Specific Actions by the City Sample Clauses

Specific Actions by the City. The City actions and proceedings subject to this Agreement shall be through the PBCE Department, as well as affected City Agencies (and when required by applicable Law, the City Council), and shall include, upon application by Developer, instituting and completing proceedings for the temporary or permanent closing or occupancy, widening, modifying (including changes from vehicular to pedestrian use) or changing the grades of streets, alleys, sidewalks, and other rights-of-way, and other necessary modifications of the streets, the street layout, and other public or private rights-of-way in or near the Project Site, including streetscape improvements, encroachment permits, improvement permits, and any requirement to abandon, remove, and relocate public utilities (and, when applicable, City utilities) within the public rights-of-way as identified in the Approvals and Subsequent Approvals. Except as set forth in Section 9.3.4 and upon receiving payments of all applicable Processing Fees then due, City Agencies shall process with due diligence all complete submissions and applications by Developer on all permits, approvals, construction, or occupancy permits for the Project, subject to the acceptance of the same as complete; provided, however, that any delays in City’s processing of such submission and applications attributable to a delay or failure by any Non-City Agency to perform or grant any required action, approval, or authorization, shall not be deemed to be breach by City of this Section.
AutoNDA by SimpleDocs
Specific Actions by the City. The City actions and proceedings subject to this Agreement shall be through the Planning Department, as well as affected City Agencies (and when required by applicable Law, the Board of Supervisors), and shall include instituting and completing proceedings for temporary or permanent closing or occupancy, widening, modifying (including changes from vehicular to pedestrian use) or changing the grades of streets, alleys, sidewalks, and other rights-of-way, and other necessary modifications of the streets, the street layout, and other public or private rights-of-way in or near the Project Site, including streetscape improvements, encroachment permits, improvement permits, and any requirement to abandon, remove, and relocate public utilities (and, when applicable, City utilities) within the public rights-of-way as identified in the Approvals and Subsequent Approvals. Except as set forth in Section 9.4.4, City Agencies shall process with due diligence all submissions and applications by Developer on all permits, approvals, construction or occupancy permits for the Project subject to the acceptance of the same as complete.
Specific Actions by the City. The City actions and proceedings subject to this Agreement shall be through the Planning Department, as well as affected City Agencies (and when required by applicable Law, the Board of Supervisors), and shall include instituting and completing proceedings for closing, vacating, widening, modifying, or changing the grades of streets, alleys, sidewalks, and other public rights-of-way and for other necessary modifications of the streets, the street layout, and other public rights-of-way in or near the Project Sites, including any requirement to abandon, remove, and relocate public utilities (and, when applicable, City utilities) within the public rights-of-way as specifically identified and approved in the Approvals and Subsequent Approvals. Except as set forth in Section 9.4.6, City Agencies shall process with due diligence all submissions and applications by CPMC on all permits, approvals, construction or occupancy permits for the Project subject to the acceptance of the same as complete.
Specific Actions by the City. City actions and proceedings subject to this ICA shall be through the Mayor or his or her designee, as well as affected City Agencies, and shall include:
Specific Actions by the City. City actions and proceedings subject to this Agreement shall be through the Planning Department, as well as affected City Agencies, (and when required by applicable law, the Board of Supervisors) and shall include:
Specific Actions by the City. Except as otherwise expressly set forth herein, references to the City are, and shall be deemed, references to the City acting by and through the Planning Director (or when required by the Applicable Standards, the affected City Agencies or the Board of Supervisors). The City actions and proceedings subject to this Agreement shall be through the Planning Department (and when required by Applicable Standards, affected City Agencies or the Board of Supervisors), and shall include instituting and completing proceedings for temporary or permanent closing, occupancy, widening, modifying or changing the grades of streets and other necessary modifications of the streets, the street layout and other public or private rights-of-way, including streetscape improvements, encroachment permits, improvement permits and any requirement to abandon, remove and relocate public utilities (and, when applicable, City utilities) as identified in the Approvals.

