Owner's Right to Suspend Completion of the Services Sample Clauses

Owner's Right to Suspend Completion of the Services. Owner may elect to suspend completion of all or any part of the Services upon ten days' prior written notice to Contractor (or, in Emergency situations, upon such prior notice as circumstances permit) indicating (a) the portion of the Services the completion of which Owner has elected to defer; (b) Owner's estimate of the duration of such suspension; and (c) the effective date of such suspension of the Services. Upon receipt of and consistent with the effective date of such notice, Contractor shall stop performance of the Services which Owner has elected to defer and shall continue to complete performance of the balance of the Services. In the event of a suspension of the Services pursuant to this Section 15.1.1, Owner shall (i) within fifteen (15) days after receipt from Contractor of an invoice and such supporting documentation as Owner reasonably requires to verify the invoiced amounts, pay to Contractor the sum of (1) such amount, if any, of the unpaid Contract Price that is representative of the actual stage of completion of the Services being deferred that have been performed to date and not previously compensated for through Contract Price payments made through such date (as reasonably determined based upon the percentage completion of applicable milestones relating to such deferred work as set forth in the Payment and Milestone Schedule or as otherwise mutually and reasonably agreed upon by the Parties), plus (2) if and to the extent appropriate based upon the duration and scope of the suspension, such reasonable demobilization costs incurred by Contractor as a result of such suspension, and (ii) authorize a Scope Change Order making equitable adjustments to one or more of the Guaranteed Completion Dates, the Construction Progress Milestone Dates, the Contract Price, the Payment and Milestone Schedule, the Project Schedule, the Performance Guarantees and such other provisions of this Agreement 128 which may be affected thereby, as appropriate. Contractor shall mitigate expenses to be borne by Owner as a result of suspension of the Services pursuant to this Section 15.1.1.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs

Related to Owner's Right to Suspend Completion of the Services

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • Right to suspend 2.1.1 Network Rail may serve a Suspension Notice where a Train Operator Event of Default has occurred and is continuing. 2.1.2 The Train Operator may serve a Suspension Notice where a Network Rail Event of Default has occurred and is continuing.

  • No Right to Subcontracting Subcontractor may not subcontract, either part or in whole, the Services authorized under this Agreement.

  • Right to Subcontract The Carrier at its discretion may subcontract on any terms the whole or any part of the Carriage.

  • OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.

  • Right to Seek Assurance The Transfer Agent may refuse to transfer, exchange or redeem shares of the Fund or take any action requested by a shareholder until it is satisfied that the requested transaction or action is legally authorized or until it is satisfied there is no basis for any claims adverse to the transaction or action. It may rely on the provisions of the Uniform Act for the Simplification of Fiduciary Security Transfers or the Uniform Commercial Code. The Company shall indemnify the Transfer Agent for any act done or omitted to be done in reliance on such laws or for refusing to transfer, exchange or redeem shares or taking any requested action if it acts on a good faith belief that the transaction or action is illegal or unauthorized.

  • Landlord’s Right to Terminate Landlord shall have the right to terminate this Lease in the event any of the following occurs, which right may be exercised by delivery to Tenant of a written notice of election to terminate within forty-five (45) days after the date of such damage: A. The Project is damaged by an Insured Peril to such an extent that the estimated cost to restore exceeds ten percent (10%) of the then actual replacement cost thereof, or the Building in which the Premises is located is damaged to such an extent that the estimated cost to restore exceeds twenty-five percent (25%) of the then actual replacement cost thereof; B. Either the Project or the Building is damaged by an Uninsured Peril to such an extent that the estimated cost to restore exceeds two percent (2%) of the then actual replacement cost of the Building; C. The Premises are damaged by any peril within twelve (12) months of the last day of the Lease Term to such an extent that the estimated cost to restore equals or exceeds an amount equal to six (6) times the Base Monthly Rent then due; or D. Either the Project or the Building is damaged by any peril and, because of the Laws then in force, (i) cannot be restored at reasonable cost to substantially the same condition in which it was prior to such damage, or (ii) cannot be used for the same use being made thereof before such damage if restored as required by this Article. E. As used herein, the following terms shall have the following meanings: (i) the term “Insured Peril” shall mean a peril actually insured against for which the insurance proceeds actually received by Landlord (and which are not required to be paid to any Lender) are sufficient (except for any “deductible” amount specified by such insurance) to restore the Project under then existing Laws to the condition existing immediately prior to the damage; and (ii) the term “Uninsured Peril” shall mean any peril which is not an Insured Peril. Notwithstanding the foregoing, if the “deductible” for earthquake or flood insurance exceeds two percent (2%) of the replacement cost of the improvements insured, such peril shall, at Landlord’s election, be deemed an “Uninsured Peril” for purposes of this Lease.

