SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:
a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or
b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Termination Notice for Force Majeure Event If a Force Majeure Event subsists for a period of 180 (one hundred and eighty) days or more within a continuous period of 365 (three hundred and sixty five) days, either Party may in its discretion terminate this Agreement by issuing a Termination Notice to the other Party without being liable in any manner whatsoever, save as provided in this Article 34, and upon issue of such Termination Notice, this Agreement shall, notwithstanding anything to the contrary contained herein, stand terminated forthwith; provided that before issuing such Termination Notice, the Party intending to issue the Termination Notice shall inform the other Party of such intention and grant 15 (fifteen) days time to make a representation, and may after the expiry of such 15 (fifteen) days period, whether or not it is in receipt of such representation, in its sole discretion issue the Termination Notice.
Termination Payment for Force Majeure Event 30.9.1 If Termination is on account of a Non-Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to 55% (fifty five per cent) of the Debt Due less Insurance Cover.
30.9.2 If Termination is on account of an Indirect Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to:
(a) 55% of the Debt Due less Insurance Cover; provided that if any insurance claims forming part of the Insurance Cover are not admitted and paid, then 80% (eighty per cent) of such unpaid claims shall be included in the computation of Debt Due;
(b) 60.5% (sixty point five per cent) of the Adjusted Equity; and
30.9.3 If Termination is on account of a Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount that would be payable under Clause 33.3.2 as if it were Authority’s Default.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Year 2000 Problem The Company and its Subsidiaries have reviewed the areas within their business and operations which could be adversely affected by, and have developed or are developing a program to address on a timely basis, the "Year 2000 Problem" (that is, the risk that computer applications used by the Company and its Subsidiaries may be unable to recognize and perform properly date-sensitive functions involving certain dates prior to and any date after December 31, 1999). Based on such review and program, the Company reasonably believes that the "Year 2000 Problem" will not have a Material Adverse Effect.
Catastrophic Leave The County will administer a Catastrophic Leave procedure designed to permit individual donations of annual leave, vacation, healthcare leave (8 hours maximum per fiscal year), compensatory and/or PIP leave time to an employee who is required to be on an extended unpaid leave due to a catastrophic medical condition or other serious circumstances.
Root Cause Analysis Upon Vendor's failure to provide the Services in accordance with the applicable Service Levels (for any reason other than a Force Majeure Event) Vendor will promptly (a) perform a root-cause analysis to identify the cause of such failure, (b) provide Prudential with a report detailing the cause of, and procedure for correcting, such failure, (c) obtain Prudential's written approval of the proposed procedure for correcting such failure, (d) correct such failure in accordance with the approved procedure, (e) provide weekly (or more frequent, if appropriate) reports on the status of the correction efforts, and (f) provide Prudential with assurances satisfactory to Prudential that such failure has been corrected and will not recur.
Recall Employees who have been laid off shall be re-employed in seniority order from most senior to least senior. Employees whose positions have been eliminated through layoff or otherwise, shall be called first to fill a vacancy within their job family.
1. Prior to other employees being recalled from the recall list, an employee who displaced another employee pursuant to provisions contained in this article shall have the right to be recalled to a vacant position for which they are qualified. However, the employee who displaces another employee shall not be eligible for a position at a higher pay grade than the one he/she originally held at the time of layoff. If the employee who displaced another employee fills a vacancy in his/her original department, then the employee whom he/she displaced will automatically be recalled into the position from which he/she previously held. After this process, other employees will be recalled to fill a vacancy for which they are qualified in the same department they were assigned at the time of their layoff.
2. Employees may be offered a position outside their department/program for which they are qualified. Employees may refuse a position outside their department/program. Employees who refuse such a position a second time shall have no further rights to recall.
3. Each employee on layoff shall be required to provide the District Personnel Office, in writing, with a current address to which a letter of recall may be sent. Employees being recalled shall be notified by “Certified Mail Delivery Confirmation” and shall have five (5) working days from the date of the receipt of notice to respond to the School Board’s offer and return to work. The School Board reserves the right to temporarily assign an employee to the vacancy until the recalled employee reports to work. If the letter is mailed to the address provided by the employee and is returned to the School Board because the address is incorrect, the School Board has fulfilled the obligation of this sub-section. If the School Board does not receive an affirmative response, the employee will be moved to the bottom of the recall list. If the recall notice is returned in the allotted time, yet not marked appropriately by the Human Resources & Equity Department, the employee shall retain his/her place on the recall list for the next job opening for which he/she is qualified. However, after the third returned notice, the employee’s name will be dropped from the recall list and the School Board shall have no further obligation to the employee.
4. An employee whose contract is non-renewed due to reorganization shall be entitled to recall rights for a layoff period of eighteen (18) months. All other employees shall be entitled to recall rights for a layoff period of twelve (12) months.
5. The employee laid off pursuant to this Article shall be given the opportunity to continue insurance coverages in existing programs during the layoff provided that the premium for such insurance programs shall be paid by the employee on a monthly basis in advance of the month due.
6. No new or substitute appointments may be made while there are laid off employees available who are qualified to fill the vacancies, except that employees may be hired into positions that have been offered and refused by employees on the layoff/recall list.
RE-WEIGHING PRODUCT Deliveries are subject to re- weighing at the point of destination by the Authorized User. If shrinkage occurs which exceeds that normally allowable in the trade, the Authorized User shall have the option to require delivery of the difference in quantity or to reduce the payment accordingly. Such option shall be exercised in writing by the Authorized User.
