Preliminary Title Report (a) Not later than four (4) business days after the date of this Agreement, Seller, with Buyer's assistance and cooperation as necessary, shall arrange for the Title Company to prepare and deliver to Buyer a preliminary title report (the "Title Report") covering the Real Property dated not earlier than the date of this Agreement, such report showing all matters of record and all items which would be shown as exceptions on a ALTA owner's policy of title insurance, together with a recent ALTA survey of the Real Property certified by a licensed land surveyor and a legible copy of each recorded document underlying any exceptions shown in the Title Report. Subject only to the following permitted exceptions (the "Permitted Exceptions"), Seller shall cause all exceptions to title to the Real Property set forth in such Title Report to be removed prior to the Closing: (1) the standard printed exceptions contained in the Title Company's form of Owner's Policy; (2) building restrictions and zoning regulations heretofore or hereafter adopted by any municipal or other public authority relating to the Property; (3) current property taxes not yet delinquent; (4) the exceptions approved by Buyer in accordance with Section 5.13(b); and (5) any exception to which Buyer, in Buyer's sole discretion, specifically and expressly consents in writing prior to the Closing. Buyer shall pay all fees and costs associated with obtaining the Title Report. (b) Buyer shall have until 5:00 p.m. (Los Angeles time) on the fifth (5th) calendar day following Buyer's receipt of the Title Report to disapprove, in Buyer's sole discretion, any matters set forth in the Title Report; provided, however, that Buyer may not disapprove of the exceptions described in items (1), (2) and (3) of Section 5.13(a). If Buyer timely disapproves of any matters set forth in the Title Report, other than with respect to the exceptions described in items (1), (2) and (3) of Section 5.13(a), Seller shall have three (3) business days to indicate in writing whether Seller will cause such disapproved matters to be removed as exceptions to title prior to or concurrently with the Closing. Seller's failure to timely respond shall be deemed to constitute Seller's irrevocable agreement to remove all such disapproved matters as exceptions to title. If Seller timely indicates that it is unwilling to remove any such disapproved matters as exceptions to title, Buyer may elect to (i) proceed with the transaction contemplated hereby and take title subject to such disapproved matters, or (ii) terminate this Agreement. Buyer's failure to make such election within three (3) business days after being informed of Seller's decision shall be deemed an election of option (i). If Buyer terminates this Agreement pursuant to this Section 5.13(b), the Deposit (and all interest accrued thereon) shall be returned to Buyer, and the parties shall have no further obligations to one another except for any obligations that, by their terms, survive the termination of this Agreement.
Preliminary Design Phase 30 percent plans) A. Proceed with Preliminary Design Phase after the completion of the Conceptual phase which includes: Acceptance by Owner of the Conceptual Report and any other Study and Report Phase deliverables; selection by Owner of a recommended solution; issuance by Owner of any instructions for use of Project Strategies, Technologies, and Techniques, or for inclusion of sustainable features in the design, and Indication by Owner of any specific modifications or changes in the scope, extent, character, or design requirements of the Project desired by Owner. 1. Prepare Preliminary Design Phase documents consisting of final design criteria, preliminary drawings, outline specifications, and written descriptions of the Project. 2. Include on plans, property lines, structure locations, ownership names and contact information. 3. In preparing the Preliminary Design Phase documents, use any specific applicable Project Strategies, Technologies, and Techniques authorized by Owner during or following the Study and Conceptual Phase, and include sustainable features, as appropriate, pursuant to Owner’s instructions. 4. Provide necessary field surveys, topographic and utility mapping for Engineer’s design purposes. Comply with the scope of work and procedure for the identification and mapping of existing utilities as defined by Section A1.03 “Utility Requirements” and Section A1.04 “Survey Services” 5. Visit the Site as needed to prepare the Preliminary Design Phase documents. 