Response to Request for Change Proposal Sample Clauses

Response to Request for Change Proposal. As soon as possible through the exercise of diligent efforts, and in any event within 30 days following KYTC’s delivery to DBT of a Request for Change Proposal, DBT shall provide KYTC with a response that contains a detailed assessment of the cost, schedule, and other impacts of the proposed KYTC-Directed Change, including the following: (a) DBT’s detailed estimate of the impacts on costs of carrying out the proposed KYTC-Directed Change, including any Extra Work Costs, or reduction in costs to DBT; (b) A Time Impact Analysis showing the effect of the proposed KYTC- Directed Change on the Baseline Schedule, including achievement of the Completion Deadlines, taking into consideration DBT’s duty to mitigate any delay, or any time saved by implementation of the proposed KYTC-Directed Change; (c) If so requested by KYTC, in its sole discretion, an alternative cost and schedule proposal showing the acceleration costs associated with meeting Completion Deadlines without an adjustment, as well as any additional costs permitted hereunder; and (d) Any other relevant information related to carrying out the proposed KYTC-Directed Change.
Sample 1Sample 2
AutoNDA by SimpleDocs
Response to Request for Change Proposal. ‌ As soon as possible through the exercise of diligent efforts, and in any event within 60 days, following IFA’s delivery to Developer of the Request for Change Proposal, Developer shall provide IFA with a written response as to whether, in Developer’s opinion, the IFA Change constitutes a Relief Event, and if so, a detailed assessment of the cost, schedule and other impacts of the proposed IFA Change, including the following: 16.1.3.1 Developer’s detailed estimate of the impacts on costs of carrying out the proposed IFA Change; 16.1.3.2 If IFA’s Notice requesting the Change Proposal is issued prior to the Final Acceptance Date, the effect of the proposed IFA Change on the Project Schedule, including achievement of the Project Schedule Deadlines, taking into consideration Developer’s duty to mitigate any delay; 16.1.3.3 The effect (if any) of the proposed IFA Change on Performance Requirements, the Rehabilitation Work Schedule and Handback Requirements; and 16.1.3.4 Any other relevant information related to carrying out the proposed IFA Change.‌
Sample 1

Related to Response to Request for Change Proposal

  • Request for Review Within sixty (60) days after receiving notice from the Plan Administrator that a claim has been denied (in part or all of the claim), then claimant (or their duly authorized representative) may file with the Plan Administrator, a written request for a review of the denial of the claim. The claimant (or his duly authorized representative) shall then have the opportunity to submit written comments, documents, records and other information relating to the claim. The Plan Administrator shall also provide the claimant, upon request and free of charge, reasonable access to, and copies of, all documents, records and other information relevant (as defined in applicable ERISA regulations) to the claimant’s claim for benefits.

  • Response to Notice Within ten business days of receiving the Claim Notice, the Respondent must notify the Claimant of its representative to negotiate the dispute.

  • Request for Proposals A State request inviting proposals for Goods or Services. This Contract shall be governed by the statutes, regulations and procedures of the State of Connecticut, Department of Administrative Services.

  • Request for clarification of the report 1. Within 10 days of the release of the report, either of the disputing Parties may submit a written request to the Panel, a copy of which shall be sent to the other Party, for clarification of any items the Party considers requires further explanation or definition. 2. The Panel shall respond to the request within 10 days following the submission of such request. The clarification of the Panel shall only be a more precise explanation or definition of the original contents of the report, and not an amendment of such report. 3. The filing of this request for clarification will not postpone the effect of the Panel report nor the deadline for compliance of the adopted decision, unless the Panel decides otherwise.

  • Response to Demand Letter Within 10 days after the receipt of the Demand Letter, RMC shall either: (a) cure the breach to OIG’s satisfaction and pay the applicable Stipulated Penalties or (b) request a hearing before an HHS administrative law judge (ALJ) to dispute OIG’s determination of noncompliance, pursuant to the agreed upon provisions set forth below in Section X.E. In the event RMC elects to request an ALJ hearing, the Stipulated Penalties shall continue to accrue until RMC cures, to OIG’s satisfaction, the alleged breach in dispute. Failure to respond to the Demand Letter in one of these two manners within the allowed time period shall be considered a material breach of this CIA and shall be grounds for exclusion under Section X.D.

  • Request for Waiver A. Prior to submission of a request for a partial or total waiver, Bidder/Contractor shall speak to the Designated Contacts of the OGS Office of Minority- and Women-Owned Business Enterprises for guidance. B. In accordance with 5 NYCRR § 142.7, a Bidder/Contractor who is able to document good faith efforts to meet the goal requirements, as set forth in clause VII below, may submit a request for a partial or total waiver on Form BDC 333, accompanied by supporting documentation. A Bidder may submit the request for waiver at the same time it submits its MWBE Utilization Plan. If a request for waiver is submitted with the MWBE Utilization Plan and is not accepted by OGS at that time, the provisions of clauses V(C), (D) & (E) will apply. If the documentation included with the Bidder’s/Contractor’s waiver request is complete, OGS shall evaluate the request and issue a written notice of acceptance or denial within twenty (20) business days of receipt. C. Contractor shall attempt to utilize, in good faith, any MBE or WBE identified within its MWBE Utilization Plan, during the performance of the Contract. Requests for a partial or total waiver of established goal requirements made subsequent to Contract award may be made at any time during the term of the Contract to OGS, but must be made no later than prior to the submission of a request for final payment on the Contract. D. If OGS, upon review of the MWBE Utilization Plan and Monthly MWBE Contractor Compliance Reports determines that Contractor is failing or refusing to comply with the contract goals and no waiver has been issued in regards to such non-compliance, OGS may issue a notice of deficiency to the Contractor. The Contractor must respond to the notice of deficiency within seven (7) business days of receipt. Such response may include a request for partial or total waiver of MWBE contract goals.

  • Cost Proposal After the Approved Working Drawings are approved by Landlord and Tenant, Landlord shall provide Tenant with a cost proposal in accordance with the Approved Working Drawings, which cost proposal shall include, as nearly as possible, the cost of all TI Allowance Items to be incurred by Tenant in connection with the construction of the Tenant Improvements (the "Cost Proposal"). Landlord does not guaranty the accuracy of the Cost Proposal. Notwithstanding the foregoing, portions of the cost of the Tenant Improvements may be delivered to Tenant as such portions of the Tenant Improvements are priced by Contractor (on an individual item-by-item or trade-by-trade basis), even before the Approved Working Drawings are completed (the "Partial Cost Proposal"). Tenant shall either (i) approve and deliver the Cost Proposal to Landlord within five (5) business days of the receipt of the same (or, as to a Partial Cost Proposal, within two (2) business days of receipt of the same), or (ii) notify Landlord within five (5) business days after Tenant's receipt of the Cost Proposal (or Partial Cost Proposal, as the case may be) that Tenant desires to revise the Approved Working Drawings to reduce the amount of the Cost Proposal (or Partial Cost Proposal, as the case may be), in which case such changes shall be made to the Approved Working Drawings only in accordance with Section 2.7 above and the revised Working Drawings shall be provided to the Contractor for repricing whereupon Landlord shall revise the Cost Proposal (or Partial Cost Proposal, as the case may be) for Tenant's approval. This procedure shall be repeated until the Cost Proposal (or Partial Cost Proposal, as the case may be) is approved by Tenant. The date by which Tenant has approved the Cost Proposal, or the last Partial Cost Proposal, as the case may be, shall be known hereafter as the "Cost Proposal Delivery Date." The total of all Partial Cost Proposals, if any, shall be known as the Cost Proposal.

  • Notice of Decision If the Plan Administrator denies part or all of the claim, the Plan Administrator shall notify the claimant in writing of such denial. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth: (a) The specific reasons for the denial; (b) A reference to the specific provisions of the Agreement on which the denial is based; (c) A description of any additional information or material necessary for the claimant to perfect the claim and an explanation of why it is needed; (d) An explanation of the Agreement’s review procedures and the time limits applicable to such procedures; and (e) A statement of the claimant’s right to bring a civil action under ERISA Section 502(a) following an adverse benefit determination on review.

  • Request for Consent If Tenant desires at any time to enter into an Assignment of this Lease or a Sublease of the Premises or any portion thereof for which Landlord’s consent is required, it shall first give written notice to Landlord of its desire to do so, which notice shall contain (i) the name of the proposed assignee, subtenant or occupant; (ii) the name and nature of the proposed assignee’s, subtenant’s, or occupant’s business to be carried on in the Premises; (iii) the terms and provisions of the proposed Assignment or Sublease; and (iv) such financial and other information as Landlord may reasonably request concerning the proposed assignee, subtenant or occupant. Any improvements, additions, or alterations to the Premises or either Building that are required by applicable Laws or are deemed necessary or appropriate by Landlord, in Landlord’s reasonable judgment, as a result of any such Sublease or Assignment including, without limitation, demising walls and/or other improvements, additions or alterations necessary to cause the Premises to be suitable for multiple tenants (all of the foregoing collectively, “Required Sublease Improvements”), shall be installed and provided by Tenant (or, at Landlord’s sole option, by Landlord but at Tenant’s expense), without cost or expense to Landlord. Landlord may condition its consent to any proposed Sublease or Assignment on both (x) the construction of Required Sublease Improvements, and (y) a requirement that funds sufficient, in Landlord’s reasonable judgment, to cause the removal of the Required Sublease Improvements and restoration of the Premises to its condition prior to installation of the Required Sublease Improvements upon the earlier of expiration or termination of the Sublease or Assignment or this Lease be provided by Tenant to Landlord upon Landlord’s approval of such Sublease or Assignment, to be held as additional security for Tenant’s obligations to remove the Required Sublease Improvements upon expiration or earlier termination of this Lease as required by Paragraph 25(a). Tenant shall reimburse Landlord upon demand for any reasonable out-of-pocket expenses incurred by Landlord in connection with such review, including reasonable attorneys’ fees, and such obligation shall be an Additional Charge.

  • Proposal Proposal means any information supplied by or on behalf of the insured, deemed to be a completed proposal form and medical questionnaire and other relevant information that the insurer may require.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!