Revision of Basic Service Compensation Sample Clauses

Revision of Basic Service Compensation. 9.1.2.1 Notwithstanding the foregoing or Section 10.1.1, when any phase or phases of the A/E's Basic Services are deleted or otherwise not performed, or any portion of a phase, or any portion of the scope of the A/E's Basic Services are deleted or otherwise not performed, or at HISD's sole discretion the project scope is increased or reduced from the scope of services described in Article 13, or if individual sites are added or deleted, then the fixed compensation for such portions of the A/E's Basic Services shall be payable based on the amount or proportion of services actually performed as determined by HISD. 9.1.2.2 Notwithstanding anything in this Agreement to the contrary: (A) Any increase(s) in the Construction Budget as set forth in Section 5.1.2 shall not be effective unless such increase(s) are approved by the HISD Board of Education (HISD Board), (B) Any increase(s) in the A/E's fees as set forth in Section 9.1.1 shall not be effective unless such increase(s) are approved in writing by the HISD Chief Operations Officer or designee. Any such increases set forth above that may be agreed to by other HISD staff shall be null and void and shall not be binding on HISD. A/E shall not have a claim, either contractually or by quantum merit, for any services rendered prior to any such required increase approval(s) as set forth above. If the A/E attempts to receive or receives an agreement modification or amendment from a district employee who is not authorized to make changes, the A/E does this at its own risk or peril and risks termination of the Agreement for cause.
Sample 1
AutoNDA by SimpleDocs

Related to Revision of Basic Service Compensation

  • Compensation for Basic Services A. Owner shall make payment for Part I and Part II services monthly. The payments shall be in proportion to the progress of Engineer's work. Final payment for each phase shall become due and payable upon completion and approval by Owner of that phase of Engineer's work. B. Owner shall make payment for Construction Phase services not more frequently than monthly in proportion to the amount of the gross progress payments to Contractor(s). C. Owner shall make no deduction from Engineer's compensation on account of penalties, liquidated damages or other sums withheld from Contractor(s) through no fault of Engineer. D. Owner shall make payment for Construction Completion Phase services upon completion of the requirements set forth in subsections II. F. 1, 2 and 3. E. Engineer shall submit requests for payment monthly on forms provided and in a manner prescribed by Owner.

  • COMPENSATION OF ULTIMUS The Trust, on behalf of each Fund, shall pay for the services to be provided by Ultimus under this Agreement in accordance with, and in the manner set forth in, Schedule B attached hereto, as such Schedule may be amended from time to time. If this Agreement becomes effective subsequent to the first day of a month or terminates before the last day of a month, Ultimus’ compensation for that part of the month in which the Agreement is in effect shall be prorated in a manner consistent with the calculation of the fees as set forth above. Payment of Ultimus’ compensation for the preceding month shall be made promptly.

  • Supplemental Compensation Pursuant to Section 7 of the Agreement, Supplemental Compensation is payable as follows.

  • Developer Compensation for Emergency Services If, during an Emergency State, the Developer provides services at the request or direction of the NYISO or Connecting Transmission Owner, the Developer will be compensated for such services in accordance with the NYISO Services Tariff.

  • Basic Compensation (a) SALARY. Executive will be paid an annual base salary of $115,000.00, subject to adjustment as provided below (the "Salary"), which will be payable in equal periodic installments according to Employer's customary payroll practices, but no less frequently than monthly. The Salary will be reviewed by the Board of Directors not less frequently than annually, and shall be increased on each anniversary of the Effective Date during the term hereof by an amount equal to not less than ten percent (10%) of the prior year's base salary.

  • Additional Compensation Notwithstanding anything in this Memorandum of Understanding to the contrary when in the judgment of the Board, it becomes necessary or desirable to utilize the services of County employees in capacities other than those for which they are regularly employed, the Board may authorize and, if appropriate, fix an additional rate of compensation for such employees.

  • Reduction of Compensation If the Firm fails to meet the submission date by less than thirty days for the draft report and/or working papers submitted to the Office of the State Auditor for review and approval or by less than thirty days from the completion date for the final reports and/or corrections to the working papers prescribed herein, the District may, with the consent of the Office of the State Auditor, reduce the agreed compensation by an amount not to exceed ten percent of the total contract price for the applicable fiscal year. If reports and/or corrections to the working papers are overdue by 30 days or more, the District may reduce, with the consent of the Office of the State Auditor, the agreed compensation by an amount not to exceed twenty percent of the total contract price for the Rev. 10/20 applicable fiscal year.

  • Compensation for Additional Services Additional Services shall be compensated as set forth on Exhibit A for the stipulated payment amounts set forth therein. Other Additional Services not set forth on Exhibit A that are required or requested by the Owner shall be compensated as agreed, using the methodology set forth on Exhibit A, prior to the Design Professional undertaking such Additional Services; provided, however, that if such compensation cannot be agreed, the Additional Services shall be performed at the hourly rates set forth and listed in Exhibit B, plus reimbursable expenses pursuant to Article 4.1.3 below, with a limitation as to maximum amount specified.

  • Payment of Compensation Consultant shall submit to City a monthly itemized statement which indicates work completed and hours of Services rendered by Consultant. The statement shall describe the amount of Services and supplies provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement. City shall, within 30 days of receiving such statement, review the statement and pay all approved charges thereon.

  • Extra Compensation The Board shall pay no fees, other than described above, to the PA/E unless authorized by the Board as follows: A. If the scope of the Project or site is changed, the Board and the PA/E shall negotiate a reasonable fee based upon the probable estimated construction cost in changing the scope of the work and the approximate percentage of the estimated construction cost which was used to negotiate this Agreement if, and, as such may be applicable. B. If the DOE or Board requires the PA/E to make major or costly changes to the Schematic, Preliminary or Construction Document Phase submittals, which changes are not caused by architectural or engineering error or oversight, the PA/E shall be paid to redesign for additional expenses in an amount agreed to by the parties. Under no circumstances will the principals of the PA/E and the principals of his consultants be paid a fee in excess of $125.00 per hour.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!