Pay Overage or Shortage
Pay Overage or Shortage Sample Clauses
Related to Pay Overage or Shortage
Damage or Destruction Condemnation (a) In the event of partial damage or destruction of the Property of a type which can, under the circumstances, be expected in the reasonable judgment of Seller and Buyer to be restored or repaired at a cost of $500,000 or less, then, this Contract shall be consummated on the Closing Date at the Purchase Price, and unless such damage has been repaired by Seller prior to Closing, Seller shall assign to Buyer the casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts expended by Seller for partial restoration and with a credit to Buyer for the amount of any deductible and/or uninsured damage. (b) In the event that the Property shall have been damaged by fire or casualty, the cost of repair or restoration of which would, in the reasonable judgment of Seller and Buyer, exceed the sum of $500,000, then unless Seller has previously repaired or restored the Property to its former condition, at Buyer’s election, Seller shall either (i) pay over or assign to Buyer, on delivery of the Deed all casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts reasonably expended by Seller for partial restoration, with a credit to Buyer for the amount of any deductible and/or uninsured damage, or (ii) direct Escrow Agent to return the Deposit to Buyer in which case, except for the Surviving Obligation, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto. Notwithstanding the foregoing, if Buyer elects to proceed with the transaction under clause (i) of this paragraph (b), in no event shall Seller be obligated to incur any out of pocket cost above $500,000 (whether attributable to a casualty being uninsured, underinsured or to any deductible). (c) If all or part of the Property is taken by condemnation, eminent domain or by agreement in lieu thereof, or any proceeding to acquire, take or condemn all or part of the Property is threatened or commenced, Buyer may either terminate this Contract (in which event Buyer shall be entitled to a return of the Deposit and accrued interest thereon, if any, and, except for the Surviving Obligations, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto) or close title to the Property in accordance with the terms hereof, without reduction in the Purchase Price, together with an assignment of Seller's rights to any award paid or payable by or on behalf of the condemning authority. If Seller has received payments from the condemning authority and if Buyer elects to close title to the Property, Seller shall credit the amount of said payment against the Purchase Price at the Closing.
Parental Allowance (a) An employee who has been granted parental leave without pay, shall be paid a parental allowance in accordance with the terms of the Supplemental Unemployment Benefit (SUB) Plan described in paragraphs (c) to (i), providing he or she: (i) has completed six (6) months of continuous employment before the commencement of parental leave without pay, (ii) provides the Employer with proof that he or she has applied for and is in receipt of parental, paternity or adoption benefits under the Employment Insurance or Québec Parental Insurance Plan in respect of insurable employment with the Employer, and (iii) has signed an agreement with the Employer stating that: (A) the employee will return to work on the expiry date of his/her parental leave without pay, unless the return to work date is modified by the approval of another form of leave; (B) Following his or her return to work, as described in section (A), the employee will work for a period equal to the period the employee was in receipt of the parental allowance, in addition to the period of time referred to in section 17.02(a)(iii)(B), if applicable; (C) should he or she fail to return to work in accordance with section (A), for reasons other than death, lay-off, early termination due to lack of work or discontinuance of a function of a specified period of employment that would have been sufficient to meet the obligations specified in section (B), or having become disabled as defined in the Public Service Superannuation Act, he or she will be indebted to the Employer for the full amount of the parental allowance he or she has received. Should he or she return to work but fail to work the total period specified in section (B), for reasons other than death, lay-off, early termination due to lack of work or discontinuance of a function of a specified period of employment that would have been sufficient to meet the obligations specified in section (B), or having become disabled as defined in the Public Service Superannuation Act, he or she will be indebted to the Employer for an amount determined as follows: (allowance received) X (remaining period to be worked following his/her return to work) [total period to be worked as specified in (B)] however, an employee whose specified period of employment expired and who is rehired by OSFI within a period of thirty (30) days or less is not indebted for the amount if his or her new period of employment is sufficient to meet the obligations specified in section (B). (b) For the purpose of sections (a)(iii)(B), and (C), periods of leave with pay shall count as time worked. Periods of leave without pay during the employee's return to work will not be counted as time worked but shall interrupt the period referred to in section (a)(iii)(B), without activating the recovery provisions described in section (a)(iii)(C). (c) Parental Allowance payments made in accordance with the SUB Plan will consist of the following: (i) where an employee is subject to a waiting period of two (2) weeks before receiving Employment Insurance parental benefits, ninety-three per cent (93%) of his/her weekly rate of pay for each week of the waiting period, less any other monies earned during this period; (ii) for each week the employee receives parental, adoption or paternity benefit under the Employment Insurance or the Québec Parental Insurance Plan, he/she is eligible to receive the difference between ninety-three per cent (93%) of his or her weekly rate and the parental, adoption or paternity benefit, less any other monies earned during this period which may result in a decrease in his/her parental, adoption or paternity benefit to which he/she would have been eligible if no extra monies had been earned during this period. (iii) where an employee becomes entitled to an extension of parental benefits pursuant to the Employment Insurance Act, the parental allowance payable under the SUB Plan described in subparagraph (ii) will be extended by the number of weeks of extended benefits which the employee receives under the EI Act. (d) At the employee's request, the payment referred to in subparagraph 17.05(c)(i) will be estimated and advanced to the employee. Adjustments will be made once the employee provides proof of receipt of EI or QPIP parental benefits. (e) The parental allowance to which an employee is entitled is limited to that provided in paragraph (c) and an employee will not be reimbursed for any amount that he or she is required to repay pursuant to the Employment Insurance Act or the Parental Insurance Act in Quebec. (f) The weekly rate of pay referred to in paragraph (c) shall be: (i) for a full-time employee, the employee's weekly rate of pay on the day immediately preceding the commencement of maternity or parental leave without pay; (ii) for an employee who has been employed on a part-time or on a combined full-time and part-time basis during the six (6) month period preceding the commencement of maternity or parental leave without pay, the rate obtained by multiplying the weekly rate of pay in subparagraph (i) by the fraction obtained by dividing the employee's straight time earnings by the straight time earnings the employee would have earned working full-time during such period. (g) The weekly rate of pay referred to in paragraph (f) shall be the rate to which the employee is entitled for the substantive level to which she or he is appointed. (h) Notwithstanding paragraph (g), and subject to subparagraph (f)(ii), if on the day immediately preceding the commencement of parental leave without pay an employee is performing an acting assignment for at least four (4) months, the weekly rate shall be the rate the employee was being paid on that day. (i) Where an employee becomes eligible for a pay increment or pay revision while in receipt of parental allowance, the allowance shall be adjusted accordingly. (j) Parental allowance payments made under the SUB Plan will neither reduce nor increase an employee's deferred remuneration or severance pay. (k) The maximum combined maternity and parental allowances payable under this collective agreement shall not exceed fifty-two (52) weeks.
Damage or Destruction If any Property shall be damaged or destroyed, in whole or in part, by fire or other property hazard or casualty, Borrower shall give prompt notice thereof to Lender and one hundred (100%) percent of the net amount of all insurance proceeds received by Lender or Borrower as a result of such damage or destruction after deduction of reasonable costs and the expenses, if any, in collecting the same, shall be applied in reduction of the outstanding Principal Balance under the Note pertaining to the Damaged Property. Notwithstanding anything to the contrary set forth above, if a particular Property (a "DAMAGED PROPERTY") shall be damaged or destroyed, in whole or in part, by fire or other casualty, Lender shall, in accordance with the provisions of this Section hereinafter set forth, make the net amount of all insurance proceeds received by Lender pursuant to the provisions of this Agreement as a result of such damage or destruction after deduction of its reasonable costs and expenses, if any, in collecting the same (hereinafter referred to as the "NET PROCEEDS") available for the repair and restoration of the Damaged Property, provided that (i) no default shall have occurred and shall be continuing under the Loan Documents, (ii) Borrower shall commence the repair and restoration of the Damaged Property, as nearly as possible to the condition the Damaged Property was in immediately prior to such fire or other casualty, with such alterations as may be approved by Lender, as soon as reasonably practicable, and shall diligently pursue the same to satisfactory completion, (iii) Lender shall be satisfied that any operating deficits which will be incurred with respect to the Damaged Property as a result of the occurrence of any such fire or other casualty will be covered out of the Net Proceeds or by Borrower out-of-pocket or with the proceeds, if any, of business interruption or rental interruption insurance, (iv) Lender shall be satisfied that, within a reasonable period of time, not to exceed one hundred eighty (180) days following the completion of such repair and restoration of the Damaged Property, the gross cash flow and the net cash flow of the Damaged Property will be restored to a level sufficient to cover all carrying costs and operating expenses of the Damaged Property, (v) Lender shall be satisfied that the repair and restoration of the Damaged Property will be completed on or before the earlier to occur of (w) ninety (90) days prior to the Maturity Date, or (x) the date on which the business interruption insurance covered by such Borrower shall expire, (vi) Lender shall be satisfied that all of the terms, covenants and provisions of this Agreement and the other Loan Documents will continue to be complied with during and subsequent to the completion of such repair and restoration and (vii) Borrower and ARC IV shall execute and deliver to Lender a completion guaranty in form and substance satisfactory to Lender pursuant to the provisions of which Borrower and ARC IV shall jointly and severally guaranty to Lender the lien-free completion of the repair and restoration of the Damaged Property in accordance with the provisions of this paragraph. The Net Proceeds shall be held by Lender in an interest-bearing account, and until disbursed in accordance with the provisions of this paragraph, shall constitute additional security for the payment of the Debt. The Net Proceeds together with interest earned thereon, shall be disbursed by Lender to, or as directed by, Borrower from time to time during the course of the repair and restoration of the Damaged Property, upon receipt of evidence satisfactory to Lender (which evidence shall in each instance and to the full extent required by Lender include receipted bills, invoices, lien waivers and a continuation and date down of title to the Damaged Property in form satisfactory to Lender and issued by the title company insuring the lien of the Mortgage encumbering such Property or another title company satisfactory to Lender) that (i) all materials installed and work and labor performed (except to the extent that they are to be paid for out of the requested disbursement) in connection with the repair and restoration of the Damaged Property have been paid for in full, and (ii) there exist no notice of pendency, stop order, notice of intention to file mechanic's or materialman's lien, mechanic's or materialman's lien or other lien or encumbrance of any nature whatsoever on the Damaged Property arising out of the repair and restoration of the Damaged Property which have not either been fully bonded to the satisfaction of Lender and discharged of record or in the alternative fully insured over to the satisfaction of Lender by the title company insuring the lien of the Mortgage encumbering the Damaged Property. The repair and restoration of the Damaged Property shall be done and completed by Borrower in an expeditious and diligent fashion and in compliance with all applicable governmental laws, rules and regulations (including, without limitation, all applicable Environmental Requirements), and all plans and specifications required in connection with the repair and restoration of the Damaged Property shall be subject to review and acceptance in all respects by Lender and by the Consultant. If Lender fails to respond within ten (10) Business Days following a request and submissions of plans and specifications for approval, such plans and specification shall be deemed approved by Lender. Upon the occurrence of an Event of Default, Lender shall have the use of such plan and specifications and all permits, licenses and approvals required or obtained in connection with the repair and restoration of the Damaged Property. The identity of the contractors, subcontractors and materialmen engaged in the repair and restoration of the Damaged Property, as well as the contracts under which they have been engaged, shall be identified to Lender and Consultant, if any. All costs and expenses incurred by Lender in connection with making the Net Proceeds available for the repair and restoration of the Damaged Property including, without limitation, reasonable counsel fees and reasonable fees of the Consultant, shall be paid by Borrower. In no event shall Lender be obligated to make disbursements of the Net Proceeds in excess of an amount equal to the costs actually incurred from time to time for work in place as part of the repair and restoration of the Damaged Property,
Parental Leave Allowance (a) An employee who qualifies for parental leave pursuant to Article 35.03, shall be paid a parental leave allowance in accordance with the Supplemental Employment Benefit (SEB) Plan. In order to receive this allowance, the employee must provide to the Employer proof of application and eligibility to receive employment insurance benefits pursuant to the Employment Insurance Act. An employee disentitled or disqualified from receiving employment insurance benefits is not eligible for parental leave allowance. (b) Pursuant to the Supplemental Employment Benefit (SEB) Plan and subject to leave apportionment pursuant to Article 35.03(b), the parental leave allowance will consist of a maximum of ten (10) weekly payments, equivalent to the difference between the employment insurance gross benefits and any other earnings received by the employee, and seventy-five (75) percent of the employee’s basic pay.
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”): (i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord; (ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed; (iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord; (iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed; (v) Construction of any Change Requests; (vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible); (vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein; (viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord; (ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or (x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Total Taking If the entire Building or Premises are taken by right of eminent domain or conveyed in lieu thereof (a “Taking”), this Lease shall terminate as of the date of the Taking.
Maximum Occupancy No more than two (2) guests per one (1) resident (who is present) are permitted in a student room/suite/apartment at any given time unless otherwise approved by the University (Residential Life).
Extended Leave of Absence Professional employees who have attained renewable contract status may request extended leaves of absence for one (1) year without pay under any one of the circumstances listed in this section. All requests for such extended leave of absence will be applied for and granted or rejected in writing. Such application will be reviewed by the principal and superintendent. If the latter approves, he/she will recommend that the leave be granted by the Board. An employee returning from an extended leave will be assigned to the same position as that which he/she held before assuming the leave, providing that position still exists. By mutual agreement between the employer and the employees, he/she may be given a different assignment. Extended leaves of absence may be requested under, but not limited to, the following: 1. To serve in a county, state, or national public office. 2. To care for a sick member of the immediate family. 3. To serve as an exchange teacher or an overseas teacher. 4. To accept a sabbatical leave.
Shift Differential Pay SECTION 1: In addition to compensation provided by the wage schedule, employees working between the hours of 3:00 P.M. and 7:00 A.M. shall be paid a shift differential premium of $.45 (forty-five cents) per hour in addition to the regular pay for those hours. SECTION 2: Employees must work a minimum of 3 (three) hours in order for shift differential to apply.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
