Preparation of Plans. [Check one box that applies:] The Developer has hired engineering firm(s) acceptable to the Owner to perform all engineering services needed for the preparation of plans, required specifications, and cost estimates, attached hereto as Exhibit A (collectively, the “Plans”), for the proposed Adjustment of the Owner Utilities. The Developer represents and warrants that the Plans conform to the most recent Utility Accommodation Rules issued by the Texas Department of Transportation (“TxDOT”), set forth in 43 Tex. Admin. Code Part 1, Chapter 21, Subchapter C et seq., (the “UAR”). By its execution of this Agreement or by the signing of the Plans, the Owner hereby approves the Plans and confirms that the Plans are in compliance with the “standards” described in Paragraph 3(a)(4). The Owner has provided plans, required specifications and cost estimates, attached hereto as Exhibit A (collectively, the “Plans”), for the proposed Adjustment of the Owner Utilities. The Owner represents and warrants that the Plans conform to the UAR. By its execution of this Agreement, the Developer and the Owner hereby approve the Plans. The Owner also has provided to the Developer a utility plan view map illustrating the location of existing and proposed utility facilities on the Developer’s right of way map of the Project. With regard to its preparation of the Plans, the Owner represents as follows [check one box that applies]: The Owner’s employees were utilized to prepare the Plans, and the charges therefore do not exceed the Owner’s typical costs for such work. The Owner utilized consulting engineers to prepare the Plans, and the fees for such work are not based upon a percentage of construction costs. Further, such fees encompass only the work necessary to prepare the Plans for Adjustment of the Owner Utilities described herein, and do not include fees for work done on any other project. The fees of the consulting engineers are reasonable and are comparable to the fees typically charged by consulting engineers in the locale of the Project for comparable work for the Owner.
Preparation of Plans. [Check one box that applies:]
Preparation of Plans. Tenant shall prepare at Tenant’s cost, subject to reimbursement from the Improvement Allowance to the extent permitted under Section 6 of this Exhibit B, as hereinafter defined, plans ("Tenant's Plans") for the construction and layout of the Premises, using Landlord's Building Standard Materials and Finishes, which Tenant Plans shall be in accordance with the layout plan attached hereto as Exhibit B-1 and the plan requirements set forth below and shall be submitted to Landlord for its approval (which may be given or denied in accordance with Section 5.9 of the Lease) on or before the Tenant’s Plan Delivery Date (as defined in Section 1.1 of this Lease). Tenants leasing partial floors shall design entrances, doors and any other elements which visually integrate with the elevator lobbies and common areas in a manner and with materials and finishes which are compatible with the Building Standard Materials and Finishes for such floor. Landlord reserves the right to reject plans which in its opinion fail to comply with this provision. All mechanical, electrical and plumbing engineering design work shall be performed by an engineer reasonably designated and/or approved by Landlord. (Landlord hereby approves AHA Consulting Engineers of Cambridge, MA and Lexington, MA (“AHA Consulting Engineers”) for such purpose). Time is of the essence with respect to Tenant's preparation and submission of Tenant's Plans. Landlord shall have the absolute right to approve Tenant's Plans in Landlord's sole discretion, and if, for any reason, Landlord does not approve Tenant's Plans, it shall state specifically the reasons therefor. Unless Tenant promptly makes the changes to Tenant's Plans as are required by Landlord, Landlord has the right to terminate this Lease and all of Landlord's obligations hereunder by written notice to Tenant. Landlord may delete from Tenant’s Plans and any Change Order, as hereinafter defined, and need not approve, any items or aspects of Tenant’s Plans which in Landlord’s reasonable judgment (i) would delay other work in the Building, (ii) would increase the cost of operating the Building or performing any other work in the Building, (iii) are incompatible with the design, quality, equipment or systems of the Building, (iv) would require unusual expense to readapt the Premises to general purpose office use or (v) otherwise do not comply with the provisions of this Lease (including, without limitation, Section 5.9).
Preparation of Plans. The Owner shall, at its own expense and prior to issuance of a building permit:
a) prepare the Site Plan delineating the Owner’s plans for the development of the Lands, which site plan shall be subject to the approval of the Municipality. It is hereby acknowledged that the Site Plan and Site Services Plan required to fulfill this condition have been prepared and approved, and are attached hereto as Schedule “B” and “C”, respectively;
b) prepare and submit to the Municipality all plans for off-site and on-site Services not detailed or fully described in the Site Plan, which plans shall also be subject to approval of the Municipality; and
c) provide to the Municipality all requisite copies of the Site Plan and the said plans for Services as may be required by the Municipality.
Preparation of Plans. Lot Grading Plan 2.1.4.4 Drainage Plan
Preparation of Plans. Borrower will cause the Plans to be prepared by the Architect and approved by Borrower, the Contractor and the Architect. All Plans will be reviewed and determined to be satisfactory by the Inspecting Architect, have all Governmental Approvals and the approval of all other entities and Persons with a right to approve any aspect of the work, including without limitation, any parties to the Project Covenant Documents.
Preparation of Plans. Landlord has prepared plans (“Landlord’s Plans”) for the construction of certain improvements in the Additional Premises attached hereto as Exhibit B-1, which Tenant hereby unconditionally approves. Landlord shall perform Landlord’s Work consistent with Landlord’s Plans using Building standard materials and finishes. Tenant acknowledges that Landlord’s Work does not include the installation of telecommunications cabling and equipment.
Preparation of Plans. Specifications, and Estimates
Preparation of Plans. Tenant shall prepare at Tenant’s cost, subject to the Improvement Allowance, as hereinafter defined, plans (“Tenant’s Plans”) for the construction of certain improvements in the Premises. Tenants leasing partial floors shall design entrances, doors and any other elements which visually integrate with the elevator lobbies and common areas in a manner and with materials and finishes which are compatible with the Building standard materials and common area finishes for such floor. Tenant shall employ the engineers utilized by Landlord to construct the Building for all mechanical, electrical and plumbing engineering design work. Tenant shall consult with Landlord from time to time as Tenant’s Plans are being prepared and Tenant’s Plans shall be subject to Landlord’s prior written approval prior to the commencement of construction. Landlord shall not unreasonably withhold, condition, or delay Landlord’s approval of the Tenant Plans, and if, for any reason, Landlord does not approve Tenant’s Plans, it shall state specifically the reasons therefor. Landlord need not approve, any items or aspects of Tenant’s Construction which in Landlord’s reasonable judgment (i) would delay other work in the Building, (ii) would increase the cost of operating the Building or performing any other work in the Building, (iii) are incompatible with the design, quality, equipment or systems of the Building, (iv) would require unusual expense to readapt the Premises to general purpose office use or (v) otherwise do not comply with the provisions of the Lease (including, without limitation, Section 10.05).
Preparation of Plans. (a) Buyer shall employ a professional engineering firm approved by Seller (the "Engineer") to prepare plans and specifications for the construction and installation of the 000xx Xxxxxx Improvements (collectively, the "Plans"), which shall comply with the requirements of all Laws (hereinafter defined) and with the standards and requirements of the City of Leawood for similar public roadways parallel to 000xx Xxxxxx commonly referred to as "reverse frontage" roads. "Laws" shall mean all applicable requirements, administrative and judicial orders, laws, statutes, ordinances, rules and regulations of all federal, state, county, municipal and local departments, commissions, boards, bureaus, agencies and officer thereof, having or claiming jurisdiction over all or any part of the 000xx Xxxxxx Improvements or the use thereof.
