Construction Document Phase 1.4.1 Based on the approved Design Development Documents, Guaranteed Maximum Price, coordinated models and any further adjustments in the scope or quality of the Project or in the Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Construction Documents consisting of Drawings, Schedules and Specifications derived from the model(s) in accordance with Owner’s written requirements setting forth in detail the requirements for construction of the Project, including, without limitation, the BIM Execution Plan and “Facility Design Guidelines”. The Plans, Drawings and Specifications for the entire Project shall be so prepared that same will call for the construction of the building and related facilities, together with its built-in permanent fixtures and equipment which will cost not more than the Guaranteed Maximum Price accepted by Owner, or the Amount Available for the Construction Contract established by Owner if no Guaranteed Maximum Price proposal has been accepted by Owner. The Architect/Engineer will be responsible for managing the design to stay within such Guaranteed Maximum Price proposal or Amount Available for the Construction Contract. The Architect/Engineer shall review the Construction Documents as they are being prepared at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Construction Documents. The Architect/Engineer shall provide the Construction Manager with a compact disc containing documents and data files derived from the model to assist the Construction Manager in fulfilling its responsibilities to the Owner.
Construction Documents Phase 2.2.1.5. Bidding or Negotiation Phase: 2.2.1.6. Construction Administration Phase
Construction Documents Phase Services 3.4.1 Based on the Owner’s approval of the Design Development Documents, and on the Owner’s authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Construction Documents for the Owner’s approval. The Construction Documents shall illustrate and describe the further development of the approved Design Development Documents and shall consist of Drawings and Specifications setting forth in detail the quality levels and performance criteria of materials and systems and other requirements for the construction of the Work. The Owner and Architect acknowledge that, in order to perform the Work, the Contractor will provide additional information, including Shop Drawings, Product Data, Samples and other similar submittals, which the Architect shall review in accordance with Section 3.6.4.
Agreement Documents 1. This Agreement consists of the following documents:
Contractor’s Completion Documents Receive from Contractor, review, and transmit to Owner maintenance and operating instructions, schedules, guarantees, bonds, certificates or other evidence of insurance required by the Construction Contract Documents, certificates of inspection, tests and approvals, and Shop Drawings, Samples, and other data. Receive from Contractor, review, and transmit to Owner the annotated record documents which are to be assembled by Contractor in accordance with the Construction Contract Documents to obtain final payment. The extent of Engineer’s review of record documents shall be to check that Contractor has submitted all pages.
Procurement Documents Agency specific documents for acquisition of goods or services that include financial obligation. Protecting Agency: Agency responsible for providing direct incident management within a specific geographical area pursuant to its jurisdictional responsibility or as specified and provided by contract, cooperative agreement, etc. Protection: The actions taken to mitigate the adverse effects of fire on environmental, social, political, economic, and community values at risk. Protection Area: That area for which a particular fire protection organization has the primary responsibility for attacking an uncontrolled fire and for directing the suppression actions.
Design Development Documents See Section 2, Part 1, Article 2.1.5.
FAILURE TO HONOUR SETTLEMENT AGREEMENT 32. If this Settlement Agreement is accepted by the Hearing Panel and, at any subsequent time, the Respondent fails to honour any of the Terms of Settlement set out herein, Staff reserves the right to bring proceedings under section 24.3 of the By-laws of the MFDA against the Respondent based on, but not limited to, the facts set out in Part IV of the Settlement Agreement, as well as the breach of the Settlement Agreement. If such additional enforcement action is taken, the Respondent agrees that the proceeding(s) may be heard and determined by a hearing panel comprised of all or some of the same members of the hearing panel that accepted the Settlement Agreement, if available.
Notice to Proceed Work shall not commence on this Project until the Director has issued a written Notice to Proceed to the Recipient. Such Notice will not be issued until the Director is assured that the Recipient has complied with the Recipient's responsibilities concerning OEPA plan approval, when applicable. A Notice to Proceed shall be required for all project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Construction Documents The architectural and engineering documents setting forth the design for the Project prepared by the Design Professional. Construction Documents include, but are not limited to, the Specifications, the Drawings, the Supplementary Conditions, the General Conditions, and all Addenda.
