OWNER SUSPENSION Sample Clauses

OWNER SUSPENSION. Should the Owner order the Contractor in writing to suspend, delay, or interrupt the performance of this Agreement or any part which affects the Work for such period of time as may be determined to be appropriate for the convenience of the Owner and not due to any act or omission of the Contractor or any other person or entity for whose acts or omissions the Contractor may be liable, then the Contractor shall immediately suspend, delay or interrupt that portion of the Work as ordered by the Owner.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
OWNER SUSPENSION. Owner may suspend performance of a portion, or all of the Work by giving Notice to Contractor. Contractor shall not be obligated to resume its construction obligations until such time as directed by Owner. When Contractor resumes its construction obligations, the delay shall be treated as a Change in the Work pursuant to Article XVI. Contractor’s Exhibit F shall be adjusted so that Contractor shall have no obligation to engage in construction at a more rapid pace than it would have had to prior to such suspension unless and on the condition that Owner shall agree to reimburse Contractor for any additional costs associated with an acceleration of Contractor’s construction schedule. In the event of any such suspension, Owner shall compensate Contractor for those costs incurred during the suspension period that are documented by Contractor to the reasonable satisfaction of Owner, attributable solely to the suspension, and are: (a) for the purpose of safeguarding and/or storing the Work and the materials and equipment at the point of fabrication, in transit or at the Job Site; (b) for personnel, Subcontractor or rented equipment, the payments of which, with Owner’s prior written approval, which approval shall not be unreasonably withheld, is continued during the suspension period; or (c) for reasonable costs of demobilization and remobilization. The rights of Owner to suspend Work for change orders, as provided in Section 16.03, are in addition to, and not subject to, the provisions of this Section 22.01.
Sample 1
OWNER SUSPENSION. The NOPs accept that the Owner may without cause and for any reason at any time at the Owner's discretion issue a written notice directing the Participants to suspend the performance of the whole or any part of any Alliance Works for any time period as the Owner decides.
Sample 1
OWNER SUSPENSION. Should the Owner order the Contractor in writing to suspend, delay, or interrupt the performance of this Agreement or any part which affects the Work for such period of time as may be determined to be appropriate for the convenience of the Owner and not due to any act or omission of the Contractor or any other person or entity for whose acts or omissions the Contractor may be liable, then the Contractor shall immediately suspend, delay or AGC DOCUMENT NO. 200 STANDARD FORM OF AGREEMENT AND GENERAL CONDITIONS BETWEEN OWNER AND CONTRACTOR (Where the Contract Price is a Lump Sum) 1997, The Associated General Contractors of America interrupt that portion of the Work as ordered by the Owner.
Sample 1
OWNER SUSPENSION. Should the Owner order the Contractor in writing to suspend, delay, or interrupt the performance of this Agreement or any part which affects the Work for such period of time as may be determined to be appropriate for the convenience of the Owner and not due to any act or omission of the Contractor or any other person or entity for whose acts or omissions the Contractor may be liable, then the Contractor shall immediately suspend, delay or interrupt that portion of the Work as AGC DOCUMENT NO. 200 STANDARD FORM OF AGREEMENT AND GENERAL CONDITIONS BETWEEN OWNER AND CONTRACTOR (Where the Contract Price is a Lump Sum) 1997, The Associated General Contractors of America ordered by the Owner.
Sample 1
OWNER SUSPENSION. Should the Owner order the Design-Builder in writing to suspend, delay, or interrupt the performance of the Work for such period of time as may be determined to be appropriate for the convenience of the Owner and not due to any act or omission of the Design-Builder or any person or entity for whose acts or omissions the Design-Builder may be liable, then the Design-Builder shall immediately suspend, delay or interrupt that portion of the Work as ordered by the Owner. The Contract Price and the Contract Time shall be equitably adjusted by Change Order for the cost and delay resulting from any such suspension.
Sample 1

Related to OWNER SUSPENSION

  • Service Suspension 8.1 By giving reasonable notice to you, or if this is not practicable, such notice as is reasonably practicable in the circumstances, we may suspend the Service (or any part of the Service) for reasons to include but not limited to: 8.1.1 for operational reasons in accordance with the service levels, or 8.1.2 if required because of a regulatory or legal change, or 8.1.3 if we are obliged to comply with the order, instruction, or request of a court, government, agency, emergency service organisation, or other competent administrative or regulatory authority, requiring suspension to the Service, or 8.1.4 if your use of the Service may damage or disrupt the proper functioning of the infrastructure and / or equipment used to provide services to our other Customers, or 8.1.5 if we have reasonable grounds to believe that you are in breach of your obligations, and you either fail to remedy that breach or fail to demonstrate to our reasonable satisfaction that no breach took place within two (2) Working Days of written notice of the suspected breach for a serious breach (serious breach to include, but not limited to, a breach likely to cause serious damage to us or our brand, or that of our contractors, or result in legal action by a third party) or within ten (10) Working Days of written notice of the suspected breach for other breach, or 8.1.6 if an undisputed invoice (or an undisputed part of an invoice) is not paid in full by the due date, provided that we have given you at least five (5) Working Days’ notice of such non- payment. 8.2 Suspension of the Service shall cause our service level obligations to be excluded for the period of the suspension. Such suspension of the Service shall continue for as long as any of the circumstances in Clauses 8 continues.

