SUSPENSION OR TERMINATION FOR OWNER'S CONVENIENCE Sample Clauses

SUSPENSION OR TERMINATION FOR OWNER'S CONVENIENCE. Owner may for its convenience terminate any part of the Services or all remaining Services at any time upon thirty (30) days' prior written notice to Contractor specifying the part of the Services to be terminated and the effective date of termination. Promptly upon receipt of such notice, Contractor shall stop performance of the terminated Services and shall promptly order and commence demobilization with regard to the terminated Services. Contractor shall continue to prosecute the part of the Services not terminated. In case of such partial termination, an equitable adjustment to one or more of the Contract Price, the Guaranteed Completion Dates, the Construction Progress Milestone Dates, the Payment and Milestone Schedule, the Project Schedule, the Performance Guarantees and, as appropriate, such other provisions of this Agreement which may be affected thereby shall be made by agreement of Owner and Contractor or otherwise pursuant to Article 12 or 21 hereof. In the event of termination by Owner under this Section 15.1 at any time prior to the Commencement Date, Owner shall pay to Contractor such amounts, if any, as are required pursuant to Section 2.2 hereof. In the event of termination by Owner under this Section 15.1 at any time on or after the Commencement Date, Owner shall pay to Contractor such amounts as are required pursuant to Section 4.4 hereof (PROVIDED that if such termination is only of part of the Services, the provisions of said Section 4.4 shall be applied only with respect to the terminated Services); PROVIDED that Contractor shall mitigate all damages or expenses to be borne by Owner under Section 4.4 hereof; and PROVIDED, FURTHER, that if Owner so requests, Contractor shall execute and deliver all documents and take all other steps, including legal assignments, as necessary to transfer to Owner (or to Owner's designee, which may be any other AES affiliate or any third party purchaser) all of Contractor's right, title and interest in and to all items procured by Contractor for the Project and all contractual rights of Contractor under all subcontracts, purchase orders, warranties, guarantees and other agreements for the Project, in each case in accordance with the provisions set forth in Section 4.4(a) and (b) hereof, as applicable.
Sample 1
AutoNDA by SimpleDocs

Related to SUSPENSION OR TERMINATION FOR OWNER'S CONVENIENCE

  • Termination for Cause and Convenience As detailed within Clause No. 3 of, Form HUD-5370-C, General Conditions for Non- Construction Contracts, Section I—(Within or without Maintenance Work).

  • Termination for Convenience TIPS may, by written notice to Vendor, terminate this Agreement for convenience, in whole or in part, at any time by giving thirty (30) days’ written notice to Vendor of such termination, and specifying the effective date thereof.

  • Suspension for Convenience The School District shall have the right, at any time during the term of this Contract, to suspend all or any part of the Services, for the convenience of the School District, for the period of time that the School District, in its sole discretion, determines to be in the best interest of the School District, upon thirty (30) days’ prior written notice to the Architectural Designer (except that in the event of a public emergency, as determined by the School District, no such period of notice shall be required.). 13.2.1 If a suspension of the Services pursuant to this Paragraph 13.2 is for greater than thirty (30) days, the Architectural Designer shall have the right to submit a claim to the School District for the payment of costs for all Services performed and Reimbursable Expenses incurred in accordance with the provisions of this Contract prior to the effective date of the suspension. 13.2.2 The Architectural Designer shall be entitled to a one-day extension of the time of performance provided in this Contract for each day that it is suspended pursuant to this Paragraph 13.2. 13.2.3 The School District shall have the right, during the period of any suspension pursuant to this Paragraph 13.2, to terminate this Contract as provided in this Section 14, in Section 6, and elsewhere in this Contract.

  • Termination for Convenience of City The City shall have the right at any time by written notice to Contractor to terminate and cancel this contract, without cause, for the convenience of the City, and Contractor shall immediately stop work. In such event City shall not be liable to Contractor except for payment for actual work performed prior to such notice in an amount proportionate to the completed contract price and for the actual costs of preparations made by Contractor for the performance of the cancelled portions of the contract, including a reasonable allowance of profit applicable to the actual work performed and such preparations. Anticipatory profits and consequential damages shall not be recoverable by Contractor.

  • Suspension or Termination of Services You agree that Firstrade Securities Inc. reserves the right in its sole discretion to suspend or terminate your access to any or all of Firstrade Securities Inc.'s Electronic Services for any reason and without prior notice to you. You agree not to hold Firstrade Securities Inc. responsible or liable for any disruptions in service due to: telephone network, computer network or other system problems beyond the control of Firstrade Securities Inc.: system maintenance or system upgrades; or any other event or circumstance beyond the control of Firstrade Securities Inc.

  • Suspension or Termination In accordance with 24 CFR 85.43, the Grantee may suspend or terminate this Agreement if the Recipient materially fails to comply with any terms of this Agreement, which include (but are not limited to), the following: 1. Failure to comply with any of the rules, regulations or provisions referred to herein, or such statutes, regulations, executive orders, and HUD guidelines, policies or directives as may become applicable at any time; 2. Failure, for any reason, of the Recipient to fulfill in a timely and proper manner its obligations under this Agreement; 3. Ineffective or improper use of funds provided under this Agreement; or 4. Submission by the Recipient to the Grantee reports that are incorrect or incomplete in any material respect. In accordance with 24 CFR 85.44, this Agreement may also be terminated for convenience by either the Grantee or the Recipient, in whole or in part, by setting forth the reasons for such termination, the effective date, and, in the case of partial termination, the portion to be terminated. However, if in the case of a partial termination, the Grantee determines that the remaining portion of the award will not accomplish the purpose for which the award was made, the Grantee may terminate the award in its entirety.

  • Termination by the Owner for Convenience § 13.2.4.1 The Owner may, at any time, terminate the Contract for the Owner’s convenience and without cause. § 13.2.4.2 Upon receipt of written notice from the Owner of such termination for the Owner’s convenience, the Design-Builder shall

  • Termination for Public Convenience Enterprise Services, for public convenience, may terminate this Contract; Provided, however, that such termination for public convenience must, in Enterprise Services’ judgment, be in the best interest of the State of Washington; and Provided further, that such termination for public convenience shall only be effective upon sixty (60) calendar days prior written notice; and Provided further, that such termination for public convenience shall not relieve any Purchaser from payment for Goods/Services already ordered as of the effective date of such notice. Except as stated in this provision, in the event of such termination for public convenience, neither Enterprise Services nor any Purchaser shall have any obligation or liability to Contractor.

  • Amendment, Suspension or Termination of the Plan By accepting this Award, Participant expressly warrants that he or she has received an Award of Restricted Stock Units under the Plan, and has received, read and understood a description of the Plan. Participant understands that the Plan is discretionary in nature and may be amended, suspended or terminated by the Company at any time.

  • Suspension or Termination of Sales Consistent with standard market settlement practices, the Company or the Agent may, upon notice to the other party hereto in writing or by telephone (confirmed immediately by verifiable email), suspend any sale of Shares, and the period set forth in an Issuance Notice shall immediately terminate; provided, however, that (A) such suspension and termination shall not affect or impair either party’s obligations with respect to any Shares placed or sold hereunder prior to the receipt of such notice; (B) if the Company suspends or terminates any sale of Shares after the Agent confirms such sale to the Company, the Company shall still be obligated to comply with Section 3(b)(v) with respect to such Shares; and (C) if the Company defaults in its obligation to deliver Shares on a Settlement Date, the Company agrees that it will hold the Agent harmless against any loss, claim, damage or expense (including, without limitation, penalties, interest and reasonable legal fees and expenses), as incurred, arising out of or in connection with such default by the Company. The parties hereto acknowledge and agree that, in performing its obligations under this Agreement, the Agent may borrow Common Shares from stock lenders in the event that the Company has not delivered Shares to settle sales as required by subsection (v) above, and may use the Shares to settle or close out such borrowings. The Company agrees that no such notice shall be effective against the Agent unless it is made to the persons identified in writing by the Agent pursuant to Section 3(b)(i).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!