Contractor’s Submittals The Contract shall submit with reasonable promptness consistent with the Work Project Schedule and in orderly sequence all Shop Drawings, Samples, or other information required by the Contract Documents, or subsequently required by Change Order. Prior to submitting, the Contractor shall review each submittal for compliance with the Contract Documents and certify its approval by an approval stamp affixed to each copy. Submittal data presented without the Contractor’s certification will be returned without review or comment, and any delay resulting from such certification is the Contractor's responsibility.
Contractor Certification for Contractor Employees Introduction Texas Education Code Chapter 22 requires entities that contract with school districts to provide services to obtain criminal history record information regarding covered employees. Contractors must certify to the district that they have complied. Covered employees with disqualifying criminal histories are prohibited from serving at a school district. Definitions: Covered employees: Employees of a contractor or subcontractor who have or will have continuing duties related to the service to be performed at the District and have or will have direct contact with students. The District will be the final arbiter of what constitutes direct contact with students. Disqualifying criminal history: Any conviction or other criminal history information designated by the District, or one of the following offenses, if at the time of the offense, the victim was under 18 or enrolled in a public school: (a) a felony offense under Title 5, Texas Penal Code; (b) an offense for which a defendant is required to register as a sex offender under Chapter 62, Texas Code of Criminal Procedure; or (c) an equivalent offense under federal law or the laws of another state. I certify that: NONE (Section A) of the employees of Contractor and any subcontractors are covered employees, as defined above. If this box is checked, I further certify that Contractor has taken precautions or imposed conditions to ensure that the employees of Contractor and any subcontractor will not become covered employees. Contractor will maintain these precautions or conditions throughout the time the contracted services are provided. OR SOME (Section B) or all of the employees of Contractor and any subcontractor are covered employees. If this box is checked, I further certify that: (1) Contractor has obtained all required criminal history record information regarding its covered employees. None of the covered employees has a disqualifying criminal history. (2) If Contractor receives information that a covered employee subsequently has a reported criminal history, Contractor will immediately remove the covered employee from contract duties and notify the District in writing within 3 business days. (3) Upon request, Contractor will provide the District with the name and any other requested information of covered employees so that the District may obtain criminal history record information on the covered employees. (4) If the District objects to the assignment of a covered employee on the basis of the covered employee's criminal history record information, Contractor agrees to discontinue using that covered employee to provide services at the District. Noncompliance or misrepresentation regarding this certification may be grounds for contract termination. None Texas Business and Commerce Code § 272 Requirements as of 9-1-2017 SB 807 prohibits construction contracts to have provisions requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. 7 5 Texas Government Code 2270 Verification Form Texas Government Code 2270 Verification Form Texas 2017 House Xxxx 89 has been signed into law by the governor and as of September 1, 2017 will be codified as Texas Government Code § 2270 and 808 et seq. The relevant section addressed by this form reads as follows: Texas Government Code Sec. 2270.002. PROVISION REQUIRED IN CONTRACT. A governmental entity may not enter into a contract with a company for goods or services unless the contract contains a written verification from the company that it: (1) does not boycott Israel; and (2) will not boycott Israel during the term of the contract engaged by: ESC Region 8/The Interlocal Purchasing System (TIPS) 0000 Xxxxxxx 000 Xxxxx Xxxxxxxxx,XX,00000 I verify by this writing that the above-named company affirms that it (1) does not boycott Israel; and (2) will not boycott Israel during the term of this contract, or any contract with the above-named Texas governmental entity in the future. I further affirm that if our company’s position on this issue is reversed and this affirmation is no longer valid, that the above-named Texas governmental entity will be notified in writing within one (1) business day and we understand that our company’s failure to affirm and comply with the requirements of Texas Government Code 2270 et seq. shall be grounds for immediate contract termination without penalty to the above-named Texas governmental entity. AND Our company is not listed on and we do not do business with companies that are on the the Texas Comptroller of Public Accounts list of Designated Foreign Terrorists Organizations per Texas Gov't Code 2270.0153 found at xxxxx://xxxxxxxxxxx.xxxxx.xxx/purchasing/docs/foreign-terrorist.pdf I swear and affirm that the above is true and correct. YES
Subcontractor compliance The Recipient is responsible for Subrecipient compliance with the requirements of this clause and may be held liable for unpaid wages due Subrecipient workers.