Related to Specific Actions by the City

  • Acceptance by the City It is expressly understood and agreed that all materials provided and/or work done by the Contractor shall be subject to inspection and acceptance by the City at its discretion, and that any progress inspections and approval by the City of any item or work shall not forfeit the right of the City to require the correction of faulty workmanship or material at any time during the course of the work, although previously approved by oversight. Nothing herein contained shall relieve the Contractor of the responsibility for proper construction and maintenance of the work, materials and equipment required under the terms of this Contract until all work has been completed and accepted by the City.

  • Termination by the City 96.1. In addition to termination pursuant to any other article of this Contract, the Commissioner may, at any time, terminate this Contract by written notice to the Contractor. In the event of termination, the Contractor shall, upon receipt of such notice, unless otherwise directed by the Commissioner:

  • Audits by The District and Correction of Accounts During the term of this Agreement and for a period of six (6) years following the termination of this Agreement, the District may begin an audit of Contractor’s provision of goods and/or services under this Agreement. Contractor agrees to retain and make available for inspection all of its records pertaining to its performance of this Agreement, including billing records and any banking records that may reflect proceeds from any transactions with the District, during the term of this Agreement and for at least six (6) years following the termination of this Agreement. If Contractor receives notice that The District is auditing its performance under this Agreement or litigation results from this Agreement, then Contractor agrees to retain and make available for inspection all of its records pertaining to its performance of this Agreement, including billing records and any banking records that may reflect proceeds from any transactions with the District, for an additional three (3) years following the conclusion of the audit or the entry of a final judgment in any such litigation and the final resolution of any possible appeals of a final judgment in any such litigation. If the District determines as result of its audit, that Contractor has failed to satisfy the invoicing or documentation requirements of this Agreement, has improperly billed the District for goods and/or services that were not actually provided, or has overcharged the District for goods and/or services that were actually provided by Contractor, then Contractor shall repay the District, without interest, for any improper payments or overpayments made by the District to Contractor within thirty (30) days of a written demand by the District. If Contractor fails to repay the District for any improper payments or overpayments within thirty (30) days of the District’s written demand, then Contractor will owe the District interest accrued daily at the rate of 7.0% per annum from the date of the District’s written demand until the improper payment and/or overpayment is repaid in full by Contractor. Conversely, if an audit initiated by the District reveals that the District owes additional compensation to Contractor pursuant to the terms of this Agreement, then the District will pay the additional compensation to Contractor, without interest, within thirty (30) days of the completion of its audit. If the District fails to pay Contractor for any additional compensation owed under this Agreement within thirty (30) days after completion of its audit, then the District will pay Contractor interest on the additional compensation accrued daily at the rate of 7.0% per annum from the date of the completion of the District’s audit.

  • Review by the Bank of Procurement Decisions The Procurement Plan shall set forth those contracts which shall be subject to the Bank’s Prior Review. All other contracts shall be subject to Post Review by the Bank.

  • Release by the Contractor The acceptance by the Contractor of final payment shall release NYSERDA from all claims and liability that the Contractor, its representatives and assigns might otherwise have relating to this Agreement.

  • Determinations by the Director All determinations required by the Director under this Agreement are subject to an HSP’s rights of review and appeal under the Act.

  • Suits by the Corporation The Corporation shall have the right to enforce full payment of the Exercise Price of all Common Shares issued by the Warrant Agent to a Registered Warrantholder hereunder and shall be entitled to demand such payment from the Registered Warrantholder or alternatively to instruct the Warrant Agent to cancel the share certificates and amend the securities register accordingly.

  • Review by the World Bank of Procurement Decisions The Procurement Plan shall set forth those contracts which shall be subject to the World Bank’s Prior Review. All other contracts shall be subject to Post Review by the World Bank.

  • TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.

  • Review by the Association of Procurement Decisions The Procurement Plan shall set forth those contracts which shall be subject to the Association’s Prior Review. All other contracts shall be subject to Post Review by the Association.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!