Rescheduling Lonza shall have the right to reschedule a Commencement Date of any Batch or Campaign upon reasonable prior written notice to Customer, provided that the rescheduled Commencement Date is no earlier or no later than [***] from the Commencement Date originally estimated at the time of Lonza’s acceptance of the binding purchase order, and further provided that Customer is able to provide the necessary Customer Materials. If the Customer requests to change the Commencement Date, Lonza will make all reasonable attempts to accommodate the request; provided, however, in the event that this change would impact other projects scheduled for occupancy in the designated suite or suites, manufacture of the Customer’s Batch or Campaign may be delayed until an adequate time period is available in the Facility schedule. Any such change requested by Customer may result in a rescheduling fee. Any delay requested by Customer of more than [***] shall be considered a cancellation pursuant to Section 6.5.
Condition of Aircraft The Aircraft at the time of its return to Lessor shall have been maintained and repaired in accordance with the Approved Maintenance Program and this Lease with the same care and consideration for the technical condition of the Aircraft as if it were to have been kept in continued regular service by the Lessee, and shall meet the following requirements:
Aircraft The Airframe to be sold by AVSA to the Owner Trustee as provided in the Participation Agreement and to be leased under the Lease (or any permitted substitute airframe thereunder) together with two Engines (whether either is an initial Engine or a Replacement Engine) whether or not any of such initial or Replacement Engines may from time to time be installed on such Airframe or may be installed on any other airframe or on any other aircraft, including any aircraft substituted pursuant to Section 11.03
Maintenance of Aircraft Lessor shall be solely responsible for securing maintenance, preventive maintenance and inspections of the Aircraft (utilizing an inspection program listed in FAR Section 91.409(f)), and shall take such requirements into account in scheduling the Aircraft hereunder.
Scheduling (a) Lessee will provide Lessor with requests for flight time and proposed flight schedules as far in advance of any given flight as possible. Lessee or the designated authorized representative(s) of Lessee shall submit scheduling requests under this Agreement to the designated authorized representative(s) of Lessor. Requests for flight time shall be in such form (whether oral or written) mutually convenient to, and agreed upon by, the parties. In addition to proposed schedules and flight times, Lessee shall upon request provide Lessor with the following information for each proposed flight prior to scheduled departure: (i) proposed departure point; (ii) destination; (iii) date and time of flight; (iv) the number of anticipated passengers; (v) the nature and extent of luggage to be carried; (vi) the date and time of a return flight, if any; and (vii) any other pertinent information concerning the proposed flight that Lessor or the flight crew may request.
Return of Aircraft 64 23.1 Date of Return................................................64 23.2
Lease of Aircraft Lessor agrees to lease the Aircraft to Lessee pursuant to the provisions of FAR Section 91.501(b)(6) and Section 91.501(c)(1) and this Agreement, and to provide a fully-qualified and credentialed flight crew for all flights to be conducted hereunder during the Term (as defined in Section 13) hereof. The parties acknowledge and agree that this Agreement did not result in any way from any direct or indirect advertising, holding out or soliciting on the part of Lessor or any person purportedly acting on behalf of Lessor. Lessor and Lessee intend that the lease of the Aircraft effected by this Agreement shall be treated as a “wet lease” pursuant to which Lessor provides transportation services to Lessee in accordance with FAR Section 91.501(b)(6) and Section 91.501(c)(1).
Return of Aircraft, Etc (a) If an Event of Default shall have occurred and be continuing and the Equipment Notes have been accelerated, subject to Section 4.03 hereof and unless the Owner Trustee or the Owner Participant shall have elected to purchase the Equipment Notes, at the request of the Mortgagee, the Owner Trustee shall promptly execute and deliver to the Mortgagee such instruments of title and other documents as the Mortgagee may deem necessary or advisable to enable the Mortgagee or an agent or representative designated by the Mortgagee, at such time or times and place or places as the Mortgagee may specify, to obtain possession of all or any part of the Mortgaged Property included in the Trust Indenture Estate to which the Mortgagee shall at the time be entitled hereunder. If the Owner Trustee shall for any reason fail to execute and deliver such instruments and documents after such request by the Mortgagee, the Mortgagee may (i) obtain a judgment conferring on the Mortgagee the right to immediate possession and requiring the Owner Trustee to execute and deliver such instruments and documents to the Mortgagee, to the entry of which judgment the Owner Trustee hereby specifically consents to the fullest extent permitted by Law, and (ii) pursue all or part of such Mortgaged Property wherever it may be found and, in the event that a Lease Event of Default has occurred and is continuing, may enter any of the premises of Lessee wherever such Mortgaged Property may be or be supposed to be and search for such Mortgaged Property and take possession of and remove such Mortgaged Property. All expenses of obtaining such judgment or of pursuing, searching for and taking such property shall, until paid, be secured by the Lien of this Trust Indenture.
Aircraft Maintenance Operator shall, at its own expense, cause the Aircraft to be inspected, maintained, serviced, repaired, overhauled, and tested in accordance with FAR Part 91 so that the Aircraft will remain in good operating condition and in a condition consistent with its airworthiness certification and shall take such requirements into account in scheduling the Aircraft hereunder, including but not limited compliance with applicable airworthiness directives and service bulletins. Performance of maintenance, preventive maintenance or inspection shall not be delayed or postponed for the purpose of scheduling the Aircraft unless such maintenance or inspection can safely be conducted at a later time in compliance with applicable laws, regulations and requirements, and such delay or postponement is consistent with the sound discretion of the pilot-in-command. In the event that any non-standard maintenance is required during the term and will interfere with User’s requested or scheduled flights, Operator, or Operator’s pilot-in-command, shall notify User of the maintenance required, the effect on the ability to comply with User’s requested or scheduled flights and the manner in which the parties will proceed with the performance of such maintenance and conduct of such flight(s). In no event shall Operator be liable to User or any other person for loss, injury or damage occasioned by the delay or failure to furnish the Aircraft under this Agreement, whether or not maintenance-related.
Shipment If any of the Major Components associated with any Unit is not Shipped on or before (with the prior approval of the Buyer) the Scheduled Major Component Shipment Date set forth in Attachment 1 for reasons attributable to the Seller and not excused elsewhere in this Contract, the Seller shall pay as liquidated damages, and not as a penalty, a sum calculated in accordance with the table below for each Unit for each day of delay after the Scheduled Major Component Shipment Date as set forth in Attachment 1 until actual Shipment of the last Major Component for such Unit: Days after Scheduled Major Component Shipment Date Liquidated Damages (per day or partial day) *** *** *** *** *** *** Such liquidated damages, if any, shall be computed based on the date of Shipment of the last Major Component for a given Unit and such computations shall disregard any part of or accessory to the Major Component which may be shipped separately and arrive later unless such part of or accessory to the Major Component is necessary for the installation of the Major Component.
