General and Administrative 4.1 This Agreement shall be governed in all respects and aspects by the laws of the State of Texas, and the parties hereby agree any legal action concerning this Agreement shall be brought in a court of competent jurisdiction, in Lubbock County, Texas. If counsel is required to enforce terms of this Agreement and/ or corollary agreements, the prevailing party shall be entitled to recover reasonable attorney fees and costs.
4.2 If any provision of this Agreement, or its application to any person or circumstance, is invalid or unenforceable, the remainder of this Agreement or the application of those provisions to other persons or circumstances shall not be affected thereby.
4.3 This Agreement and the attachments hereto, contain the entire Agreement of the parties and there are no representatives, inducements, promises, agreements, arrangements, or undertakings, oral or written, between parties other than those set forth and duly executed in writing. No agreement of any kind shall be binding upon either party unless and until the same has been made in writing and duly executed by both parties. The Agreement shall not be modified or amended except by written agreement executed by both parties.
4.4 The parties have reviewed this Agreement in its entirety and acknowledge each has had a full opportunity to negotiate the Agreements terms. Therefore, the parties expressly waive any and all applicable common law and statutory rules of construction any provision of this Agreement should be construed against the Agreement’s drafter, and agree and affirm the Agreement and all provisions thereof shall in all cases be construed as a whole, according to the fair meaning of the language utilized.
4.5 Failure to insist upon strict compliance with any of the terms, covenants, and conditions hereof shall not be deemed a waiver of such terms, covenants, and conditions, nor shall any waiver or relinquishment of any right or power here under at any one or more times be deemed a waiver or relinquishment of such right or power at any other time or times. No waiver shall be valid unless in writing and signed by all parties.
4.6 The captions of each section are added as a matter of convenience only and shall be considered of no effect in the construction of any provision of this Agreement.
4.7 This Agreement may be executed by facsimile or e-mail attachment and/ or in any number of counterparts, any or all of which may contain the signatures of less than all parties, and all of which shall be construed together as but a single instrument and shall be binding on the parties as though originally executed on one originally executed document. All facsimile and e-mail attachment counterparts shall be promptly followed with delivery of original executed counterparts.
4.8 This Agreement shall become effective upon execution of the Group Contract, Group Itinerary, and Group Package Options form by the parties involved.
Minor and Administrative Errors A Competent Authority shall notify the Competent Authority of the other Party when the first-mentioned Competent Authority has reason to believe that administrative errors or other minor errors may have led to incorrect or incomplete information reporting or resulted in other infringements of this Agreement. The Competent Authority of such other Party shall apply its domestic law (including applicable penalties) to obtain corrected and/or complete information or to resolve other infringements of this Agreement.
Indemnification Procedures If any third-‐party claim is commenced that is indemnified under Section 7.1 above, ICANN shall provide notice thereof to Registry Operator as promptly as practicable. Registry Operator shall be entitled, if it so elects, in a notice promptly delivered to ICANN, to immediately take control of the defense and investigation of such claim and to employ and engage attorneys reasonably acceptable to ICANN to handle and defend the same, at Registry Operator’s sole cost and expense, provided that in all events ICANN will be entitled to control at its sole cost and expense the litigation of issues concerning the validity or interpretation of ICANN’s policies, Bylaws or conduct. ICANN shall cooperate, at Registry Operator’s cost and expense, in all reasonable respects with Registry Operator and its attorneys in the investigation, trial, and defense of such claim and any appeal arising therefrom, and may, at its own cost and expense, participate, through its attorneys or otherwise, in such investigation, trial and defense of such claim and any appeal arising therefrom. No settlement of a claim that involves a remedy affecting ICANN other than the payment of money in an amount that is fully indemnified by Registry Operator will be entered into without the consent of ICANN. If Registry Operator does not assume full control over the defense of a claim subject to such defense in accordance with this Section 7.2, ICANN will have the right to defend the claim in such manner as it may deem appropriate, at the cost and expense of Registry Operator and Registry Operator shall cooperate in such defense. [Note: This Section 7.2 is inapplicable to intergovernmental organizations or governmental entities.]
GRIEVANCE AND ARBITRATION PROCEDURES A. A grievance is a dispute, claim, or complaint arising under this Agreement, filed by either an authorized representative of or an employee in the Bargaining Unit, or the County, involving the interpretation or application of this Agreement. All discipline shall be for just cause.
B. Grievances will be processed in the following manner and strictly in accordance with the following stated time limits:
Step 1. The aggrieved employee shall be accorded fifteen (15) working days from the occurrence of the action or event or when the employee has knowledge or should have had knowledge of the action or the event giving rise to the complaint to seek resolution on an informal basis. The Employee must discuss his alleged grievance with the Airport Fire Chief and the Fire Rescue Division Director. If informal resolution is not accomplished, the employee, if a Union member, must present the proposed grievance in writing to a Union officer on or before the fifteenth (15th) working day for consideration by the Union Grievance committee. If, in the Committee's opinion, no reasonable grievance exists, no further action may be taken.
Step 2. If the Committee wishes to pursue the member's complaint, a written grievance shall be presented to the Director of the Fire Rescue Division or his designee within twenty (20) working days from the occurrence of the action or event giving rise to the grievance or from the date on which the employee reasonably should have had knowledge of that occurrence. A written grievance must be presented on a grievance form provided by the County in Appendix A. Upon receipt of a formal grievance or a class action submitted by the Union, the Fire Rescue Division Director or his designee shall investigate the facts and conduct a meeting within five (5) working days with the aggrieved employee and any other persons possessing knowledge considered critical by the Director. The aggrieved employee may be accompanied at this meeting by a local Union representative. The Fire Rescue Division Director or his designee shall notify the grievant of his decision no later than five (5) working days following the date of the meeting.
Step 3. If the grievance is not resolved at the second step, the aggrieved employee shall present the written grievance within five (5) working days of the Step 2 decision to the Department Head. The Department Head or his designee shall investigate the facts and may conduct a hearing within five
Indemnification Process 20.2.1 As used in this Section 20, “Indemnified Person” means a person whom an Indemnifying Party is obligated to indemnify, defend and/or hold harmless under Section 20.1.
20.2.2 An Indemnifying Party’s obligations under Section 20.1 shall be conditioned upon the following:
Referral Procedures For Local Unions now having a job referral system as contained in their Collective Bargaining Agreement, the Contractor agrees to utilize such system and it shall be used exclusively by such Contractor, except as it may be modified by this Article. Referrals shall not be affected by obligations of Union membership or the lack thereof. Where airport security clearance requirements apply to work to be performed, the Contractor shall inform the Union’s hiring hall dispatcher of those requirements when requesting workers. For those Local Unions having a Book system as part of their Collective Bargaining Agreement, such system will be honored in regards to lay-off of workers from covered projects.
Section 2. In the event that Local Unions are unable to fill any request for employees within the time specified by the local CBAs the Contractor may employ applicants from any other available source. The Contractor shall inform the Union of the name and social security number of any applicants hired from other sources and shall refer the applicant to the Local Union for dispatch to the Covered Project prior to the commencement of work, and make trust fund contributions for every hour worked.
Section 3. There shall be no discrimination against any employee or applicant for employment because of his/her membership or non-membership in the Union or based upon race, creed, color, sex, age or national origin, or any other legally protected class of such employee or applicant.
Section 4. No employee covered by this PLA shall be required to join any Union as a condition of being employed on the Covered Project; provided, however, that an employee who is a member of the referring Union at the time of the referral shall maintain that membership while employed under the PLA. All employees shall, however, be required to comply with the union security provision of the applicable Collective Bargaining Agreement, for the period during which they are performing on-site work, except as modified by this PLA. The Contractor agrees to deduct union dues or representation fees, whichever is applicable, from the pay of any employee who executes a voluntary authorization for such deductions and to remit the dues to the Union or Council. Initiation fees shall be waived for those employees who are not members of any signatory Union when they begin work on this Covered Project. The dues obligations of such employees shall be confined to that portion of union membership dues directly related to representation of workers in collective bargaining, and in enforcement of the Unions’ collective bargaining agreements. Nothing in this Section is intended to eliminate or affect the right of any employee to join the Union or the right of any union to collect full dues from its member.