Contractor Key Personnel The Contractor shall assign a Corporate OASIS Program Manager (COPM) and Corporate OASIS Contract Manager (COCM) as Contractor Key Personnel to represent the Contractor as primary points-of-contact to resolve issues, perform administrative duties, and other functions that may arise relating to OASIS and task orders solicited and awarded under XXXXX. Additional Key Personnel requirements may be designated by the OCO at the task order level. There is no minimum qualification requirements established for Contractor Key Personnel. Additionally, Contractor Key Personnel do not have to be full-time positions; however, the Contractor Key Personnel are expected to be fully proficient in the performance of their duties. The Contractor shall ensure that the OASIS CO has current point-of-contact information for both the COPM and COCM. In the event of a change to Contractor Key Personnel, the Contractor shall notify the OASIS CO and provide all Point of Contact information for the new Key Personnel within 5 calendar days of the change. All costs associated with Contractor Key Personnel duties shall be handled in accordance with the Contractor’s standard accounting practices; however, no costs for Contractor Key Personnel may be billed to the OASIS Program Office. Failure of Contractor Key Personnel to effectively and efficiently perform their duties will be construed as conduct detrimental to contract performance and may result in activation of Dormant Status and/or Off-Ramping (See Sections H.16. and H.17.).
Subcontractor Requirements The Supplier must ensure that any subcontract entered into for the purpose of this Agreement contains an equivalent clause granting the rights specified in this clause.
Subcontracting Plan The Contractor shall comply with the Contractor’s Subcontracting Plan and Subcontracting Plan Addendums, incorporated into the OASIS contract by reference, to ensure that small business, small disadvantage business (SDB), women-owned business (WOSB), HUBZone small business (HUBZone), veteran-owned small business (VOSB), and service-disabled veteran-owned small business (SDVOSB), are provided the maximum practicable opportunity to participate as Subcontractors. As stated in 15 U.S.C. 637(d)(8), any Contractor or Subcontractor failing to comply in good faith with the requirements of the subcontracting plan is in material breach of its contract. Further, 15 U.S.C. 637(d)(4)(F) directs that a Contractor’s failure to make a good faith effort to comply with the requirements of the subcontracting plan shall result in the imposition of liquidated damages. The OASIS Program Office requires use of the electronic Subcontracting Reporting System (eSRS) modules as the secure, confidential, information management tool to evaluate subcontracting goal performance for OASIS. The Subcontracting Plan covers the OASIS program as whole, however, the Contractor shall submit Individual Subcontract Reports (ISR) for Individual Subcontracting Plans, if applicable, and Summary Subcontract Reports (SSR) per each individual Pool the Contractor has a contract award using the web-based eSRS at xxxx://xxx.xxxx.xxx. Affiliates of the Prime Contractor or Subcontractor are not included in these reports. Subcontract award data reported by Prime Contractors and Subcontractors shall be limited to awards made to their immediate next-tier Subcontractors. Contractors are required to adhere to their Subcontracting Plan, incorporated into the basic contract by reference. When a Contractor does not meet any one or more of their Subcontracting Goals for a given reporting period, the Contractor shall explain, in writing, the rationale for not meeting the goals in the comments section of the ISR/SSR.
Subcontractor Payments Subject to Agency’s prior approval, Agency will reimburse Outside Counsel for the actual, reasonable and necessary expenses relating to Outside Counsel’s use of subcontractors. Outside Counsel shall be responsible for any payments and other claims due to subcontractors for work performed under this OCC. Outside Counsel, in subcontracting for any performances or in support of any of the performances specified herein (e.g., expert services, local counsel, and other services), expressly understands and agrees that Agency shall not be directly liable in any manner to Outside Counsel’s subcontractor(s).
HUB Subcontracting Plan The Owner has adopted Exhibit H, Policy on Utilization of Historically Underutilized Business ("Policy"), which is incorporated herein by reference. Contractor, as a provision of the Agreement must comply with the requirements of the Policy and adhere to the HUB Subcontracting Plan submitted with Contractor's Proposal and attached as Exhibit I. No changes to the HUB Subcontracting Plan can be made by the Contractor without the prior written approval of the Owner in accordance with the Policy.
Solicitations for Subcontractors, Including Procurements of Materials and Equipment In all solicitations either by competitive bidding or negotiation made by the contractor for work to be performed under a subcontract, including procurements of materials or leases of equipment, each potential subcontractor or supplier shall be notified by the contractor of the contractor's obligations under this contract and the Regulations relative to nondiscrimination on the grounds of race, color, or national origin, sex, age, and disability/handicap.
Contractor Selection In this section, please describe the selection process, including other sources considered and the rationale for selecting the contractor. Please answer all questions:
