Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever.
(ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties.
(iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority.
(iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i).
(v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party.
(vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway.
(vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.
Demolition The Lessor shall remove existing abandoned electric, telephone, and data cabling and devices, as well as any other improvements or fixtures in place, to accommodate the Government’s requirements. Any demolition of existing improvements that is necessary to satisfy the Government’s layout shall be done at the Lessor’s expense.
Environmental Management (a) The Operator must, prior to the commencement of any Train Services (including any new or varied Train Services):
(i) cause a suitably qualified person reasonably acceptable to both Parties to prepare a report (“Environmental Investigation and Risk Management Report”) containing an environmental investigation component and an environmental risk management component which respectively identify:
(A) possible risks of Environmental Harm arising out of the proposed use of the Nominated Network by the Operator, including risks associated with those matters identified in Part 3 of Schedule 6; and
(B) the manner in which the Operator proposes to address the possible risks of Environmental Harm identified in the Environmental Investigation and Risk Management Report as well as the roles and responsibilities, including financial responsibility, for the control measures proposed and an audit regime, provided that if the Operator has an existing Environmental Management System it proposes to use in connection with the proposed Train Services on the Nominated Network, the Environmental Investigation and Risk Management Report should also detail the extent to which the Operator believes its existing Environmental Management System addresses the risks identified in the Environmental Investigation and Risk Management Report; and
(ii) provide a copy of the Environmental Investigation and Risk Management Report to Aurizon Network for its consideration and, if requested by Aurizon Network, a copy of the relevant parts of the Operator’s existing Environmental Management System referred to in the Environmental Investigation and Risk Management Report.
(b) If the Environmental Investigation and Risk Management Report discloses areas of risk which, in the reasonable opinion of Aurizon Network, cannot be adequately managed by the proposals set out in the Environmental Investigation and Risk Management Report or, in the reasonable opinion of Aurizon Network, fails to identify and adequately deal with additional relevant environmental risks, then Aurizon Network may give notice to that effect to the Operator within thirty (30) days after the date on which the Environmental Investigation and Risk Management Report was received by Aurizon Network (or such other period as the Parties, acting reasonably, may agree), detailing the risks not so adequately managed or not so identified or adequately dealt with. If Aurizon Network does not give such notice, the Environmental Investigation and Risk Management Report, subject to Clause 9.1(k), shall be included in Part 1 of Schedule 9 and amendments made to this Agreement [(including variations to the Base Access Charges)] if applicable. [Bracketed text is only included where Operator pays non-TOP Access Charges]
(c) If Aurizon Network gives notice pursuant to Clause 9.1 (b) the Operator may respond, by a date agreed by the Parties, with a written proposal which demonstrates how the Operator proposes to manage those risks (“Operator’s Proposal”). The Operator’s Proposal must:
(i) contain an investigation of the areas of risk and/or additional relevant environmental risks referred to in Clause 9.1(b);
(A) specify risk abatement or attenuation measures which the Operator proposes to undertake in relation to them; and/or
(B) specify how the Access Charges might contain a component reflecting the cost to Aurizon Network of assuming all or some portion of the risk;
(ii) in relation to paragraph (ii)(A) specify a timeframe for implementation of those measures; and
(iii) specify details of any public consultation the Operator proposes to undertake in connection with the implementation of any such measures.
(d) Aurizon Network may, acting reasonably, accept or reject all or part of the Operator’s Proposal.
(e) If Aurizon Network accepts the Operator’s Proposal, then it will be incorporated into and form part of the Environmental Investigation and Risk Management Report which, subject to Clause 9.1(k), shall be included in Part 1 of Schedule 9 and amendments made to the Agreement [(including variations to the Base Access Charges)] if applicable. [Bracketed text is only included where Operator pays non-TOP Access Charges]
(f) If the Operator fails to submit to Aurizon Network an Operator’s Proposal by the date agreed by the Parties or if Aurizon Network rejects all or part of the Operator’s Proposal, Aurizon Network may advise the Operator of the risks not adequately managed or not identified or adequately dealt with and then either Party may refer the issue of whether the Environmental Investigation and Risk Management Report and/or the Operator’s Proposal does or does not adequately manage or does or does not identify or adequately deal with the relevant environmental risks to an expert for determination in accordance with Clause 18.3.