Section 5. The Parties agree that where a Contractor is not party to a current Collective Bargaining Agreement with the Union having jurisdiction over the affected work, the Contractor may request by name, and the Local will honor, referral of up to a maximum of five (5) persons per each contractor (“core” employees), provided that the Contractor first demonstrate that those persons possess the following qualifications:
(1) Any license required by state or federal law for the Project work to be performed;
(2) Have worked a total of at least one thousand two hundred (1,200) hours in the construction craft during the prior two (2) years;
(3) Were on the Contractor’s active payroll for at least sixty (60) out of the ninety (90) calendar days prior to the contract award;
(4) Have the ability to perform the work safely. The Contractor may elect to hire its first “core” employee to be a xxxxxxx. After the Contractor hires his first core employee, the Union will refer to such Contractor one journeyman employee from the hiring hall out-of-work list for the affected trade or craft, then refer one of such Contractor’s “core” employees as a journeyman, and shall alternate one core employee and one employee from the out-of-work list, until such Contractor’s crew requirements are met or until such Contractor has hired five (5) “core” employees, whichever occurs first. Thereafter, all additional employees in the affected trade or craft shall be hired exclusively from the hiring hall out-of-work list(s). For the duration of the Contractor’s work the ratio of “core” employees to hiring hall referrals shall be maintained and when the Contractor’s workforce is reduced, employees shall be reduced in the same ratio as was applied in the initial hiring. All employees, core and union, shall be dispatched from the appropriate union. Trust benefits shall be paid on all employees, core and union.
Section 6. Upon referral or dispatch from a Union, “turnaround” or refusal of any worker by the Contractors, requires written explanation from the Contractor that shall be communicated through the Prime Contractor to the Port and affected Union within 48 hours.
Section 7. Individual seniority will not be recognized or applied to employees working on the Project. This provision will not interfere with or supersede the use by individual Contractors of “call lists” maintained by such Contractor pursuant to addenda to the local Collective Bargaining Agreement between such Contractor and a Union signatory to this PLA.
Section 8. The selection of craft foremen and/or general foremen and the number of such foremen and/or general foremen required shall be entirely the responsibility of the Contractor. Craft foremen shall be designated working foremen at the request of the Contractor. Craft workers covered by this PLA will, in the normal day- to-day operations, take their direction and supervision from their xxxxxxx.
Dispute Resolution Procedures (a) In the event a dispute arises about the interpretation, application, calculation of Loss, or calculation of payments or otherwise with respect to this Single Family Shared-Loss Agreement (“SF Shared-Loss Dispute Item”), then the Receiver and the Assuming Institution shall make every attempt in good faith to resolve such items within sixty (60) days following the receipt of a written description of the SF Shared-Loss Dispute Item, with notification of the possibility of taking the matter to arbitration (the date on which such 60-day period expires, or any extension of such period as the parties hereto may mutually agree to in writing, herein called the “Resolution Deadline Date”). If the Receiver and the Assuming Institution resolve all such items to their mutual satisfaction by the Resolution Deadline Date, then within thirty (30) days following such resolution, any payment due as a result of such resolution shall be made arising from the settlement of the SF Shared-Loss Dispute.
