Listing Period Extension The Commission shall be due if the Property is sold, conveyed, exchanged, optioned, or otherwise transferred within _ _ days (“Extension Period”) after the expiration of the Listing Period to anyone with whom the Broker or Agency has negotiated unless the Property is listed, in good faith, with another real estate agency. The term “negotiation” shall include providing information about the Property, showing the Property, or presenting an offer on the Property. All rights under this Section shall terminate upon the expiration of the Extension Period.
Loop Provisioning Involving IDLC 2.16.1 Where TWTC has requested an Unbundled Loop and AT&T uses IDLC systems to provide the local service to the customer and AT&T has a suitable alternate facility available, AT&T will make such alternative facilities available to TWTC. If a suitable alternative facility is not available, then to the extent it is technically feasible, AT&T will implement one of the following alternative arrangements for TWTC (e.g., hairpinning):
Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
ROAD WORK PHASE APPROVAL Purchaser shall obtain written approval from the Contract Administrator upon completion of each of the following phases of road work: Drainage installation Subgrade compaction Rock compaction SUBSECTION RESTRICTIONS
Requesting Price Increase/Required Documentation Contractor must submit a written notification at least thirty (30) calendar days prior to the requested effective date of the change, setting the amount of the increase, along with an itemized list of any increased prices, showing the Contractor’s current price, revised price, the actual dollar difference and the percentage of the price increase by line item. Price change requests must include H-GAC Forms D Offered Item Pricing and E Options Pricing, or the documentation used to submit pricing in the original Response and be supported with substantive documentation (e.g. manufacturer's price increase notices, copies of invoices from suppliers, etc.) clearly showing that Contractor's actual costs have increased per the applicable line item bid. The Producer Price Index (PPI) may be used as partial justification, subject to approval by H-GAC, but no price increase based solely on an increase in the PPI will be allowed. This documentation should be submitted in Excel format to facilitate analysis and updating of the website. The letter and documentation must be sent to the Bids and Specifications manager, Xxxxxxx Xxxxxx, at Xxxxxxx.Xxxxxx@x-xxx.xxx Review/Approval of Requests If H-GAC approves the price increase, Contractor will be notified in writing; no price increase will be effective until Contractor receives this notice. If H-GAC does not approve Contractor’s price increase, Contractor may terminate its performance upon sixty (60) days advance written notice to H-GAC, however Contractor must fulfill any outstanding Purchase Orders. Termination of performance is Contractor’s only remedy if H-GAC does not approve the price increase. H-GAC reserves the right to accept or reject any price change request.
Termination for Market Change (a) In the event of delay or interruption under B8.33, exceeding 90 days, and Contract has not been modified to include replacement timber, this contract may be terminated upon election and written notice by Purchaser, if (i) a rate redetermination for market change under B3.33 shows that the appraised weighted average Indicated Advertised Rate of all Included Timber remaining immediately prior to the delay or interruption has been reduced through a market change by an amount equal to or more than the the weighted average Current Contract Rate, or (ii) the appraised value of the remaining timber is insufficient to cover the adjusted base rates as determined under B3.33.
Motion for Preliminary Approval The Parties agree to jointly prepare and file a motion for preliminary approval (“Motion for Preliminary Approval”) that complies with the Court’s current checklist for Preliminary Approvals.
Program Overview A. Goals of the Choice Neighborhoods Program. The Choice Neighborhoods Program employs a comprehensive approach to neighborhood transformation. The program transforms neighborhoods of concentrated poverty into mixed-income neighborhoods of long-term viability by revitalizing severely distressed public and/or assisted housing; improving access to economic opportunities; and investing and leveraging investments in well-functioning services, effective schools and education programs, public assets, public transportation, and improved access to jobs. Choice Neighborhoods ensures that current residents benefit from this transformation by preserving affordable housing in the neighborhood or providing the choice to move to affordable housing in another neighborhood of opportunity. The purpose of this grant is to implement a Transformation Plan that has been developed through a local planning process and furthers the goals of the Choice Neighborhoods Program. The core goals of Choice Neighborhoods are:
Rate Redetermination for Environmental Modification In the event of a contract modification under B8.33 or partial termination under B8.34, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber remaining immediately prior to the revision and the appraised unit value of Included Timber to be cut under the modification. The appraisal shall consider the estimated cost of any construction work listed in the Schedule of Items that was performed and abandoned. Tentative Rates and Flat Rates in effect at the time of the revision will be adjusted by said differences to become Current Contract Rates. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates, or differences for rates subject to B3.2, and Required Deposits shall be considered established under B3.1 for timber Scaled subsequent to the contract revision.
Modified Work Week Where Employees in a unit have indicated a desire to work a modified work week, the Employer may authorize experiments with modified work week schedule, providing operational requirements permit and the provision of services are not adversely affected. The averaging period for a modified work week shall not exceed three (3) calendar weeks, and the work day shall not exceed ten (10) hours .