6. Advise Owner if additional reports, data, information, or services of the types described are necessary and assist Owner in obtaining such reports, data, information, or services. 7. Continue to assist Owner with Project Strategies, Technologies, and Techniques that Owner has chosen to implement. 8. Based on the information contained in the Preliminary Design Phase documents, prepare a revised opinion of probable Construction Cost, and assist Owner in tabulating the various cost categories which comprise Total Project Costs. 9. Obtain and review Owner’s instructions regarding Owner’s procurement of construction services (including instructions regarding advertisements for bids, instructions to bidders, and requests for proposals, as applicable), Owner’s construction contract practices and requirements, insurance and bonding requirements, electronic transmittals during construction, and other information necessary for the finalization of Owner’s bidding-related documents (or requests for proposals or other construction procurement documents), and Construction Contract Documents. Also obtain and review copies of Owner’s design and construction standards, Owner’s standard forms, general conditions, supplementary conditions, text, and related documents or content for Engineer to include in the draft bidding-related documents (or requests for proposals or other construction procurement documents), and in the draft Construction Contract Documents, when applicable. 10. Development communication plan for project: considering the use of door hangers, letters, public meetings, changeable message boards. 11. Furnish 6 review copies of the Preliminary Design Phase documents, opinion of probable Construction Cost, and any other Preliminary Design Phase deliverables to Owner by established due date, and review them with Owner. Owner shall submit to Engineer any comments regarding the furnished items. 12. Revise the Preliminary Design Phase documents, opinion of probable Construction Cost, and any other Preliminary Design Phase deliverables in response to Owner’s comments, as appropriate, and furnish to Owner 6 copies of the revised Preliminary Design Phase documents, revised opinion of probable Construction Cost, and any other deliverables by the specified due date. 13. Engineer’s services under the Preliminary Design Phase will be considered complete on the date when Engineer has delivered to Owner the revised Preliminary Design Phase documents, revised opinion of probable Construction Cost, and any other Preliminary Design Phase deliverables.
EU SURVEY 5.1. The participant shall complete and submit the online EU Survey after the mobility abroad within 30 calendar days upon receipt of the invitation to complete it.
Preliminary Matters 3.1. At least five (5) days prior to the pre-construction meeting described in Section 3.2, Contractor shall submit to Consultant for Consultant’s review and acceptance: 3.1.1. A progress schedule in the indicated form: Bar Chart Modified Critical Path Method (“CPM”) CPM Computerized CPM (CPM is interpreted to be generally as outlined in the Association of General Contractors (“AGC”) publication, “The Use of CPM in Construction.”) The progress schedule shall indicate the start and completion dates of the various stages of the Work, and shall show an activity network for the planning and execution of the Work. Included with the progress schedule shall be a narrative description of the progress schedule. The progress schedule must be updated monthly by Contractor, submitted as part of each Application for Payment, and must be acceptable to Consultant. 3.1.2. A preliminary schedule of Shop Drawing submissions; and 3.1.3. In a lump sum contract or in a contract that includes lump sum bid items of Work, a preliminary schedule of values for all of the Work that includes quantities and prices of items aggregating the Contract Price and that subdivides the Work into component parts in sufficient detail to serve as the basis for progress payments during construction. Such prices will include a breakdown of labor, equipment, materials, and an appropriate amount of overhead and profit applicable to each item of Work, which amounts Contractor must confirm in writing at the time of submission. In addition, after award but prior to the submission of the progress schedule, Consultant, Contract Administrator, and Contractor shall meet with all utility owners and secure from them a schedule of utility relocation; provided, however, that neither Consultant nor Town shall be responsible for the nonperformance by the utility owners. 