SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.
4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work.
4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged.
4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents.
4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents.
4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof.
4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals.
4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Product Labeling The labeling of all Licensed Products sold or offered for sale under this Agreement shall expressly state that the Licensed Product is manufactured under a license from the Medicines Patent Pool.
New Products You agree to comply with NASD Notice to Members 5-26 recommending best practices for reviewing new products.
Combination Products If a LICENSED PRODUCT is sold to any third party in combination with other products, devices, components or materials that are capable of being sold separately and are not subject to royalties hereunder (“OTHER PRODUCTS,” with the combination of products being referred to as “COMBINATION PRODUCTS” and the Other Product and Licensed Product in such Combination Product being referred to as the “COMPONENTS”), the NET SALES of such LICENSED PRODUCT included in such COMBINATION PRODUCT shall be calculated by multiplying the NET SALES of the COMBINATION PRODUCT by the fraction A/(A+B), where A is the average NET SALES price of such LICENSED PRODUCT in the relevant country, as sold separately, and B is the total average NET SALES price of all OTHER PRODUCTS in the COMBINATION PRODUCT in the relevant country, as sold separately. If, in any country, any COMPONENT is not sold separately, NET SALES for royalty determination shall be determined by the formula [C / (C+D)], where C is the aggregate average fully absorbed cost of the Licensed Product components during the prior Royalty Period and D is the aggregate average fully absorbed cost of the other essential functional components during the prior Royalty Period, with such costs being determined in accordance with generally accepted accounting principles. To the extent that any SUBLICENSE INCOME relates to a COMBINATION PRODUCT or is otherwise calculated based on the value of one or more licenses or intellectual property rights held by the COMPANY, an AFFILIATE or SUBLICENSEE, COMPANY shall determine in good faith and report to THE PARTIES the share of such payments reasonably attributable to COMPANY’s or such AFFILIATE’s sublicense of the rights granted hereunder, based upon their relative importance and proprietary protection, which portion shall be the SUBLICENSE INCOME. THE PARTIES shall have the right to dispute such sharing determination in accordance with the dispute provisions of the AGREEMENT.
Supply of Product 4.1 DAEWOONG shall manufacture and supply Product to AEON in a primary packaged and labeled form. Product packaging shall display the logo of DAEWOONG (to the extent required by applicable law) and AEON and the outer label shall be marked using English language in accordance with applicable laws and Product’s Regulatory Approvals.
4.2 AEON’s estimate sales forecast of the Product during the Term of Agreement in the Territory in the Field is set forth in Annex D. Within ninety (90) days after the Effective Date, AEON shall provide DAEWOONG with a non-binding twelve (12) month rolling forecast of its requirements of Product, which the Parties agree is not a commitment to buy any stated quantity. Thereafter, on at least a quarterly basis, AEON shall provide DAEWOONG with an updated twelve (12) month rolling forecast, together with a binding six (6) month forecast to the extent AEON has requested Safety Stock as described in Article 4.10 below. Each such forecast shah be referred to herein as a “Forecast.”
4.3 AEON may from time to time submit Purchase Orders to DAEWOONG for Product in accordance with the forecasting requirements in Article 4.2. Orders will be shipped on CIF Los Angeles port.
4.4 Once a Purchase Order for Product and Product Samples has been received by DAEWOONG, it shall be considered as irrevocable.
4.5 AEON agrees herein to place an Order for Product not later than [***] from receipt of Regulatory Approval.
4.6 Individual Purchase Orders of Product shall be placed at least [***] in advance of the required delivery date.
4.7 For the purpose of Commercialization, AEON will store and maintain the full quantity of Product in a clean, secured area in accordance with the reasonable directions and specifications provided by DAEWOONG in writing in connection thereof in the Territory. AEON will advise DAEWOONG on the applicable requirements specifically deriving from the laws and regulations in the Territory.
4.8 AEON agrees that DAEWOONG and its collaborators and agents, in DAEWOONG’s sole discretion, which collaborators and Agents will be subject to appropriate obligations of confidentiality, will have the right upon reasonable prior notice, to observe and to inspect and to audit AEON’s facility to ascertain compliance by AEON with the terms of this Agreement, including without limitation (a) the holding facilities for Product, and (b) AEON’s compliance with applicable law, including cGMP (if applicable). Following any such audit, DAEWOONG will discuss its observations and conclusions with AEON and corrective actions, if any, will be agreed upon by the Parties, and executed by AEON using Commercially Reasonable Efforts.
4.9 In addition to any other rights and remedies available to AEON, AEON shall have the right to recover lost profits in the event that DAEWOONG fails to deliver at least [***] in any [***] (a “Supply Default Event”). For purposes of this provision, lost profits would be equal to [***] of AEON operating profit (sales less direct expenses and the puce paid by AEON for such Products) on Products that have not been shipped against firm Purchase Orders during the period leading up to the Supply Default Event and bona fide Purchase Orders submitted by AEON that are consistent with the Forecast during the Supply Default Period (as defined below). Such payment shall be made with respect to all Product not shipped in the period giving rise to the Supply Default and for the period until DAEWOONG is again timely shipping Product to meet AEON’s needs (the “Supply Default Period”). The first such payment shall be made within [***] of the Supply Default Event, and every [***] thereafter. AEON agrees to permit full disclosure to DAEWOONG of AEON’s accounting records, solely related to the calculation of lost profits, for the [***] ending on the first day of the month in which the Supply Event Default occurred. In the event that DAEWOONG is unable to supply both AEON’s requirements of Product and its own and third parties’ requirements for Product, DAEWOONG shall allocate Product that DAEWOONG has in inventory and that DAEWOONG is able to Product, so that AEON receives its requirements of Product in priority to DAEWOONG and third parties.
