Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
Landlord’s Right to Enter Landlord and its agents shall have the right to enter the Leased Premises during normal business hours after giving Tenant reasonable notice (which shall be prior written notice except in the event of a circumstance which Landlord in good faith believes to be an emergency) and subject to Tenant’s reasonable security measures for the purpose of (i) inspecting the same; (ii) showing the Leased Premises to prospective purchasers, mortgagees or, during the last nine (9) months of the Lease Term or during any period that Tenant is in monetary or material non-monetary default beyond the applicable cure period, if any, expressly set forth in this Lease, tenants; (iii) making necessary alterations, additions or repairs; and (iv) performing any of Tenant’s obligations when Tenant has failed to do so after the expiration of any applicable notice and cure period expressly set forth in this Lease. Landlord shall have the right to enter the Leased Premises during normal business hours (or as otherwise agreed), subject to Tenant’s reasonable security measures, for purposes of supplying any maintenance or services agreed to be supplied by Landlord. Landlord shall have the right to enter the Common Areas during normal business hours for purposes of (i) inspecting the exterior of the Building and the Common Areas; (ii) posting notices of nonresponsibility (and for such purposes Tenant shall provide Landlord at least ten (10) days’ prior written notice of any work to be performed on the Leased Premises, as well as notice within one (1) day after the commencement of such work); and (iii) supplying any services to be provided by Landlord. Landlord shall also have the right, upon reasonable advance notice to Tenant, to access the Building’s vertical risers and the interstitial space above Tenant’s acoustical ceiling to connect new utility and communications lines from other floors to the base Building utility lines; all of such work shall be done after hours or on weekends. Any entry into the Leased Premises or the Common Areas obtained by Landlord in accordance with this paragraph shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of, the Leased Premises, or an eviction, actual or constructive of Tenant from the Leased Premises or any portion thereof. Landlord shall conduct all of Landlord’s activities on the Leased Premises during such period of entry in a manner designed to cause minimal interference to Tenant and Tenant’s use of the Leased Premises.
Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT.
B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate.
B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner.
B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment.
B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.
LANDLORD'S RIGHT TO PERFORM TENANT'S OBLIGATIONS (a) Without limiting the rights and remedies of Landlord contained in Sections 20.2 and 20.3 above, if Tenant shall be in default in the performance of any of the terms, provisions, covenants or conditions to be performed or complied with by Tenant pursuant to this Lease, then Landlord may at Landlord’s option, without any obligation to do so, and without notice to Tenant perform any such term, provision, covenant, or condition, or make any such payment and Landlord by reason of so doing shall not be liable or responsible for any loss or damage thereby sustained by Tenant or anyone holding under or through Tenant or any of Tenant’s Agents.
(b) Without limiting the rights of Landlord under Sections 20.2 and 20.3 above, Landlord shall have the right at Landlord’s option, without any obligation to do so, to perform any of Tenant’s covenants or obligations under this Lease without notice to Tenant in the case of an emergency, as determined by Landlord in its sole and absolute judgment, or if Landlord determines, in its sole and absolute judgment, that such action is necessary or desirable to avoid imminent harm to the Premises or any persons.
(c) If Landlord performs any of Tenant’s obligations hereunder in accordance with this Section 20.4, the full amount of the cost and expense incurred or the payment so made or the amount of the loss so sustained shall immediately be owing by Tenant to Landlord, and Tenant shall promptly pay to Landlord upon demand, as Additional Charges, the full amount thereof with interest thereon from the date of payment by Landlord at the lower of (i) ten percent (10%) per annum, or (ii) the highest rate permitted by applicable law.
Landlord’s Right to Terminate Landlord shall have the right to terminate this Lease in the event any of the following occurs, which right may be exercised by delivery to Tenant of a written notice of election to terminate within forty-five (45) days after the date of such damage:
A. The Project is damaged by an Insured Peril to such an extent that the estimated cost to restore exceeds ten percent (10%) of the then actual replacement cost thereof, or the Building in which the Premises is located is damaged to such an extent that the estimated cost to restore exceeds twenty-five percent (25%) of the then actual replacement cost thereof;
B. Either the Project or the Building is damaged by an Uninsured Peril to such an extent that the estimated cost to restore exceeds two percent (2%) of the then actual replacement cost of the Building;
C. The Premises are damaged by any peril within twelve (12) months of the last day of the Lease Term to such an extent that the estimated cost to restore equals or exceeds an amount equal to six (6) times the Base Monthly Rent then due; or
D. Either the Project or the Building is damaged by any peril and, because of the Laws then in force, (i) cannot be restored at reasonable cost to substantially the same condition in which it was prior to such damage, or (ii) cannot be used for the same use being made thereof before such damage if restored as required by this Article.