3.2. At a time specified by Consultant, but before Contractor starts the Work at the Project site, a conference attended by Contractor, Consultant, and others as deemed appropriate by Contract Administrator, will be held to discuss the schedules referred to in Section 3.1; to discuss procedures for handling Shop Drawings and other submittals and for processing Applications for Payment; and to establish a working understanding among the Parties as to the Work. 3.3. Within thirty-five (35) days from the Project Initiation Date set forth in the applicable Notice to Proceed, a conference attended by Contractor, Consultant, and others, as appropriate, will be held to finalize the schedules submitted in accordance with Section 3.1. Within forty-five
Preliminary Approval A. As soon as practicable after this Agreement is fully executed, for settlement purposes only, the Plaintiffs and Co-Lead Counsel shall request the Court to make preliminary findings, enter the Preliminary Approval Order granting conditional certification of the Class, subject to final findings and ratification in the Final Order and Judgment, and appoint the Plaintiffs as class representatives and Co-Lead Counsel as counsel for the Class. Neither Defendant nor Defendant’s Counsel will object to such requests for the purposes of effectuating the Settlement. Such agreement not to object to class certification shall extend only as necessary to effectuate the Settlement. As set forth in the draft Preliminary Approval Order, the Plaintiffs shall request the Court to enter an order: 1. preliminarily approving and finding this Agreement and the Settlement as being fair, reasonable, and adequate; 2. conditionally certifying the Litigation as a settlement class action under Rule 23(b)(3) and (e) of the Federal Rules of Civil Procedure; 3. appointing Plaintiffs as class representatives and Co-Lead Counsel as counsel for the Class; 4. preliminarily approving the form, manner, and content of the Class Notice, as provided herein, and finding that notice is fair, reasonable, and the best notice practicable under the circumstances in connection with notifying the Class Members of their rights and responsibilities under the Settlement and satisfying due process and Rule 23 of the Federal Rules of Civil Procedure; 5. appointing the Settlement Administrator to send Class Notice and administer the Settlement; 6. providing that Class Members will have until a date certain to object to or file a request for exclusion from the Settlement, as provided herein;
Preliminary Examination 24.1 The Purchaser will examine the bids to determine whether they are complete, whether any computational errors have been made, whether required sureties have been furnished, whether the documents have been properly signed, and whether the bids are generally in order. 24.2 Arithmetical errors will be rectified on the following basis. If there is a discrepancy between the unit price and the total price that is obtained by multiplying the unit price and quantity, the unit price shall prevail, and the total price shall be corrected. If the Supplier does not accept the correction of the errors, its bid will be rejected, and its bid security may be forfeited. If there is a discrepancy between words and figures, the amount in words will prevail. 24.3 The Purchaser may waive any minor informality, nonconformity, or irregularity in a bid which does not constitute a material deviation, provided such waiver does not prejudice or affect the relative ranking of any Bidder. 24.4 Prior to the detailed evaluation, pursuant to ITB Clause 25 the Purchaser will determine the substantial responsiveness of each bid to the bidding documents. For purposes of these Clauses, a substantially responsive bid is one which conforms to all the terms and conditions of the bidding documents without material deviations. Deviations from, or objections or reservations to critical provisions, such as those concerning Bid Security (ITB Clause 15), Applicable Law (GCC Clause 30), and Taxes and Duties (GCC Clause 32), will be deemed to be a material deviation. The Purchaser’s determination of a bid’s responsiveness is to be based on the contents of the bid itself without recourse to extrinsic evidence.