(g) If the expert determines that the Environmental Investigation and Risk Management Report and/or Operator’s Proposal does adequately manage the risks or identifies and adequately deals with the risks, then the Environmental Investigation and Risk Management Report as modified by the Operator’s Proposal (if applicable) will, subject to Clause 9.1(k), be accepted and included in Part 1 of Schedule 9 and amendments made to this Agreement [(including variations to the Base Access Charges)] if applicable. [Bracketed text is only included where Operator pays non-TOP Access Charges]
(h) If the expert determines that the Environmental Investigation and Risk Management Report and/or Operator’s Proposal does not adequately manage the risks or does not identify and adequately deal with the risks, then provided the Operator amends the Environmental Investigation and Risk Management Report in accordance with the expert’s determination and/or recommendations within the time frame specified by the expert, the Environmental Investigation and Risk Management Report as amended will, subject to Clause 9.1(k), be accepted and included in Part 1 of Schedule 9 and amendments made to the Agreement [(including variations to the Base Access Charges)] if applicable. [Bracketed text is only included where Operator pays non-TOP Access Charges]
(i) If the expert determines that the Environmental Investigation and Risk Management Report and/or Operator’s Proposal does not adequately manage the risks or does not identify and adequately deal with the risks and the Operator fails to amend the Environmental Investigation and Risk Management Report in accordance with the expert’s determination and/or recommendations within the time frame specified by the expert, Aurizon Network may terminate this Agreement by written notice to the Operator and the End User.
(j) The Parties agree to implement the determination of the expert.
(k) If:
(i) an Environmental Investigation and Risk Management Report is included in Part 1 of Schedule 9; and
(ii) amendments (if any) are made to this Agreement as a result of or in connection with that inclusion of the Environmental Investigation and Risk Management Report, then the commencement of the amendment of this Agreement to include the Environmental Investigation and Risk Management Report and those amendments is subject to and conditional upon the Operator being notified by Aurizon Network that all necessary amendments (if any) to the End User Access Agreement (including variations to the amounts payable by the End User) have been made in respect of such matters and any relevant nomination of the Operator by the End User in accordance with the End User Access Agreement has, if necessary, been varied.
Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.
Electrical connections Equipment requiring electrical connections for operation shall either be hard wired to the Authorized User's provided connections or the Contractor shall be responsible for a male electrical union. All connections shall be made by the Contractor and accomplished in accordance with National Electrical Code requirements. Electrically operated equipment shall be available in the following volts and phases: 208 volt 1 or 3 phase, 60 HZ 220 volt 1 or 3 phase, 60 HZ 440 volt 1 or 3 phase, 60 HZ
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.
Emergency Situations If the condition is an emergency, this will be communicated to the Contractor with the request that corrections are to be accomplished immediately. The Contractor shall respond to the notice in emergency situations within twenty-four hours. If the Contractor fails to respond within this time limit, the Owner may correct the defect and charge the Contractor for the Work. If it is determined the complaint is not the responsibility of the Contractor, the Contractor shall be promptly paid for the cost of the corrective work. The Contractor shall give notice in writing to the Owner when corrections have been completed.
Eye Examinations All represented employees, who are health service system members, shall be eligible for one (1) annual VDT examination and prescribed eyewear.
Polygraph Examination No employee shall be compelled to submit to a polygraph examination. No disciplinary action whatsoever shall be taken against an employee refusing to submit to a polygraph examination; nor shall any comment be anywhere recorded indicating that an employee offered to take, took or refused to take a polygraph examination unless otherwise agreed to in writing by the parties; nor shall any testimony or evidence of any kind regarding an employee's offer to take, refusal to take, or the results of a polygraph examination be admissible in any proceeding pursuant to this Agreement, unless otherwise agreed to in writing by the parties.
