Indemnity Limitation for TIPS Sales Texas and other jurisdictions restrict the ability of governmental entities to indemnify others. Vendor agrees that if any "Indemnity" provision which requires the TIPS Member to indemnify Vendor is included in any TIPS sales agreement/contract between Vendor and a TIPS Member, that clause must either be stricken or qualified by including that such indemnity is only permitted, "to the extent permitted by the laws and constitution of [TIPS Member's State]” unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing an "Indemnity" clause that conflicts with these terms is rendered void and unenforceable.
Payment of Wages With the agreement of the majority of the employees, the company may elect to pay wages weekly by electronic funds transfer (EFT) to up to two accounts of the employee’s choice.
PAYMENT OF WAGES AND ALLOWANCES 26:01 Pay Days
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Prices and Terms of Payment (a) In consideration of the sale of Products and/or the performance of Services by Signify, Customer shall pay all prices and fees (“Prices”) in accordance with the Agreement and this section 2. Prices are in euro and unless agreed otherwise based on Ex Works – Signify facility (INCOTERMS latest version). Unless stipulated otherwise by the applicable INCOTERMS, Prices do not include any taxes, duties or other governmental fees, now or hereafter enacted, including value-added or similar taxes levied by any government, and Signify may add these to the Price or invoice separately, and Customer will reimburse Signify promptly on first request. (b) Subject to notice to Customer, Signify reserves the right to adjust Prices for Products and/or Services not yet delivered or performed to reflect variations in individual costs of more than five percent (5%) including any foreign exchange rate fluctuations, raw materials and other costs of manufacturing and distribution, and labor costs, that take effect between the date of the Agreement and delivery of Products and/or performance of Services. In addition, if an Agreement has a term longer than twelve (12) months, Signify may adjust Prices as of each 1st April (i) for the change in the most recently published producer price index (PPI) compared to twelve (12) months earlier; and (ii) to reflect variations in the foreign exchange rate between the foreign currency and the Euro currency of more than 5% since the date of an Offer. (c) Any cancellation, delay or other change by Customer of a purchase order previously accepted by Signify will require the prior approval of Signify and the approval will be without prejudice to any rights or remedies Signify may have under the Agreement or at law. If, on request of Customer, Signify agrees to any such change in purchase order or a change in an Agreement, including an (partial) cancellation, delay or suspension, the addition, omission, alteration, substitution or modification of the design, quality, standard, quantity, manufacturing site or performance (including sequence, quantities or timing) of Products and/or Services (each, a “Variation”), or a Variation is required due to (i) changes in applicable laws, regulations or industry standards, (ii) emergency situations, (iii) incorrect or incomplete information provided by Customer, or (iv) non-compliance by Customer of any of its obligations under an Agreement, Customer shall reimburse Signify for all costs and expenses incurred in respect of such Variation promptly on first request. (d) Signify may invoice Customer upon shipment of Products, or when Services have been performed. Signify may require (i) Customer to pay on fixed payment days; (ii) an advance payment of (part of) the Price; and/or (iii) invoice per separate specified phase, time period or milestone of performance. Customer shall make net payment within thirty (30) days of date of invoice to the designated bank account of Signify. Customer shall pay all amounts due to Signify in full without any set-off, counterclaim, deduction or (tax) withholding. (e) In the event Customer fails to make any payment due under an Agreement on the due date, then, whether or not Signify has made a formal demand for payment and in addition to any other rights and remedies available to Signify, to the extent permitted by applicable law: (i) all amounts due from Customer will be considered payable and non-disputed, admitted debt; (ii) Customer shall pay Signify interest on all due amounts from the due date until Signify has received full payment thereof, at the rate of eighteen percent (18%) per annum or the applicable statutory rate, whichever is higher, and shall pay Signify all costs of payment collection, including attorneys’ fees; and (iii) Signify may cancel any credit issued to Customer and require, to its satisfaction, that Customer provides (additional) security, pre-payments or deposits, and may implement additional conditional payment terms or accelerate payments schedules for any outstanding performance. (f) Signify may set off against and deduct from any amount that Signify (or any of its affiliates) owes to Customer under any agreement any amount that Customer owes to Signify or against any advance payments or deposits made by Customer. In the event that Signify sets off amounts in different currency it will use a commonly used currency conversion rate.
