Power of the Authority to undertake works (i) In the event the Parties are unable to agree to the proposed Change of Scope Orders in accordance with Clause 13.2, the Authority may, after giving notice to the Contractor and considering its reply thereto, award such Works or services to any person or agency on the basis of open competitive bidding. It is also agreed that the Contractor shall provide assistance and cooperation to the person or agency who undertakes the works or services hereunder. The Contractor shall not be responsible for rectification of any Defects, but the Contractor shall carry out maintenance of such works after completion of Defect Liability Period of work by other person or agency during the remaining period of this agreement without any extra payment.
(ii) The Works undertaken in accordance with this Clause 13.5 shall conform to the Specifications and Standards and shall be carried out in a manner that minimises the disruption in operation of the Project Highway. The provisions of this Agreement, insofar as they relate to Works and Tests, shall apply mutatis mutandis to the Works carried out under this Clause 13.5.
Power of the Arbitrator 1. An arbitrator shall not have the power to add to, subtract from, modify, or alter the terms of this Contract.
2. S/he shall have no power to rule on the substantive reasons of the Board not to reemploy an annual contract teacher, placement of an annual contract teacher on a fourth year of annual contract, or the decision not to continue any teacher in any extracurricular activity, provided that said reason does not amount to a violation, misinterpretation, or misapplication of this Contract. The arbitrator, however, shall have the power to rule on the procedural violations of the above.
3. S/he shall have no power to rule on an alleged violation, misinterpretation, or misapplication of School Board policy, provided that there was no violation, misinterpretation, or misapplication of this Contract.
Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works.
(iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor:
(a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre.
(b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7
(c) all environmental clearances as required under Clause 4.3.8
(iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).
Authority Each party represents that it is authorized to bind to the terms of this DPA, including confidentiality and destruction of Student Data and any portion thereof contained therein, all related or associated institutions, individuals, employees or contractors who may have access to the Student Data and/or any portion thereof.
Power; Authority It has all requisite power and authority to enter into this Agreement, to perform its obligations hereunder and to consummate the transactions contemplated hereby. The execution, delivery and performance of this Agreement, the purchase of the Transferred Assets and the consummation of the transactions provided for herein have been duly authorized by all necessary action on the part of the Buyer. This Agreement has been duly executed and delivered by the Buyer and constitutes the legal, valid and binding obligation of the Buyer enforceable against the Buyer in accordance with its terms, except as such enforceability may be limited by bankruptcy, insolvency, reorganization, moratorium or other laws affecting creditors’ rights and by general principles of equity (whether applied in a proceeding at law or in equity).
Overriding powers of the Authority (i) If in the reasonable opinion of the Authority, the Contractor is in material breach of its obligations under this Agreement and, in particular, the Maintenance Requirements, and such breach is causing or likely to cause material hardship or danger to the Users and pedestrians, the Authority may, without prejudice to any of its rights under this Agreement including Termination thereof, by notice require the Contractor to take reasonable measures immediately for rectifying or removing such hardship or danger, as the case may be.
(ii) In the event that the Contractor, upon notice under Clause 14.9 (i), fails to rectify or remove any hardship or danger within a reasonable period, the Authority may exercise overriding powers under this Clause 14.9 (ii) and take over the performance of any or all the obligations of the Contractor to the extent deemed necessary by it for rectifying or removing such hardship or danger; provided that the exercise of such overriding powers by the Authority shall be of no greater scope and of no longer duration than is reasonably required hereunder; provided further that any costs and expenses incurred by the Authority in discharge of its obligations hereunder shall be recovered by the Authority from the Contractor, and the Authority shall be entitled to deduct any such costs and expenses incurred from the payments due to the Contractor under Clause 19.7 for the performance of its Maintenance obligations.