E. As used herein, the following terms shall have the following meanings: (i) the term “Insured Peril” shall mean a peril actually insured against for which the insurance proceeds actually received by Landlord (and which are not required to be paid to any Lender) are sufficient (except for any “deductible” amount specified by such insurance) to restore the Project under then existing Laws to the condition existing immediately prior to the damage; and (ii) the term “Uninsured Peril” shall mean any peril which is not an Insured Peril. Notwithstanding the foregoing, if the “deductible” for earthquake or flood insurance exceeds two percent (2%) of the replacement cost of the improvements insured, such peril shall, at Landlord’s election, be deemed an “Uninsured Peril” for purposes of this Lease.
Landlord’s Right to Perform Tenant’s Covenants Tenant covenants and agrees that, if it shall at any time fail to make any payment or perform any other act on its part to be made or performed as in this Lease provided, then Landlord, in its sole discretion may after due notice to, or demand upon, Tenant and subject to the limitations set forth below, make any payment or perform any other act on the part of Tenant to be made and performed as in this Lease provided, in such manner and to such extent as Landlord may reasonably deem desirable, and in exercising any such rights, Landlord may pay necessary and incidental costs and expenses, employ counsel, and incur and pay reasonable attorneys’ fees. The making of any such payment or the performing of any other act by Landlord pursuant to this Article shall not waive, or release Tenant from, any obligations of Tenant in this Lease contained. All sums so paid by Landlord and all reasonably necessary and incidental costs and expenses in connection with the performance of any such act by Landlord shall, except as otherwise in this Lease expressly provided, be payable to Landlord on demand, and Tenant covenants to pay any such sum or sums promptly, and Landlord shall have (in addition to any other right or remedy of Landlord) the same rights and remedies in the event of the non-payment thereof by Tenant as in the case of default by Tenant in the payment of the Base Rent. Whenever practicable, Landlord, before proceeding as provided in this Section 12.4, shall give Tenant notice in writing of the failure of Tenant which Landlord proposes to remedy, and shall allow Tenant such length of time as may be reasonable in the circumstances, consistent with any grace periods contained herein, but not exceeding 30 days from the giving of notice, to remedy the failure itself and, if Tenant shall not remedy the failure in the time so allowed, Landlord shall be deemed to have given “due notice” and may proceed as provided in this Section 12.4; provided that nothing in this Section shall prevent Landlord from acting without notice to Tenant in case of any emergency wherein there is danger to property or person or where there may exist any violation of legal requirements including but not limited to the presence of Hazardous Materials, in which event no notice shall be required.
Right to Seek Assurance The Transfer Agent may refuse to transfer, exchange or redeem shares of the Fund or take any action requested by a shareholder until it is satisfied that the requested transaction or action is legally authorized or until it is satisfied there is no basis for any claims adverse to the transaction or action. It may rely on the provisions of the Uniform Act for the Simplification of Fiduciary Security Transfers or the Uniform Commercial Code. The Company shall indemnify the Transfer Agent for any act done or omitted to be done in reliance on such laws or for refusing to transfer, exchange or redeem shares or taking any requested action if it acts on a good faith belief that the transaction or action is illegal or unauthorized.
LANDLORD'S RIGHT TO INSPECT Tenant shall permit Landlord and its authorized representatives to inspect the Leased Property, or any portion thereof, during usual business hours upon not less than forty-eight (48) hours’ notice and to make such repairs as Landlord is permitted or required to make pursuant to the terms of this Agreement, provided that any inspection or repair by Landlord or its representatives will not unreasonably interfere with Tenant’s use and operation of the Leased Property and further provided that in the event of an emergency, as determined by Landlord in its reasonable discretion, prior Notice shall not be necessary.