(b) If the Receiver and the Assuming Institution fail to resolve any outstanding SF Shared-Loss Dispute Items by the Resolution Deadline Date, then either party may notify the other of its intent to submit the SF Shared-Loss Dispute Item to arbitration pursuant to the provisions of this Article VII. Failure of either party to submit pursuant to paragraph (c) hereof any unresolved SF Shared-Loss Dispute Item to arbitration within thirty (30) days following the Resolution Deadline Date (the date on which such thirty (30) day period expires is herein called the “Arbitration Deadline Date”) shall extinguish that party’s right to submit the non-submitted SF Shared-Loss Dispute Item to arbitration, and constitute a waiver of the submitting party’s right to dispute such non-submitted SF Shared-Loss Dispute Item (but not a waiver of any similar claim which may arise in the future).
(c) If a SF Shared-Loss Dispute Item is submitted to arbitration, it shall be governed by the rules of the American Arbitration Association (the “AAA”), except as otherwise provided herein. Either party may submit a matter for arbitration by delivering a notice, prior to the Arbitration Deadline Date, to the other party in writing setting forth:
(i) A brief description of each SF Shared-Loss Dispute Item submitted for arbitration;
(ii) A statement of the moving party’s position with respect to each SF Shared-Loss Dispute Item submitted for arbitration;
(iii) The value sought by the moving party, or other relief requested regarding each SF Shared-Loss Dispute Item submitted for arbitration, to the extent reasonably calculable; and
(iv) The name and address of the arbiter selected by the moving party (the “Moving Arbiter”), who shall be a neutral, as determined by the AAA. Failure to adequately include any information above shall not be deemed to be a waiver of the parties right to arbitrate so long as after notification of such failure the moving party cures such failure as promptly as reasonably practicable.
(d) The non-moving party shall, within thirty (30) days following receipt of a notice of arbitration pursuant to this Section 7.1, deliver a notice to the moving party setting forth:
(i) The name and address of the arbiter selected by the non-moving party (the “Respondent Arbiter”), who shall be a neutral, as determined by the AAA;
(ii) A statement of the position of the respondent with respect to each Dispute Item; and
(iii) The ultimate resolution sought by the respondent or other relief, if any, the respondent deems is due the moving party with respect to each SF Shared-Loss Dispute Item. Failure to adequately include any information above shall not be deemed to be a waiver of the non-moving party’s right to defend such arbitration so long as after notification of such failure the non-moving party cures such failure as promptly as reasonably practicable
(e) The Moving Arbiter and Respondent Arbiter shall select a third arbiter from a list furnished by the AAA. In accordance with the rules of the AAA, the three (3) arbiters shall constitute the arbitration panel for resolution of each SF Loss-Share Dispute Item. The concurrence of any two (2) arbiters shall be deemed to be the decision of the arbiters for all purposes hereunder. The arbitration shall proceed on such time schedule and in accordance with the Rules of Commercial Arbitration of the AAA then in effect, as modified by this Section 7.1. The arbitration proceedings shall take place at such location as the parties thereto may mutually agree, but if they cannot agree, then they will take place at the offices of the Corporation in Washington, DC, or Arlington, Virginia.
(f) The Receiver and Assuming Institution shall facilitate the resolution of each outstanding SF Shared-Loss Dispute Item by making available in a prompt and timely manner to one another and to the arbiters for examination and copying, as appropriate, all documents, books, and records under their respective control and that would be discoverable under the Federal Rules of Civil Procedure.
Procedures and Presumptions for Determination of Entitlement to Indemnification It is the intent of this Agreement to secure for Indemnitee rights of indemnity that are as favorable as may be permitted under the DGCL and public policy of the State of Delaware. Accordingly, the parties agree that the following procedures and presumptions shall apply in the event of any question as to whether Indemnitee is entitled to indemnification under this Agreement:
a. To obtain indemnification under this Agreement, Indemnitee shall submit to the Company a written request, including therein or therewith such documentation and information as is reasonably available to Indemnitee and is reasonably necessary to determine whether and to what extent Indemnitee is entitled to indemnification. The Secretary of the Company shall, promptly upon receipt of such a request for indemnification, advise the Board in writing that Indemnitee has requested indemnification. Notwithstanding the foregoing, any failure of Indemnitee to provide such a request to the Company, or to provide such a request in a timely fashion, shall not relieve the Company of any liability that it may have to Indemnitee unless, and to the extent that, such failure actually and materially prejudices the interests of the Company.