  • Post Suspension 1. Without prejudice to the procedures in Article 190 (Examination of the Benefit Suspension Level), if the Party complained against considers that it has eliminated the non-conformity that the Panel has found, it may provide written notice to the complaining Party with a description of how non-conformity has been removed. If the complaining Party has disagreement, it may refer the matter to the original Panel within 60 days after receipt of such written notice. Otherwise, the complaining Party shall promptly stop the suspension of benefits. 2. The Panel shall release its report within 60 days after the referral of the matter. If the Panel concludes that the Party complained against has eliminated the non-conformity, the complaining Party shall promptly stop the suspension of benefits.

  • Termination and Suspension Customer is entitled to suspend the performance of its obligations in whole or in part or terminate the Agreement with immediate effect, without prejudice to its right to claim damages and without any compensation to or indemnification of Supplier (i) in case Supplier has been declared bankrupt, is in a state of liquidation, has ceased or suspended whole or a substantial part of its business, is subject of a court order or preventative legal scheme of settlement, (ii) in case of non- compliance with the Compliance Requirements or the provisions of safety, health, environment and security or (iii) in case of not approved changes pursuant to article 10. After such termination Customer may return received Goods and/or Services in whole or partly against repayment and retransfer of ownership therein to Supplier.

  • Notice of Suspension The importer and the applicant shall be promptly notified of the suspension of the release of goods according to Article 51.

  • CERTIFICATION REGARDING DEBARMENT AND SUSPENSION The undersigned (authorized official signing for the contracting organization) certifies to the best of his or her knowledge and belief, that the contractor, defined as the primary participant in accordance with 45 CFR Part 76, and its principals: are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from covered transactions by any Federal Department or agency have not within a 3-year period preceding this contract been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; are not presently indicted or otherwise criminally or civilly charged by a governmental entity (Federal, State, or local) with commission of any of the offenses enumerated in Section 2 of this certification; and have not within a 3-year period preceding this contract had one or more public transactions (Federal, State, or local) terminated for cause or default. Should the Contractor or Subrecipient not be able to provide this certification, an explanation as to why should be placed after the assurances page in the contract. The contractor agrees by signing this contract that it will include, without modification, the clause above certification in all lower tier covered transactions (i.e., transactions with sub-grantees and/or contractors) and in all solicitations for lower tier covered transactions in accordance with 45 CFR Part 76.

  • Termination; Suspension Your right to use the Online Backup Feature will terminate on expiration of the Service Period. Symantec may immediately suspend or terminate use of the Online Backup Feature during the Service Period for Your failure to or Symantec’s reasonable belief that You have failed to comply with these terms and conditions (other than a trivial or inconsequential breach) or any other misuse of the Online Backup Feature. Following the expiration or termination of the Service Period:  Symantec may permanently delete any Data stored to the online backup space provided with Your Software and Services ;  Symantec will not be obligated to maintain such Data, forward such Data to You or a third party, or migrate such Data to another backup service or account; and  You will not be able to store the Data to any additional backup space that You may have purchased separately unless and until the Service Period is renewed.

  • Additional Event of Suspension Section 4.01. Pursuant to Section 6.02 (l) of the General Conditions, the following additional event is specified, namely, that a situation has arisen which shall make it improbable that the Program, or a significant part thereof, will be carried out.

  • No Suspension Trading in the Common Stock shall not have been suspended on the Exchange and the Common Stock shall not have been delisted from the Exchange.

  • CERTIFICATION REGARDING DEBARMENT OR SUSPENSION Contractor certifies that neither Contractor or its principals; its subcontractors or their principals; the sub-recipients (if applicable) or their principals are suspended, debarred, proposed for debarment, voluntarily excluded from covered transactions, or otherwise disqualified by any federal department or agency from doing business with the Federal Government pursuant to Executive Orders 12549 and 12689. Contractor specifically covenants that neither the Contractor or its principals, its sub-contractors or their principals, or the sub-recipients (if applicable) or their principals are included on the Excluded Parties List System (“EPLS”) maintained by the General Services Administration (“GSA”).

  • Certification Regarding Debarment, Suspension, and Other Responsibility Matters The Contractor identified in Section 1.3 of the General Provisions agrees to comply with the provisions of Executive Office of the President, Executive Order 12549 and 45 CFR Part 76 regarding Debarment, Suspension, and Other Responsibility Matters, and further agrees to have the Contractor’s representative, as identified in Sections 1.11 and 1.12 of the General Provisions execute the following Certification: INSTRUCTIONS FOR CERTIFICATION 1. By signing and submitting this Agreement, the prospective primary participant is providing the certification set out below. 2. The inability of a person to provide the certification required below will not necessarily result in denial of participation in this covered transaction. If necessary, the prospective participant shall submit an explanation of why it cannot provide the certification. The certification or explanation will be considered in connection with the NH Department of Health and Human Services’ (DHHS) determination whether to enter into this transaction. However, failure of the prospective primary participant to furnish a certification or an explanation shall disqualify such person from participation in this transaction. 3. The certification in this clause is a material representation of fact upon which reliance was placed when DHHS determined to enter into this transaction. If it is later determined that the prospective primary participant knowingly rendered an erroneous certification, in addition to other remedies available to the Federal Government, DHHS may terminate this transaction for cause or default. 4. The prospective primary participant shall provide immediate written notice to the DHHS agency to whom this Agreement is submitted if at any time the prospective primary participant learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances. 5. The terms “covered transaction,” “debarred,” “suspended,” “ineligible,” “lower tier covered transaction,” “participant,” “person,” “primary covered transaction,” “principal,” “proposal,” and “voluntarily excluded,” as used in this clause, have the meanings set out in the Definitions and Coverage sections of the rules implementing Executive Order 12549: 45 CFR Part 76. See xxxxx://xxx.xxxxxxx.xxx/app/details/CFR-2004-title45-vol1/CFR-2004-title45-vol1-part76/context. 6. The prospective primary participant agrees by submitting this Agreement that, should the proposed covered transaction be entered into, it shall not knowingly enter into any lower tier covered transaction with a person who is debarred, suspended, declared ineligible, or voluntarily excluded from participation in this covered transaction, unless authorized by DHHS. 7. The prospective primary participant further agrees by submitting this proposal that it will include the clause titled “Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion - Lower Tier Covered Transactions,” provided by DHHS, without modification, in all lower tier covered transactions and in all solicitations for lower tier covered transactions. 8. A participant in a covered transaction may rely upon a certification of a prospective participant in a lower tier covered transaction that it is not debarred, suspended, ineligible, or involuntarily excluded from the covered transaction, unless it knows that the certification is erroneous. A participant may decide the method and frequency by which it determines the eligibility of its principals. Each participant may, but is not required to, check the Nonprocurement List (of excluded parties) xxxxx://xxx.xxxx.xxx/current/title-22/chapter-V/part-513. 9. Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render in good faith the certification required by this clause. The knowledge and information of a participant is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings. 10. Except for transactions authorized under paragraph 6 of these instructions, if a participant in a covered transaction knowingly enters into a lower tier covered transaction with a person who is suspended, debarred, ineligible, or voluntarily excluded from participation in this transaction, in addition to other remedies available to the Federal government, DHHS may terminate this transaction for cause or default. PRIMARY COVERED TRANSACTIONS 11. The prospective primary participant certifies to the best of its knowledge and belief, that it and its principals: 11.1. Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from covered transactions by any Federal department or agency; 11.2. Have not within a three-year period preceding this proposal (Agreement) been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State or local) transaction or a contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; 11.3. Are not presently indicted for otherwise criminally or civilly charged by a governmental entity (Federal, State or local) with commission of any of the offenses enumerated in paragraph (l)(b) of this certification; and 11.4. Have not within a three-year period preceding this application/proposal had one or more public transactions (Federal, State or local) terminated for cause or default. 12. Where the prospective primary participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal (contract). LOWER TIER COVERED TRANSACTIONS 13. By signing and submitting this lower tier proposal (Agreement), the prospective lower tier participant, as defined in 45 CFR Part 76, certifies to the best of its knowledge and belief that it and its principals: 13.1. Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any federal department or agency. 13.2. Where the prospective lower tier participant is unable to certify to any of the above, such prospective participant shall attach an explanation to this proposal (Agreement). 14. The prospective lower tier participant further agrees by submitting this proposal (Agreement) that it will include this clause entitled “Certification Regarding Debarment, Suspension, Ineligibility, and Voluntary Exclusion - Lower Tier Covered Transactions,” without modification in all lower tier covered transactions and in all solicitations for lower tier covered transactions.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!