Title Report If no Additional Mortgage Policy is required with respect to such Additional Mortgaged Property, a title report issued by the Title Company with respect thereto, dated not more than 30 days prior to the date such Additional Mortgage is to be recorded and satisfactory in form and substance to Administrative Agent;
Completion Schedule 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof. 6.2 ENGINEER shall adhere to all time limits stated in this Agreement or included in any accepted time schedule. All such time limits shall be of the essence to this Agreement. 6.3 In all events the various stages and phases of ENGINEER’S services are to be completed in such sequence and at such times, and with approved or agreed upon time limits, as may be required to assure the timely, continuous, efficient and diligent prosecution of the work and services provided for by this Agreement. 6.4 OWNER may at any time, by written order, make changes within the general scope of the Agreement in the services of work to be performed. If ENGINEER believes that such a change justifies an increase in ENGINEER’S contract time or contract price required to perform the series under this Agreement it must assert such claim in writing within thirty (30) days of receipt of OWNER’S written order giving rise to the claim. No claim for adjustment in the contract time or contract price will be valid if not submitted in accordance with this paragraph. No services for which ENGINEER will charge additional compensation shall be furnished without the written authorization of OWNER. 6.5 ENGINEER shall carry on all work required under this Agreement and maintain the schedule for services during all disputes or disagreements with OWNER. No work shall be delayed or postponed pending resolution of any disputes or disagreements except as permitted in Article 8, or as ENGINEER and OWNER may otherwise agree in writing. 6.6 If the commencement, prosecution or completion of the services under this Agreement, or of the construction of the Project is delayed by any act, omission, delay, neglect or default of ENGINEER, or anyone employed by ENGINEER, or by any damage or acts caused by the negligent acts or omission by ENGINEER, then ENGINEER shall be liable to OWNER for any and all costs, assessments, expense, liabilities or damages caused thereby, in accordance with Section 4.8. 6.7 ENGINEER shall not be responsible for any time delays in the Project, or in the performance of services under this Agreement, to the extent such delays are caused solely by any act, omission, neglect or default of OWNER or anyone employed by OWNER, or by the unreasonable delay of any review agency or utility, or for any delay or damage caused by fire or the combined action of workers and which are in no way chargeable, in whole or in part, to ENGINEER, or by any other conditions or circumstances beyond the control of ENGINEER, its employee, agent, or other persons for whose acts or omissions ENGINEER is responsible. In the event of such delay, ENGINEER shall be entitled to an adjustment in the schedules or agreed time limitations for the performance of services, and this Agreement shall be modified in writing accordingly. Any claim of ENGINEER for adjustment under this cause must be asserted in writing within thirty (30) days from the date of the occurrence of the event giving rise to the claim, unless OWNER grants a further period of time before the date of final payment to ENGINEER. The adjustment of time for the performance of services, as provided in this paragraph, shall be ENGINEER’s sole exclusive right, entitlement and remedy in the event of such delays, and ENGINEER shall have no claim against OWNER for adjustment for increase in costs of performance, or other damages occurred in connection therewith.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Title and Survey Review The condition of the title to the Properties. Prior to the Effective Date, Seller has provided to Buyer an ALTA title report or commitment for title insurance (individually, a “Title Commitment” and collectively, the “Title Commitments”) prepared by First American Title Insurance Company (the “Title Company”) with respect to each Real Property. Buyer may request from the Title Company an updated Title Commitment, together with copies of all documents referred to therein, for any or all of the Properties. Prior to the Effective Date, Seller has provided to Buyer a copy of an existing survey of each Property, and Buyer may, at Buyer’s sole cost and expense, obtain an update of each survey (the “Surveys”). It shall be a condition to Closing that the Title Company shall be committed to issue to Buyer an ALTA extended coverage Owner’s Policy of Title Insurance for each Property, in an amount equal to the Allocated Purchase Price and insuring title to each Property is vested in Buyer, subject only to the “Permitted Exceptions” (as hereinafter defined) and including only the “Endorsements” (as hereinafter defined) (individually and collectively, the “Title Policy”). The following matters shall be deemed “Permitted Exceptions”: all matters disclosed by the Title Commitments other than (A) those matters which the Title Company has removed from the Title Commitment by written supplement and (B) those “Mandatory Cure Items” (as hereinafter defined). “Mandatory Cure Items” shall mean (1) those matters which Seller has agreed in writing to cause to be removed at or before Closing in accordance with, and subject to, Paragraph 3(c), (2) any mortgages, deeds of trust or other similar encumbrance evidencing outstanding indebtedness voluntarily created by Seller which can be satisfied by the payment of an ascertainable amount of money, and (3) any mechanic’s, materialman’s or broker’s liens filed against a Property as a result of Seller’s acts or omissions (e.g., failure to pay) which can be satisfied by the payment of an ascertainable amount of money. The “Endorsements” shall include only those endorsements which, prior to the expiration of the Due Diligence Period, the Title Company has agreed in writing to include in the applicable Title Policy or Seller has agreed in writing to cause to be included in such Title Policy;