b. Upon written request by Indemnitee for indemnification pursuant to the first sentence of Section 6(a) hereof, a determination with respect to Indemnitee’s entitlement thereto shall be made in the specific case by one of the following four methods, which shall be at the election of the Board (1) by a majority vote of the disinterested directors, even though less than a quorum, (2) by a committee of disinterested directors designated by a majority vote of the disinterested directors, even though less than a quorum, (3) if there are no disinterested directors or if the disinterested directors so direct, by independent legal counsel in a written opinion to the Board, a copy of which shall be delivered to the Indemnitee, or (4) if so directed by the Board, by the stockholders of the Company. For purposes hereof, disinterested directors are those members of the Board who are not parties to the action, suit or proceeding in respect of which indemnification is sought by Indemnitee.
c. If the determination of entitlement to indemnification is to be made by Independent Counsel pursuant to Section 6(b) hereof, the Independent Counsel shall be selected as provided in this Section 6(c). The Independent Counsel shall be selected by the Board. Indemnitee may, within ten (10) days after such written notice of selection shall have been given, deliver to the Company a written objection to such selection; provided, however, that such objection may be asserted only on the ground that the Independent Counsel so selected does not meet the requirements of “Independent Counsel” as defined in Section 13 of this Agreement, and the objection shall set forth with particularity the factual basis of such assertion. Absent a proper and timely objection, the person so selected shall act as Independent Counsel. If a written objection is made and substantiated, the Independent Counsel selected may not serve as Independent Counsel unless and until such objection is withdrawn or a court has determined that such objection is without merit. If, within twenty (20) days after submission by Indemnitee of a written request for indemnification pursuant to Section 6(a) hereof, no Independent Counsel shall have been selected and not objected to, either the Company or Indemnitee may petition the Court of Chancery of the State of Delaware or other court of competent jurisdiction for resolution of any objection which shall have been made by the Indemnitee to the Company’s selection of Independent Counsel and/or for the appointment as Independent Counsel of a person selected by the court or by such other person as the court shall designate, and the person with respect to whom all objections are so resolved or the person so appointed shall act as Independent Counsel under Section 6(b) hereof. The Company shall pay any and all reasonable fees and expenses of Independent Counsel incurred by such Independent Counsel in connection with acting pursuant to Section 6(b) hereof, and the Company shall pay all reasonable fees and expenses incident to the procedures of this Section 6(c), regardless of the manner in which such Independent Counsel was selected or appointed.
d. In making a determination with respect to entitlement to indemnification hereunder, the person or persons or entity making such determination shall presume that Indemnitee is entitled to indemnification under this Agreement. Anyone seeking to overcome this presumption shall have the burden of proof and the burden of persuasion by clear and convincing evidence. Neither the failure of the Company (including by its directors or independent legal counsel) to have made a determination prior to the commencement of any action pursuant to this Agreement that indemnification is proper in the circumstances because Indemnitee has met the applicable standard of conduct, nor an actual determination by the Company (including by its directors or independent legal counsel) that Indemnitee has not met such applicable standard of conduct, shall be a defense to the action or create a presumption that Indemnitee has not met the applicable standard of conduct.
e. Indemnitee shall be deemed to have acted in good faith if Indemnitee’s action is based on the records or books of account of the Enterprise (as hereinafter defined), including financial statements, or on information supplied to Indemnitee by the officers of the Enterprise in the course of their duties, or on the advice of legal counsel for the Enterprise or on information or records given or reports made to the Enterprise by an independent certified public accountant or by an appraiser or other expert selected with reasonable care by the Enterprise. In addition, the knowledge and/or actions, or failure to act, of any director, officer, agent or employee of the Enterprise shall not be imputed to Indemnitee for purposes of determining the right to indemnification under this Agreement. Whether or not the foregoing provisions of this Section 6(e) are satisfied, it shall in any event be presumed that Indemnitee has at all times acted in good faith and in a manner he reasonably believed to be in or not opposed to the best interests of the Company. Anyone seeking to overcome this presumption shall have the burden of proof and the burden of persuasion by clear and convincing evidence.