Certain Rules Relating to the Payment of Additional Amounts (a) If any Affected Person requests compensation under Section 5.01, or if the Borrower is required to pay any additional amount to any Affected Person or to any Governmental Authority for the account of any Affected Person pursuant to Section 5.03, then such Affected Person shall (at the request of the Borrower) use commercially reasonable efforts to designate a different lending office for funding or booking the related Loans hereunder or to assign and delegate (or cause to be assigned and delegated) such Affected Person’s rights and obligations hereunder to another office, branch or Affiliate of such Affected Person if, in the judgment of such Affected Person, such designation or assignment (i) would eliminate or reduce amounts payable pursuant to Section 5.01 or 5.03, as the case may be, in the future and (ii) would not subject such Affected Person to any unreimbursed cost or expense and would not otherwise be disadvantageous to such Affected Person. The Borrower hereby agrees to pay all reasonable out of pocket costs and expenses incurred by any Affected Person in connection with any such designation or assignment and delegation. (b) If (i) any Affected Person requests compensation under Section 5.01, (ii) the Borrower is required to pay any additional amount to any Affected Person or any Governmental Authority for the account of any Affected Person pursuant to Section 5.03, (iii) any Affected Person has become a Defaulting Lender or (iv) any Affected Person has failed to consent to a proposed amendment, waiver, discharge or termination that requires the consent of all Lenders and with respect to which the other Lenders shall have or would have granted their consent, then the Borrower may, at its sole expense and effort, upon notice to the Administrative Agent, require the Administrative Agent to cause the related Affected Person to assign and delegate, without recourse (in accordance with and subject to all applicable transfer restrictions), all its interests, rights and obligations under this Agreement and the other Transaction Documents to another appropriate Person (which, in the case of a Lender, shall be an Eligible Assignee) that shall acquire such interest or assume such commitment; provided that (a) the Borrower shall have received the prior written consent of the Administrative Agent and the other Lenders, which consent shall not unreasonably be withheld, (b) such Affected Person, if a Lender, shall have received payment of an amount equal to its outstanding Capital and, if applicable, accrued Interest and Fees thereon and all other amounts then owing to it hereunder from the assignee or the Borrower, (c) in the case of any such assignment and delegation resulting from a claim for compensation under Section 5.01 or payments required to be made pursuant to Section 5.03, such assignment is expected to result in a reduction in such compensation or payments for future periods and (d) in the case of any such assignment and delegation resulting from the failure of an Affected Person to provide a consent, the assignee shall have given such consent and, as a result of such assignment and delegation and any contemporaneous assignments and delegations and consents, the applicable amendment, waiver, discharge or termination can be effected. An Affected Person shall not be required to make any such assignment and delegation if, prior thereto, as a result of a waiver or consent by such Affected Person or otherwise, the circumstances entitling the Borrower to require such assignment and delegation have ceased to apply.
Payment of GST Payment of the additional amount will be made at the same time as payment for the supply is required to be made under this Contract.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Prompt Payment to Subcontractors (a) Within 7 days of receipt by the Contractor of each payment from the City under this contract, the Contractor shall pay all Subcontractors (which term includes subconsultants and suppliers) based on work completed or service provided under the subcontract. Should any payment to the Subcontractor be delayed by more than 7 days after receipt of payment by the Contractor from the City under this contract, the Contractor shall pay the Subcontractor interest, beginning on the 8th day, at the rate of 1% per month or fraction thereof on such unpaid balance as may be due. By appropriate litigation, Subcontractors shall have the right to enforce this subsection (a) directly against the Contractor, but not against the City of Durham. (b) If the individual assigned to administer this contract for the City (in this section, titled “Prompt Payment to Subcontractors,” he or she will be referred to as the “Project Manager”) determines that it is appropriate to enforce subsection (a) in this manner, the City may withhold from progress or final payments to the Contractor the sums estimated by the Project Manager to be (i) the amount of interest due to the Subcontractor under subsection (a), and/or (ii) the amounts past-due under subsection (a) to the Subcontractor but not exceeding 5% of the payment(s) due from the City to the Contractor. This subsection (b) does not limit any other rights to withhold payments that the City may have. (c) Nothing in this section (titled “Prompt Payment to Subcontractors”) shall prevent the Contractor at the time of invoicing, application, and certification to the City from withholding invoicing, application, and certification to the City for payment to the Subcontractor for unsatisfactory job progress; defective goods, services, or construction not remedied; disputed work; third-party claims filed or reasonable evidence that such a claim will be filed; failure of the subcontractor to make timely payments for labor, equipment, and materials; damage to the Contractor or another subcontractor; reasonable evidence that the subcontract cannot be completed for the unpaid balance of the subcontract sum; or a reasonable amount for retainage not to exceed 10%. (d) The Project Manager may require, as a prerequisite to making progress or final payments, that the Contractor provide statements from any Subcontractors designated by the Project Manager regarding the status of their accounts with the Contractor. The statements shall be in such format as the Project Manager reasonably requires, including notarization if so specified.
