Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.
Tenant’s Work After the Commencement Date, Tenant at its sole cost and expense intends to construct leasehold improvements in the Demised Premises (“Tenant’s Work”) as detailed in the plans and specifications to be prepared by Tenant’s architect (“TI Architect”). Tenant shall be allowed to select a general contractor to perform the Tenant’s Work, provided said general contractor shall be properly licensed, bonded and of a reputation reasonably acceptable to Landlord. An affiliate of Landlord, Minkoff Development Corporation (“MDC”), shall act as Landlord’s construction manager to review plans and oversee construction of the Tenant’s Work by the general contractor. MDC shall receive a fee equal to one percent (1%) of the cost of the Tenant’s Work, which fee shall not exceed $50,000. Tenant shall have the right to submit plans for the Tenant’s Work in stages for portions of the Demised Premises. Tenant shall cause the TI Architect to prepare and deliver to Landlord for Landlord’s or MDC’s review preliminary plans (architectural, mechanical, electrical, plumbing and structural, if necessary) and specifications for the proposed leasehold improvements (the “Preliminary Plans”). Landlord shall have five (5) business days after its receipt thereof (or such additional time as may reasonably be necessary) to review the Preliminary Plans, request any changes it deems reasonably appropriate, and indicate on the Preliminary Plans which portions of the leasehold improvements are to be removed by Tenant prior to the expiration or termination of the Lease. The TI Architect shall modify the Preliminary Plans to accommodate Landlord’s changes, and resubmit the revised plans (the “Revised Preliminary Plans”) to Landlord for approval. If Tenant or the TI Architect elect not to make said changes to the Preliminary Plans, then Landlord shall have the right to require Tenant to perform corresponding restoration work to effect said changes prior to the expiration or termination of the Lease. Upon receipt of Landlord’s approval of the Revised Preliminary Plans, the TI Architect shall prepare a complete set of construction drawings and specifications for the construction of the proposed leasehold improvements (the “Working Drawings”). The Working Drawings shall be in sufficient detail for (i) Tenant’s general contractor to obtain bids from all trades for and to perform the work described on the Working Drawings; (ii) Tenant’s general contractor to secure building permits from the requisite governmental authorities having jurisdiction over same; and (iii) Landlord or MDC to indicate the portion of Tenant’s Work, if any, which Tenant is to remove by expiration or termination of the Lease. The Working Drawings shall conform to and be consistent with the Revised Preliminary Plans and comply with all applicable Laws and Insurance Requirements, as those terms are defined in the Lease. The Working Drawings shall be submitted to MDC for review and approval, which approval (or a request for changes to be made) shall be given within ten (10) days after receipt thereof. Within five (5) business days after MDC’s approval of the Working Drawings, as modified by any revisions requested by MDC, Landlord and Tenant shall initial same to confirm their mutual approval thereof (the “Approved Working Drawings ”). The Approved Working Drawings will indicate which portions of the Tenant’s Work, if any, will have to be removed by Tenant prior to the expiration or termination of the Lease, and Tenant will timely comply with such requirement and repair any damage to the Land or the Building caused thereby at its own expense. Tenant will have no obligation to remove any other portion of the Tenant’s Work.
Cost of Tenant Improvements Unless specified otherwise herein, Landlord shall bear and pay the cost of the Tenant Improvements (which cost shall include, without limitation, the costs of construction, the cost of permits and permit expediting, and all architectural and engineering services obtained by Landlord in connection with the Tenant Improvements, the Contractor's fees, Landlord's fee for construction administration in an amount equal to the amount charged by any construction manager retained by Landlord (the "Construction Manager") up to a maximum of $6,121,750 (the "Tenant Improvement Allowance"). The Tenant Improvement Allowance shall be utilized only for building improvements to the Building (and Tenant's architect fees), and not for signage, furniture costs, any third party consulting or contracting fees, any telecom/cabling costs, or any other purpose. Tenant shall bear and pay the cost of the Tenant Improvements (including but not limited to all of the foregoing fees and costs) in excess of the Tenant Improvement Allowance, if any. The cost of the Tenant Improvements shall exclude the cost of furniture, fixtures and inventory and other items of Tenant's Work (as defined below). Notwithstanding the foregoing, the Tenant Improvement Allowance shall not be used for (and Tenant shall have no responsibility for) the following costs except to the extent any of the foregoing are caused by Tenant, are due to Tenant Delays or result from the failure of Tenant to comply with the terms of the Lease or this Work Letter: (1) Property Maintenance Costs prior to the Delivery Date; (2) charges for overtime, except to the extent approved by Tenant; (3) costs to correct construction defects; (4) costs incurred to enforce contracts or cure contractor or subcontractor defaults (including legal fees); or (5) principal or interest on construction loan obtained by Landlord for construction of the Tenant Improvements.
Plans and Specifications Tenant shall be solely responsible for the preparation of the final architectural, electrical and mechanical construction drawings, plans and specifications (called “plans”) necessary for Tenant to construct the Premises for Tenant’s occupancy, which plans shall be subject to approval by Landlord’s architect and engineers and shall comply with their reasonable requirements to avoid aesthetic or other conflicts with the design and function of the balance of the Building. Landlord’s approval is solely given for the benefit of Landlord, and neither Tenant nor any third party shall have the right to rely upon Landlord’s approval of Tenant’s plans for any purpose whatsoever other than that Landlord does not object thereto under this Lease. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan submission by Tenant within 8 business days after Landlord’s receipt thereof. If Landlord fails to respond to any such submission within such 8 business day period, which failure continues for more than 2 business days after Tenant gives Landlord a written notice (the “Deemed Approved Notice”) advising Landlord that such plan submission shall be deemed approved within 2 business days of Landlord’s receipt of the Deemed Approved Notice, then such plan submission shall be deemed approved hereunder. The Deemed Approved Notice shall, in order to be effective, contain on the first page thereof, in a font at least twice as large as the font of any other text contained in such notice, a legend substantially as follows: “FAILURE TO RESPOND TO THIS NOTICE WITHIN TWO (2) BUSINESS DAYS AFTER RECEIPT HEREOF SHALL CONSTITUTE LANDLORD’S APPROVAL OF SUBMITTED PLANS.” In the event Landlord’s architect’s or engineers’ approval of Tenant’s plans is withheld or conditioned, Landlord shall send prompt written notification thereof to Tenant and include a reasonably detailed statement identifying the reasons for such refusal or condition, and Tenant shall promptly have the plans revised by its architect to incorporate all reasonable objections and conditions presented by Landlord and shall resubmit such plans to Landlord. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan re-submission by Tenant within 8 business days after Landlord’s receipt thereof. Such process shall be followed until the plans shall have been approved by Landlord’s architect and engineers without unreasonable objection or condition. Without limiting the foregoing, Tenant shall be responsible for all elements of the design of Tenant’s plans (including, without limitation, compliance with law, functionality of design, the structural integrity of the design, the configuration of the Premises and the placement of Tenant’s furniture, appliances and equipment), and Landlord’s approval of Tenant’s plans shall in no event relieve Tenant of the responsibility for such design. Tenant agrees it shall be solely responsible for the timely preparation and submission of all such plans and for all elements of the design of such plans and for all costs related thereto. (The word “architect” as used in this Section 3.2 shall include an interior designer or space planner.) Tenant shall reimburse Landlord Landlord’s reasonable out-of-pocket expense incurred in connection with the review of Tenant’s plans.
Tenant Improvements Subject to the terms and conditions hereof, Landlord agrees, at its cost and expense to complete a “turnkey” interior build-out (“Tenant Improvements”) of the Leased Premises in accordance with the conditions stated in the Work Letter attached hereto as Exhibit C and incorporated hereby pursuant to the Approved Final Plans to be finalized and approved in accordance with the Work Letter and upon approval attached thereto. Any changes or modifications to the Approved Final Plans thereafter must be done in writing and signed by both Tenant and Landlord in accordance with the Work Letter. So long as in accordance with Article 19 of this Lease, Tenant agrees that Landlord shall be entitled to select, in its reasonable discretion and acting in good faith, all architects, engineers, contractors and material suppliers necessary to furnish the labor and materials for the construction of the Tenant Improvements. Landlord shall be the sole contracting party with respect to the employment of contractors which perform the work necessary to construct the Tenant Improvements. Tenant shall not be entitled to access to the Leased Premises prior to the Date of Substantial Completion and Tenant shall not interfere with or impair in any material way the construction of the Tenant Improvements, and any such interference or impairment shall be included within a Tenant Delay as defined in the Work Letter and shall entitle Landlord to all remedies provided herein for breach of this Lease. Prior to the Possession Date, Tenant shall not enter into any contract for construction of any improvements within the Leased Premises with any person other than Landlord without Landlord's prior written consent. Tenant, at Tenant's expense, shall obtain and maintain any and all necessary permits and licenses to enable Tenant to conduct Tenant’s Permitted Use, and the failure of Tenant to obtain or maintain same shall not in any manner affect the Tenant’s obligations hereunder. Landlord shall be solely responsible, at its cost and expense, for obtaining all permits and approvals related to the Tenant Improvements.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Construction of Tenant Improvements After the Landlord and Ground Lessor (in accordance with Paragraph 12 hereof) approve Tenant’s Plans and Tenant receives any necessary building permits, Tenant shall administer and diligently prosecute the construction of Tenant Improvements in accordance with Tenant’s Plans, in compliance with applicable Laws, and using building standard material, subject to Landlord’s right, at its election, to itself construct the Restroom Improvements. All Tenant Improvements (other than, if applicable, the Restroom Improvements) shall be constructed by Tenant’s Contractor (and/or its subcontractors), and Tenant shall be responsible for project management with respect to construction of the Tenant Improvements. During construction of the Tenant Improvements, Tenant and its contractors and subcontractors (i) shall not interfere with the access to, use of, or business conducted within any other portions of the Project by other tenants or occupants, (ii) shall use diligent efforts to coordinate the timing of work, deliveries and other construction matters with tenants or occupants of the Project that could be adversely impacted by such work, deliveries and construction matters, including, without limitation, by scheduling work CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. that would create noise, vibrations, dust or other similar annoyances to other tenants or occupants of the Project outside normal business hours, notwithstanding any additional cost (for overtime or otherwise) that Tenant may incur, (iii) shall clean and secure construction and staging areas daily, (iv) shall stage all construction and store all construction materials and equipment in a location designated by Landlord (in Landlord’s sole discretion) on the Project, and (v) shall otherwise abide by all rules and requirements established or imposed by Landlord relating to the performance of the Tenant Improvements, including rules relating to any required shutdown of utilities (including life-safety systems), storage of materials, and coordination of work with other tenant’s or occupant’s contractors. Tenant shall not be charged any construction management fee for Landlord’s review of Tenant’s Plans or any oversight of the construction of the Tenant Improvements.
Landlord Improvements Landlord will construct a laboratory build-out for the Premises ("Landlord Improvements") pursuant to plans submitted by Landlord to Tenant and reasonably approved by Tenant ("Plans"), which shall be consistent with the floor plan attached hereto as Exhibit "C." The Plans generally shall provide for the Landlord Improvements to be constructed in order to accommodate generally accepted generic biotechnical laboratory uses, except as Landlord may otherwise agree. Unless otherwise determined by Landlord, the Tenant Improvements shall include the construction of an energy efficient electronically controlled central HV/AC plant. Within five (5) days after the Effective Date, Tenant shall provide to Landlord for Landlord's review and approval the following: (i) a proposed detailed list of equipment for the Premises, with the make, model, and specifications, and (ii) a detailed chemical inventory, with all codes and classifications. Tenant shall provide to Landlord such other information as Landlord may reasonably request for construction of the Landlord Improvements within five (5) days after written request therefor. Tenant shall provide written notice of its disapproval of the Plans within five (5) days after the Plans have been submitted detailing its precise reasons for disapproval. The failure of Tenant to disapprove the Plans in writing within a five (5) day period shall be conclusively deemed Tenant's approval of the Plans. Landlord shall have its architect revise the Plans to remedy any reasonable objections of Tenant, and Tenant shall have an additional five (5) day period to review the revised Plans to reasonably determine if such objections were satisfied; provided, however, Tenant shall make no new objections to the Plans. If there are any reasonable objections not addressed by revised Plans, the review procedure shall be repeated until all Tenant's objections are reasonably satisfied. If Tenant has not fully approved the Plans within sixty (60) days after the date such plans were first submitted to Tenant hereunder, Landlord at its sole election may terminate this Lease. Tenant shall timely sign and submit to Landlord a Certificate of Approval of Tenant Improvement Plans in the form as shown in Exhibit "F" attached to this Lease and incorporated herein by this reference ("Certificate"). In the case where Tenant is deemed to have approved the Plans on account of Tenant's failure to timely respond following the delivery of the Plans, such approval shall be deemed to have been given in accordance with the terms of the Certificate. Tenant acknowledges that Landlord may reasonably change the Plans as required by Applicable Law or unforeseen circumstances.