(iii) In the event of a national emergency, civil commotion or any other circumstances specified in Clause 21.3, the Authority may take over the performance of any or all the obligations of the Contractor to the extent deemed necessary by it, and exercise such control over the Project Highway or give such directions to the Contractor as may be deemed necessary; provided that the exercise of such overriding powers by the Authority shall be of no greater scope and of no longer duration than is reasonably required in the circumstances which caused the exercise of such overriding power by the Authority. For the avoidance of doubt, it is agreed that the consequences of such action shall be dealt in accordance with the provisions of Article 21. It is also agreed that the Contractor shall comply with such instructions as the Authority may issue in pursuance of the provisions of this Clause 14.9 (iii), and shall provide assistance and cooperation to the Authority, on a best effort basis, for performance of its obligations hereunder.
Power The Purchaser has all requisite power to execute and deliver this Agreement and to carry out and perform its obligations under the terms of this Agreement.
Rights and discretions of the Agent (a) The Agent may rely on:
(i) any representation, notice or document believed by it to be genuine, correct and appropriately authorised; and
(ii) any statement made by a director, authorised signatory or employee of any person regarding any matters which may reasonably be assumed to be within his knowledge or within his power to verify.
(b) The Agent may assume (unless it has received notice to the contrary in its capacity as agent for the Lenders) that:
(i) no Default has occurred (unless it has actual knowledge of a Default arising under Clause 22.1 (Non-payment));
(ii) any right, power, authority or discretion vested in any Party or the Majority Lenders has not been exercised; and
(iii) any notice or request made by the Parent (other than a Utilisation Request) is made on behalf of and with the consent and knowledge of all the Obligors.
(c) The Agent may engage, pay for and rely on the advice or services of any lawyers, accountants, surveyors or other experts.
(d) The Agent may act in relation to the Finance Documents through its personnel and agents.
(e) The Agent may disclose to any other Party any information it reasonably believes it has received as agent under this Agreement.
(f) Notwithstanding any other provision of any Finance Document to the contrary, neither the Agent nor the Arrangers are obliged to do or omit to do anything if it would or might in its reasonable opinion constitute a breach of any law or regulation or a breach of a fiduciary duty or duty of confidentiality.
(g) Without prejudice to the generality of paragraph (f) above, the Agent may disclose the identity of a Defaulting Lender to the other Finance Parties and the Parent and shall disclose the same upon the written request of the Parent or the Majority Lenders.
(h) The Agent may not disclose to any Finance Party any details of the rate notified to the Agent by any Lender or the identity of any such Lender for the purpose of paragraph (a)(ii) of Clause 10.2 (Market Disruption).
Power of Sale If an Event of Default should occur, Beneficiary may ------------- enforce payment of the obligations secured hereby and shall, at its option, execute or cause the Trustee to execute a written notice of such default and of its election to cause to be sold the Property to satisfy the obligations hereof, and shall cause such notice to be recorded in the office of the recorder of each county wherein said Property is situated. Prior to publication of the notice of sale, Beneficiary shall deliver to Trustee this Deed of Trust and the Note or other evidence of indebtedness which is secured hereby, together with a written request for the Trustee to proceed with a sale of the property described herein, pursuant to the provisions of law and this Deed of Trust. Notice of sale having been given as then required by law and not less than the time then required by law having elapsed after recordation of such notice of default, Trustee, without demand on Trustor, shall sell said property at the time and place of sale fixed by it in said notice of sale, either as a whole or in separate parcels and in such order as it may determine, at public auction to the highest bidder for cash in lawful money of the United States, payable at time of sale. Trustee may postpone sale of all or any portion of said property by public announcement at such time and place of sale, and from time to time thereafter may postpone such sale by public announcement at the time fixed by the preceding postponement. Trustee shall deliver to the purchaser its deed conveying the property so sold, but without any covenant or warrant, express or implied. The recitals in such deed of any matters or facts shall be conclusive proof of the truthfulness thereof. Any person, including Trustor, Trustee, or Beneficiary, may purchase at such sale. After deducting all reasonable costs, fees, and expenses of Trustee and of this Trust, including cost of evidence of title and reasonable counsel fees in connection with sale, Trustee shall apply the proceeds of sale (i) to the payment of all sums expended under the terms hereof, not then repaid with accrued interest at the Default Rate, as defined in the Note, provided, however, that such interest rate shall in no event exceed the maximum interest rate allowed by law; (ii) all other sums then secured hereby; and (iii) the remainder, if any, to the person or persons legally entitled thereto.