  • Landlord’s Right to Perform Tenant’s Covenants Tenant covenants and agrees that, if it shall at any time fail to make any payment or perform any other act on its part to be made or performed as in this Lease provided, then Landlord, in its sole discretion may after due notice to, or demand upon, Tenant and subject to the limitations set forth below, make any payment or perform any other act on the part of Tenant to be made and performed as in this Lease provided, in such manner and to such extent as Landlord may reasonably deem desirable, and in exercising any such rights, Landlord may pay necessary and incidental costs and expenses, employ counsel, and incur and pay reasonable attorneys’ fees. The making of any such payment or the performing of any other act by Landlord pursuant to this Article shall not waive, or release Tenant from, any obligations of Tenant in this Lease contained. All sums so paid by Landlord and all reasonably necessary and incidental costs and expenses in connection with the performance of any such act by Landlord shall, except as otherwise in this Lease expressly provided, be payable to Landlord on demand, and Tenant covenants to pay any such sum or sums promptly, and Landlord shall have (in addition to any other right or remedy of Landlord) the same rights and remedies in the event of the non-payment thereof by Tenant as in the case of default by Tenant in the payment of the Base Rent. Whenever practicable, Landlord, before proceeding as provided in this Section 12.4, shall give Tenant notice in writing of the failure of Tenant which Landlord proposes to remedy, and shall allow Tenant such length of time as may be reasonable in the circumstances, consistent with any grace periods contained herein, but not exceeding 30 days from the giving of notice, to remedy the failure itself and, if Tenant shall not remedy the failure in the time so allowed, Landlord shall be deemed to have given “due notice” and may proceed as provided in this Section 12.4; provided that nothing in this Section shall prevent Landlord from acting without notice to Tenant in case of any emergency wherein there is danger to property or person or where there may exist any violation of legal requirements including but not limited to the presence of Hazardous Materials, in which event no notice shall be required.

  • Landlord’s Right to Perform Except as specifically provided otherwise in this Lease, all covenants and agreements by Tenant under this Lease shall be performed by Tenant at Tenant’s sole cost and expense and without any abatement or offset of Rent. If Tenant shall fail to pay any sum of money (other than Base Rent) or perform any other act on its part to be paid or performed hereunder and such failure shall continue for three (3) days with respect to monetary obligations (or ten (10) days with respect to non-monetary obligations, except in case of emergencies, in which such case, such shorter period of time as is reasonable under the circumstances) after Tenant’s receipt of written notice thereof from Landlord, Landlord may, without waiving or releasing Tenant from any of Tenant’s obligations, make such payment or perform such other act on behalf of Tenant. All sums so paid by Landlord and all necessary incidental costs incurred by Landlord in performing such other acts shall be payable by Tenant to Landlord within five (5) days after demand therefor as Additional Rent.

  • LANDLORD'S RIGHT TO PERFORM TENANT'S OBLIGATIONS (a) Without limiting the rights and remedies of Landlord contained in Sections 20.2 and 20.3 above, if Tenant shall be in default in the performance of any of the terms, provisions, covenants or conditions to be performed or complied with by Tenant pursuant to this Lease, then Landlord may at Landlord’s option, without any obligation to do so, and without notice to Tenant perform any such term, provision, covenant, or condition, or make any such payment and Landlord by reason of so doing shall not be liable or responsible for any loss or damage thereby sustained by Tenant or anyone holding under or through Tenant or any of Tenant’s Agents. (b) Without limiting the rights of Landlord under Sections 20.2 and 20.3 above, Landlord shall have the right at Landlord’s option, without any obligation to do so, to perform any of Tenant’s covenants or obligations under this Lease without notice to Tenant in the case of an emergency, as determined by Landlord in its sole and absolute judgment, or if Landlord determines, in its sole and absolute judgment, that such action is necessary or desirable to avoid imminent harm to the Premises or any persons. (c) If Landlord performs any of Tenant’s obligations hereunder in accordance with this Section 20.4, the full amount of the cost and expense incurred or the payment so made or the amount of the loss so sustained shall immediately be owing by Tenant to Landlord, and Tenant shall promptly pay to Landlord upon demand, as Additional Charges, the full amount thereof with interest thereon from the date of payment by Landlord at the lower of (i) ten percent (10%) per annum, or (ii) the highest rate permitted by applicable law.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!