f. If the person, persons or entity empowered or selected under Section 6 to determine whether Indemnitee is entitled to indemnification shall not have made a determination within sixty (60) days after receipt by the Company of the request therefor, the requisite determination of entitlement to indemnification shall be deemed to have been made and Indemnitee shall be entitled to such indemnification absent (i) a misstatement by Indemnitee of a material fact, or an omission of a material fact necessary to make Indemnitee’s statement not materially misleading, in connection with the request for indemnification, or (ii) a prohibition of such indemnification under applicable law; provided, however, that such sixty (60) day period may be extended for a reasonable time, not to exceed an additional thirty (30) days, if the person, persons or entity making such determination with respect to entitlement to indemnification in good faith requires such additional time to obtain or evaluate documentation and/or information relating thereto.
g. Indemnitee shall cooperate with the person, persons or entity making such determination with respect to Indemnitee’s entitlement to indemnification, including providing to such person, persons or entity upon reasonable advance request any documentation or information which is not privileged or otherwise protected from disclosure and which is reasonably available to Indemnitee and reasonably necessary to such determination. Any Independent Counsel, member of the Board or stockholder of the Company shall act reasonably and in good faith in making a determination regarding the Indemnitee’s entitlement to indemnification under this Agreement. Any costs or expenses (including attorneys’ fees and disbursements) incurred by Indemnitee in so cooperating with the person, persons or entity making such determination shall be borne by the Company (irrespective of the determination as to Indemnitee’s entitlement to indemnification) and the Company hereby indemnifies and agrees to hold Indemnitee harmless therefrom.
h. The Company acknowledges that a settlement or other disposition short of final judgment may be successful if it permits a party to avoid expense, delay, distraction, disruption and uncertainty. In the event that any action, claim or proceeding to which Indemnitee is a party is resolved in any manner other than by adverse judgment against Indemnitee (including, without limitation, settlement of such action, claim or proceeding with or without payment of money or other consideration) it shall be presumed that Indemnitee has been successful on the merits or otherwise in such action, suit or proceeding. Anyone seeking to overcome this presumption shall have the burden of proof and the burden of persuasion by clear and convincing evidence.
i. The termination of any Proceeding or of any claim, issue or matter therein, by judgment, order, settlement or conviction, or upon a plea of nolo contendere or its equivalent, shall not (except as otherwise expressly provided in this Agreement) of itself adversely affect the right of Indemnitee to indemnification or create a presumption that Indemnitee did not act in good faith and in a manner which he reasonably believed to be in or not opposed to the best interests of the Company or, with respect to any criminal Proceeding, that Indemnitee had reasonable cause to believe that his conduct was unlawful.
Arbitration Procedures In the event that the teacher and the School Board are unable to resolve any grievance, the grievance may be submitted to arbitration as defined herein:
1. Request: A request to submit a grievance to arbitration must be in writing signed by the aggrieved party, and such request must be filed in the office of the superintendent within ten (10) days following the decision in Level III of the grievance procedure.
Dispute Resolution and Applicable Law 1. The Parties shall first attempt to settle amicably any dispute arising out of this Agreement. Any dispute shall be resolved by arbitration, ousting jurisdiction by ordinary courts, by a panel of three arbitrators. Each party to the dispute will nominate one arbitrator. These two arbitrators will then designate a third arbitrator who will also act as chairman. The arbitration decision shall be binding on the parties. The arbitration rules of the CEPANI shall be applicable. The place of any hearing shall be Brussels and the language of the arbitration shall be English. Each Party may at any time request from any competent judicial authority any interim or conservatory measure.
2. This Agreement shall be governed by the laws of Belgium.
