Requests for Final Construction Advance Sample Clauses

Requests for Final Construction Advance. As a condition precedent to the final Acquisition/Construction Advance, in addition to all other conditions precedent in this 49 Agreement, Completion of the Improvements shall have occurred and Borrower must deliver the following items to Lender: (i) A certificate of completion from the Inspecting Architects/ Engineers, Contractor, and Borrower, in form and substance acceptable the TFC, that Completion of all Improvements has occurred. (ii) Evidence that all Governmental Requirements have been satisfied, including but not limited to, delivery to TFC of (i) a permanent certificate of occupancy or its equivalent, if local Governmental Authorities issue such document, permitting the Improvements to be legally occupied, and (ii) evidence that all Improvements are in compliance with the accessibility requirements of the federal Fair Housing Act, the federal Americans with Disabilities Act, and the state Americans with Disabilities Act in effect in the state in which the Marathon Key Resort is located. (iii) Evidence in the form of an affidavit that no mechanic's or materialman's lien or other encumbrance has been filed and remains in effect against the Marathon Key Resort. (iv) Final lien waivers and releases by the Architect, Contractor, and all subcontractors, materialmen, and other Persons who have supplied labor, materials, or services for the construction of the Improvements, or who otherwise might be entitled to claim a contractual, statutory, or constitutional lien against the Marathon Key Resort. (v) Endorsement and extension of the Title Policy to acknowledge completion of the construction of the Improvements without any encroachment and compliance with all applicable matters of public record and Governmental Requirements, with no exceptions other than the Permitted Exceptions. (vi) Three (3) copies of an "as-built" survey of the Marathon Key Resort prepared by a surveyor licensed in Florida satisfactory to Lender and the Title Company in accordance with the Plans. The "as-built' survey shall show all of the Units and other Improvements in place, including, without limitation, striping of parking areas, the location of building and setback lines and the distance of the Improvements from the building and setback lines; and shall contain a statement as to the number of parking spaces, square footage and height of the Improvements and such other matters as TFC shall require. The survey shall be prepared in accordance with the standards set forth by ALTA/...
Sample 1
AutoNDA by SimpleDocs

Related to Requests for Final Construction Advance

  • Advance Requests Borrower may request that Lender make an Advance by delivering to Lender an Advance Request therefor and Lender shall be entitled to rely on all the information provided by Borrower to Lender on or with the Advance Request. The Lender may honor Advance Requests, instructions or repayments given by the Borrower (if an individual) or by any Authorized Person.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Draw Request At such time as the Borrower shall desire to obtain, subject to the other requirements hereof, a disbursement of any portion of the proceeds of the Loan, the Borrower shall complete, execute and deliver to the City a properly completed draw request in a form designated by the City, together with the General Contractor's Payment Request which shall have been approved by the City's Inspector and by such other documents as the City may request ("Draw Request"), all in such form as the City may require from time to time. No failure or delay on the part of the City to require any such documents or information shall operate in any way so as to waive the City's rights to require all such documents and information at a later time. Draw requests will occur no more often than monthly, only with proper certification of completion from the Architect, and with the xxxxx 0% retainage being paid only after receipt of a Certificate of Occupancy and Release of Liens. All draw disbursements shall be made in accordance with the Escrow and Disbursing Agreement.

  • PRE-CONSTRUCTION PHASE FEE The Pre-Construction Phase Fee is the total compensation payable to Contractor for the performance of Pre-Construction Phase Services, except for Additional Pre-Construction Phase Services approved in advance and in writing by Owner. The Pre-Construction Phase Fee shall be a lump sum amount based on the AACC established in this Agreement. 6.1 Except as specifically allowed by Owner, Contractor shall not be entitled to any increase in the Pre-Construction Phase Fee for any costs, expenses, liabilities or other obligations arising from the performance of Pre-Construction Phase Services. 6.2 Costs associated with the following items are specifically, but not exclusively, included in the establishment of the Pre-Construction Phase Fee: profit and profit sharing; general overhead; salaries and labor; housing and relocation; estimating, scheduling and information management systems and software; contract administration; office expenses; printing and copying; consulting fees; legal or accounting fees; cost of money; taxes; insurance premiums and deductibles; bond costs; purchase or rental of equipment; utilities; travel; per diem; fines or penalties; and damage awards. 6.3 If the scope of the Pre-Construction Phase Services is changed materially, the Pre- Construction Phase Fee shall be equitably adjusted. If the AACC is changed materially before acceptance of the GMP Proposal, the Pre-Construction Phase Fee shall be adjusted in writing in proportion to the change in the AACC. There shall be no adjustments in the Pre-Construction Phase Fee following acceptance of the GMP Proposal. 6.4 For Additional Pre-Construction Phase Services that are approved in advance and in writing by Owner, Contractor shall be entitled to additional compensation computed as follows: 6.4.1 A pre-established lump sum amount; or 6.4.2 The hourly cost of Contractor’s employees or consultants who actually perform the Additional Services based on the employee’s Worker Wage Rate or prorated Monthly Rate plus the actual cost of allowable expenses incurred in the performance of the Additional Pre-Construction Phase Services, plus an overhead and profit markup of ten percent (10%) of the total cost; or 6.4.3 As otherwise agreed in advance and in writing.

  • Work in Advance of Shift When a nurse at the request of the Employer, reports for work in advance of the assigned shift, all hours worked prior to the scheduled shift shall be paid at one and one-half times (1 ½ X) the nurse's regular rate.

  • No Construction Loans No Mortgage Loan was made in connection with (i) the construction or rehabilitation of a Mortgage Property or (ii) facilitating the trade-in or exchange of a Mortgaged Property other than a construction-to-permanent loan which has converted to a permanent Mortgage Loan;

  • Determination to Honor Drawing Request In determining whether to honor any request for drawing under any Letter of Credit by the beneficiary thereof, Agent shall be responsible only to determine that the documents and certificates required to be delivered under such Letter of Credit have been delivered and that they comply on their face with the requirements of such Letter of Credit and that any other drawing condition appearing on the face of such Letter of Credit has been satisfied in the manner so set forth.

  • Disbursement of Advance Proceeds All Advances shall be disbursed from whichever office or other place Agent may designate from time to time and, together with any and all other Obligations of Borrowers to Agent or Lenders, shall be charged to Borrowers' Account on Agent's books. During the Term, Borrowers may use the Revolving Advances by borrowing, prepaying and reborrowing, all in accordance with the terms and conditions hereof. The proceeds of each Revolving Advance requested by Borrowers or deemed to have been requested by Borrowers under Section 2.2(a) hereof shall, with respect to requested Revolving Advances to the extent Lenders make such Revolving Advances, be made available to the applicable Borrower on the day so requested by way of credit to such Borrower's operating account at PNC, or such other bank as Borrowing Agent may designate following notification to Agent, in immediately available federal funds or other immediately available funds or, with respect to Revolving Advances deemed to have been requested by any Borrower, be disbursed to Agent to be applied to the outstanding Obligations giving rise to such deemed request.

  • Construction Administration Phase Delete the following paragraph if Submittal Exchange isn’t going to be used: 2.

  • Advance Request To obtain a Term Loan Advance, Borrower shall complete, sign and deliver an Advance Request (at least one (1) Business Day before the Closing Date and at least five (5) Business Days before each Advance Date other than the Closing Date) to Agent. The Lenders shall fund the Term Loan Advance in the manner requested by the Advance Request provided that each of the conditions precedent to such Term Loan Advance is satisfied as of the requested Advance Date.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!