Over-Allowance Amount The amount that is equal to the difference between (i) the amount of the Cost Proposal and (ii) the amount of the TI Allowance (less any portion thereof already disbursed by Landlord, or in the process of being disbursed by Landlord, on or before the Cost Proposal Delivery Date that is not otherwise included within the Cost Proposal) shall be referred to herein as the "Over-Allowance Amount." Tenant shall pay to Landlord (a) one-half (1/2) of such Over-Allowance Amount no later than ten (10) days after the Cost Proposal Delivery Date and (b) the other one-half (1/2) of such Over-Allowance Amount within ten (10) days after Landlord gives Tenant written notice that the construction of the Tenant Improvements is completed. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any then remaining portion of the TI Allowance, and such disbursement shall be pursuant to the same procedure as the TI Allowance. In the event that after the Cost Proposal Delivery Date, any revisions, changes, or substitutions shall be made to the Construction Drawings or the Tenant Improvements, any additional costs which arise in connection with such revisions, changes or substitutions shall be paid by Tenant to Landlord as an addition to the Over-Allowance Amount as follows: (1) one-half (1/2) of such additional amount within five (5) days after Landlord's invoice therefor and (2) the remaining one-half (1/2) of such additional amount within five (5) days following Tenant's receipt of Landlord's written notice that the work to which the change order applies is complete. In addition, upon Landlord's determination of the actual costs incurred by or on behalf of Landlord for the TI Allowance Items, Tenant shall pay Landlord the amount, if any, by which such actual costs exceed the sum of the TI Allowance and the Over-Allowance Amount within fifteen (15) days after being billed therefor, or Landlord may, at its election, require that Tenant deposit with Landlord the full amount of such excess prior to Landlord's delivery of the Expansion Space to Tenant. No portion of the TI Allowance shall be used to pay Tenant or Tenant's agents, contractors or employees, unless and until Landlord's contractors and any other persons and entities employed by or under contract with Landlord have been paid in full.
Minimum Cash Balance Licensee shall fund the Facility Checking Account --------------------- with an initial amount equal to $25,000.00 and thereafter Licensee shall provide the working capital required by Section I(H) of this Agreement
Minimum Adjusted EBITDA As of any date of determination from and after April 1, 2008, if Borrowers do not have Net Debt in an amount less than $4,000,000 at all times during the most recently completed fiscal quarter, then Borrowers shall not fail to achieve Adjusted EBITDA, measured on a quarter-end basis, of at least the required amount set forth in the following table for the applicable period set forth opposite thereto (and the failure to do so shall be deemed an Event of Default): Applicable Amount Applicable Period $(1,234,000) For the 3 month period ending March 31, 2008 $(1,246,000) For the 6 month period ending June 30, 2008 $(200,000) For the 9 month period ending September 30, 2008 $(839,000) For the 12 month period ending December 31, 2008 $(750,000) For the 12 month period ending March 31, 2009 17 Applicable Amount Applicable Period $(500,000) For the 12 month period ending June 30, 2009 $(150,000) For the 12 month period ending September 30, 2009 $150,000 For the 12 month period ending December 31, 2009 $350,000 For the 12 month period ending March 31, 2010 $550,000 For the 12 month period ending June 30, 2010 $750,000 For the 12 month period ending September 30, 2010 $950,000 For the 12 month period ending December 31, 2010 and for each 12 month period ending as of the last day of each fiscal quarter thereafter
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Make-Whole Amount The term “
Payment Period Whenever a payment under this Agreement specifies a payment period with reference to a number of days (e.g., “payment shall be made within forty (40) days following the date of termination), the actual date of payment within the specified period shall be within the sole discretion of the Company.
Minimum Consolidated Adjusted EBITDA The Borrower will maintain, as of the last day of each Fiscal Quarter, commencing with the Fiscal Quarter ending June 30, 2003, a minimum Consolidated Adjusted EBITDA of no less than (i) $0 for the Fiscal Quarter ending June 30, 2003, (ii) $1,000,000 for the Fiscal Quarter ending September 30, 2003 and (iii) $2,500,000 for each Fiscal Quarter thereafter.
Maximum Advance Amount The amount of an Advance requested by the Company shall not exceed the Maximum Advance Amount. In addition, in no event shall the number of shares issuable to the Investor pursuant to an Advance cause the aggregate number of shares of Common Stock beneficially owned by the Investor and its affiliates to exceed nine and 9/10 percent (9.9%) of the then outstanding Common Stock of the Company. For the purposes of this section beneficial ownership shall be calculated in accordance with Section 13(d) of the Exchange Act.
Measurement Period (b) In this Agreement, unless the contrary intention appears, a reference to: