Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).
Service Changes PBI may modify its Service by giving written notice to you (a “Service Change Notice”), which will state whether the change is material. After receiving a Service Change Notice, if the change is material, you may terminate Service by giving us a termination notice at the address indicated in Section 21 or you may create a case at xxxxxxxxxxx.xxx/xx/xxxxxxx-xx.xxxx (follow the instructions under “how to create a case”).
Change Order (5) The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.
Change Order Formats Formats for Lump Sum Change Orders and for Change Orders based upon either a force account or upon unit pricing with an indeterminate number of units are in Section 7, Forms.
Other Change Orders For Change Orders involving the following situations that would materially affect the completion of the Work by lengthening the critical path of the Construction Progress Schedule, the Design Professional shall determine the appropriate number of days and thereby extend the Material Completion and Occupancy Date. The Contractor expressly agrees that the Contractor’s sole monetary remedy for such extensions of Contract Time shall be calculated at the daily rate established for Time Dependent Overhead Costs in the Contract.
Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Housing.
For Lump Sum Change Order The payment and extension of time (if any) provided by this Change Order constitutes compensation in full to the Contractor and its Subcontractors and Suppliers for all costs and markups directly and indirectly attributable to the Change Order herein, for all delays related thereto and for performance of changes within the time stated.
The Change Order The Change Order is the instrument by which adjustments in the Contract Sum and the Contract Time are effected. The Change Order shall be accompanied by a breakdown as set forth in Paragraph 3.2.7.4. The breakdown is for the purpose of enabling the Design Professional and the Owner to make a judgment on the dollar amount of the adjustment in the Contract Sum and is not a part of the Change Order. No condition, term, qualification, limitation, exception, exemption, modification, or proviso, except as set forth in this Part, shall appear in the breakdown. Only such conditions, terms, qualifications, limitations, exceptions, exemptions, modifications, and provisos as are permitted under this Part are valid. The Design Professional shall certify to the dollar amount and description of the adjustments permitted by the Change Order.
Work Order (s) means a detailed scope of work for a Service required by Transnet, including timeframes, Deliverable, Fees and costs for the supply of the Service to Transnet, which may be appended to this Agreement from time to time.
Product Changes Vocera shall have the right, in its absolute discretion, without liability to End User, to update to provide new functionality or otherwise change the design of any Product or to discontinue the manufacture or sale of any Product. Vocera shall notify End User at least 90 days prior to the delivery of any Product which incorporates a change that adversely affects form, fit or function (“Material Change”). Vocera shall also notify End User at least 90 days prior to the discontinuance of manufacture of any Product. Notification will be made as soon as reasonably practical for changes associated with regulatory or health and safety issues.