Calculation of Time Period When calculating the period of time before which, within which or following which any act is to be done or step taken pursuant to this Agreement, the date that is the reference date in calculating such period shall be excluded. If the last day of such period is a non-Business Day, the period in question shall end on the next succeeding Business Day.
Calculation of Time Periods Except as otherwise indicated, all periods of time referred to herein shall include all Saturdays, Sundays and holidays; provided, however, that if the date to perform the act or give any notice with respect to this Agreement shall fall on a day other than a Business Day, such act or notice may be timely performed or given if performed or given on the next succeeding Business Day.
Part-Time Nurse is a Nurse hired to a position to work on a regular or temporary basis that is less than the work period of a Full-Time Nurse.
Criminal Records Check Except as provided by Governor’s executive order or state or federal law as implemented by Agency rule or policy, the Employer will not require a criminal records check on any current employee in his or her current position if the requirement was not in place when the employee was appointed to the position. Agencies will send Agency rules, policies, and subsequent changes to SEIU Headquarters. Upon notification, the Union may exercise its rights pursuant to Article 5 of this agreement as it applies to changes in Agency rule or policy implementing Governor’s executive orders or state or federal laws regarding criminal records check requirements.
Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.
Amending of Time Limits The time limits fixed in both the grievance and arbitration procedure may be extended by consent of the parties.
Part-time Scheduling Subject to Section B of this Article, the Employer and the Association endorse the principle that less than full time equivalent ("FTE") positions shall, within reason, be expected to work a biweekly work period that equates to an eighty (80) hour work period multiplied by the position's FTE. (e.g., 80 hours @ .75 = 60 hours). It is further understood by both parties that ASF Members assigned to less than a FTE position may be required, during the peak work periods, to exceed their normal biweekly work period. FLSA non-exempt ASF Members who work a part-time schedule will earn overtime for hours worked in excess of forty (40) in a work week. The Employer agrees to review any ASF position that is less than one (1) FTE if the Association can demonstrate that the position has regularly been required to work a work period that substantially exceeds the normal work period as defined above, and adjust the FTE of the respective position as deemed appropriate by the Employer.
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof
CONTRACT WORK HOURS AND SAFETY STANDARDS As per the Contract Work Hours and Safety Standards Act (40 U.S.C. 3701-3708), where applicable, all Customer Purchase Orders in excess of ,000 that involve the employment of mechanics or laborers must include a provision for compliance with 40 U.S.C. 3702 and 3704, as supplemented by Department of Labor regulations (29 CFR Part 5). Under 40 U.S.C. 3702 of the Act, each contractor must be required to compute the wages of every mechanic and laborer on the basis of a standard work week of 40 hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of 40 hours in the work week. The requirements of 40 U.S.C. 3704 are applicable to construction work and provide that no laborer or mechanic must be required to work in surroundings or under working conditions which are unsanitary, hazardous or dangerous. These requirements do not apply to the purchases of supplies or materials or articles ordinarily available on the open market, or contracts for transportation or transmission of intelligence.
CONTRACTOR INVOICE Contractor shall submit to Purchaser’s designated invoicing contact properly itemized invoices. Such invoices shall itemize the following: (a) Master Contract No. 02120 (b) Contractor name, address, telephone number, and email address for billing issues (i.e., Contractor Customer Service Representative) (c) Contractor’s Federal Tax Identification Number (d) Date(s) of delivery (e) Invoice amount; and (f) Payment terms, including any available prompt payment discounts. Contractor’s invoices for payment shall reflect accurate Master Contract prices. Invoices will not be processed for payment until receipt of a complete invoice as specified herein.
