occurrence and during the continuance of an Event of Default, apply any or all amounts then in, or thereafter deposited in, the Cash Collateral Accounts which application shall be effected in the manner provided in Section 7.4 of this Agreement. The reasonable costs and expenses (including reasonable attorneys' fees) of collection, whether incurred by an Assignor or the Collateral Agent, shall be borne by the relevant Assignor. The Collateral Agent shall deliver a copy of each notice referred to in the preceding clause (y) to the relevant Assignor, provided, that the failure by the Collateral Agent to so notify such Assignor shall not affect the effectiveness of such notice or the other rights of the Collateral Agent created by this Section 3.3.