4.10 At the request of AEON, DAEWOONG shall at its own cost and expense during the Term, maintain an amount of inventory of Product equal to AEON’s requirements for Product for [***] based on AEON’s most recent forecast (“Safety Stock”). The Safety Stock shall be (i) maintained for the sole benefit of AEON and its Affiliates, (ii) shall be stored at a secure facility in compliance with GMP, and (iii) shall not be used for the benefit of any other customer of DAEWOONG. DAEWOONG shall rotate the Safety Stock on a “First Expiry-First Out” basis for routine fulfillment of firm orders, subject to Article 7.
Licensed Products Lessee will obtain no title to Licensed Products which will at all times remain the property of the owner of the Licensed Products. A license from the owner may be required and it is Lessee's responsibility to obtain any required license before the use of the Licensed Products. Lessee agrees to treat the Licensed Products as confidential information of the owner, to observe all copyright restrictions, and not to reproduce or sell the Licensed Products.
Product Recalls (a) If either Party reasonably decides or is required by any government authority or court of competent jurisdiction, to initiate a product recall, withdrawal or field correction with respect to, or if there is any governmental seizure of, the Product, the Party initiating or required to initiate such action will notify the other Party promptly of the details regarding such action, including providing copies of all relevant documentation concerning such action. The Parties will assist each other in investigating any such situation and all regulatory contacts that are made and all activities concerning seizure, recall, withdrawal or field correction will be jointly coordinated by HSL and LMI.
(b) If any such recall, withdrawal, field correction or seizure occurs due solely to (i) failure of any Product produced by HSL hereunder to conform to Specifications (including, without limitation, being adulterated or misbranded) or any warranty or other requirement set forth in this Agreement, (ii) the failure of HSL to comply in all material respects with any applicable law, rule, regulation, guideline, standard, court order or decree or (iii) the negligent or intentional wrongful act or omission of HSL in connection with the production of Product hereunder, then HSL shall bear the **** of any such seizure, recall, withdrawal or field correction and shall reimburse LMI for its ****, including any purchase price payments made to HSL and related taxes to the extent related to such recalled Product. To the extent any such recall, withdrawal, field correction or seizure occurs for any reason other than that set forth in the immediately preceding sentence, then LMI shall bear the **** of any such seizure, recall, withdrawal or field correction. If both HSL and LMI contribute to the cause of a seizure, recall, withdrawal or field correction, the cost and expense thereof will be shared in proportion to each Party’s contribution to the problem. For the purposes of this Agreement, the expenses of any recall, withdrawal, field correction or seizure shall include, without limitation, the out-of-pocket expenses of notification and destruction or return of the recalled Product and all other out-of-pocket costs incurred in connection with such recall but shall not include a Party’s lost profits. HSL’s reimbursement for the costs of LMI Materials related to such recall, withdrawal or field correction is limited by Section 5.6(c).
Product Data Illustrations, standard schedules, performance charts, instructions, brochures, diagrams, and other information furnished by Developer to illustrate a material, product, or system for some portion of the Work.
Product Specifications (a) Supplier shall manufacture all Products according to the Specifications in effect as of the date of this Agreement, with such changes or additions to the Specifications of the Products related thereto as shall be requested by Buyer in accordance with this Section or as otherwise agreed in writing by the Parties. All other Products shall be manufactured with such Specifications as the Parties shall agree in writing.
(b) Buyer may request changed or additional Specifications for any Product by delivering written notice thereof to Supplier not less than one hundred twenty (120) days in advance of the first Firm Order for such Product to be supplied with such changed or additional Specifications. Notwithstanding the foregoing, if additional advance time would reasonably be required in order to implement the manufacturing processes for production of a Product with any changed or additional Specifications, and to commence manufacture and delivery thereof, Supplier shall so notify Buyer, and Supplier shall not be required to commence delivery of such Product until the passage of such additional time.
(c) Supplier shall be required to accommodate any change of, or additions to, the Specifications for any Product, if and only if (i) in Supplier’s good faith judgment, such changed or additional Specifications would not require Supplier to violate good manufacturing practice, (ii) the representation and warranty of Buyer deemed made pursuant to Subsection (e) below is true and correct, and (iii) Buyer agrees to reimburse Supplier for the incremental costs and expenses incurred by Supplier in accommodating the changed or additional Specifications, including the costs of acquiring any new machinery and tooling. For the avoidance of doubt, such costs and expenses shall be payable by Buyer separately from the cost of Products at such time or times as Supplier shall request.
(d) Supplier shall notify Buyer in writing within thirty (30) days of its receipt of any request for changed or additional Specifications (i) whether Supplier will honor such changed or additional Specifications, (ii) if Supplier declines to honor such changed or additional Specifications, the basis therefor and (iii) if applicable, the estimated costs and expenses that Buyer will be required to reimburse Supplier in respect of the requested changes or additions, as provided in Subsection (c) above. Buyer shall notify Supplier in writing within fifteen (15) days after receiving notice of any required reimbursement whether Buyer agrees to assume such reimbursement obligation.
(e) By its request for any changed or additional Specifications for any Product, Buyer shall be deemed to represent and warrant to Supplier that the manufacture and sale of the Product incorporating Buyer’s changed or additional Specifications, as a result of such incorporation, will not and could not reasonably be expected to (i) violate or conflict with any contract, agreement, arrangement or understanding to which Buyer and/or any of its Affiliates is a party, including this Agreement and any other contract, agreement, arrangement or understanding with Supplier and/or its Affiliates, (ii) infringe on any trademark, service xxxx, copyright, patent, trade secret or other intellectual property rights of any Person, or (iii) violate any Applicable Law. Buyer shall indemnify and hold Supplier and its Affiliates harmless (including with respect to reasonable attorneys’ fees and disbursements) from any breach of this representation and warranty.
