Term Termination and Survival 9.1 This Agreement shall commence as of the Effective Date and shall continue thereafter until the completion of the Services under all Statements of Work unless sooner terminated pursuant to Section 9.2 or Section 9.3.
9.2 Either Party may terminate this Agreement, effective upon written notice to the other Party (the “Defaulting Party”) if the Defaulting Party:
(a) Materially breaches this Agreement, and such breach is incapable of cure, or with respect to a material breach capable of cure, the Defaulting Party does not cure such breach within 30 days after receipt of written notice of such breach.
(b) Becomes insolvent or admits its inability to pay its debts generally as they become due.
(c) Becomes subject, voluntarily or involuntarily, to any proceeding under any domestic or foreign bankruptcy or insolvency law, which is not fully stayed within seven business days or is not dismissed or vacated within 45 business days after filing.
(d) Is dissolved or liquidated or takes any corporate action for such purpose.
(e) Makes a general assignment for the benefit of creditors.
(f) Has a receiver, trustee, custodian, or similar agent appointed by order of any court of competent jurisdiction to take charge of or sell any material portion of its property or business.
9.3 Notwithstanding anything to the contrary in Section 9.2(a), TAI may terminate this Agreement upon written notice to XXX upon the occurrence of any of the following events (each of the following, a “Specified Event of Default”):
(a) XXX fails to pay any undisputed amount when due hereunder and such failure continues for 30 days after XXX’s receipt of written notice of nonpayment;
(b) XXX fails to timely achieve, complete, or pass any of the XXX Caravan STC Milestone Requirements by the applicable XXX Completion Date (subject to the applicable cure period) as set forth in Exhibit A as determined in the good faith discretion of TAI; provided that, the applicable XXX Completion Dates shall be equitably adjusted to the extent XXX is not able to achieve, complete or pass any XXX Caravan STC Milestone Requirement or such XXX Caravan STC Milestone Requirement is not otherwise met, in each case as a result of (a) the material breach of TAI of its obligations hereunder or (b) the occurrence of a Force Majeure Event, with an extension to the corresponding XXX Completion Date commensurate with the delay caused by such TAI breach or Force Majeure Event, provided, however, that no extension related to a Force Majeure Event shall be longer than 45 days;
(c) the occurrence of a “Change of Control”, which means (i) the acquisition by any Person of ownership or power to vote more than 49% of the voting stock of XXX by means of any transaction or series of related transactions (including any reorganization, merger or consolidation, but excluding any business combination with a SPAC by XXX or its Affiliate completed prior to the one (1) year anniversary of the date hereof), (ii) the acquisition of ownership or power to vote more than 10% of the voting stock of XXX by a TAI competitor, (iii) a sale of all or substantially all of the assets of XXX, (iv) a material change of XXX’s senior leadership occurring prior to the five (5) year anniversary of the date hereof, in each case of the foregoing clauses (i) – (iv), directly or indirectly, including as to any successor of XXX;
Agreement Term and Termination This agreement will remain in effect until the expiration or termination of Customer’s Subscription, whichever is earliest. Customer may terminate this agreement at any time by contacting its Reseller. The expiration or termination of this agreement will only terminate Customer’s right to place new orders for additional Products under this agreement.
Dissolution and Termination (a) The Company shall not be dissolved by the admission of Substitute Members or Additional Members. The Company shall dissolve, and its affairs shall be wound up, upon:
(i) an election to dissolve the Company by the Manager (or, if the Manager has been removed for “cause” pursuant to Section 5.2, an election to dissolve the Company by an affirmative vote of the holders of not less than a majority of the Common Shares then Outstanding entitled to vote thereon);
(ii) the sale, exchange or other disposition of all or substantially all of the assets and properties of the Company;
(iii) the entry of a decree of judicial dissolution of the Company pursuant to the provisions of the Delaware Act; or
(iv) at any time that there are no members of the Company, unless the business of the Company is continued in accordance with the Delaware Act.
Effective Date Term and Termination 1.1 The effective date ("EFFECTIVE DATE") of this Agreement shall be the date first above written.
1.2 The term of this Agreement ("TERM") commences on the Effective Date, and unless the Agreement is terminated pursuant to Section 1.3 or 1.4, it shall continue in force until "Completion Date" (as defined in Section 3.2).
1.3 Each party may terminate this Agreement (effective immediately upon written notice) if the other party materially breaches any provision of this Agreement if such breach continues and is not cured within [***] after written notice thereof by the non-breaching party, including the nature of the breach upon which such notice is based. SVI may terminate this Agreement upon written notice to Customer if Customer fails to pay, within [***] of a Payment Date, any amount payable hereunder. SVI may suspend its performance of services under the terms of this Agreement pending receipt of such payment. Any such termination by SVI shall not affect SVI and Customer's respective rights with respect to any Deliverables and/or Professional Services delivered or performed and fully paid during the Term.
1.4 Customer may terminate this Agreement during the Term (a) upon written notice to SVI after [***] prior written notice, provided that Customer shall remain obligated to pay to SVI all amounts due SVI to such termination date (b) upon [***] written notice to SVI after a change of control (as defined in Section 13.1), or (c) on the occurrence of any of the following: (i) an assignment by SVI for the benefit of creditors; (ii) the appointment of a trustee or receiver for substantially all of SVI's assets; or (iii) to the extent termination is enforceable under the U.S. Bankruptcy Code, a proceeding in bankruptcy is instituted against SVI which is acquiesced in, is not dismissed within [***], or results in an adjudication of bankruptcy.
1.5 After expiration or termination of this Agreement for any reason, other than related to Customer's breach, SVI shall promptly deliver any partially-created Deliverable that exists as of the expiration or termination date; provided that Customer pays SVI all amounts then due SVI. Upon delivery, such Deliverable shall be considered a "Deliverable" for all purposes hereunder.
1.6 Subject to each party's rights, remedies and defenses relating to any breach by the other party, the provisions of Sections 1.5, 1.6, 6 (with respect to Deliverables delivered in the Term, subject to Section 1.5), 9.1 (with respect to fees accrued prior to expiration or termination), 9.3, 12.2(a), 12.3-12.7, 14-33 shall survive expiration or termination of this Agreement (including the Revenue Sharing Term in Section 17.1) for any reason. [***] = Confidential Treatment Requested
Contract Term and Termination 14.1 The Contract becomes effective when the Holder / Authorized user receives the card and the PIN and is valid for a period of 60 months with the possibility of being automatically extended for new successive periods of 60 months. If neither party sends the other party a written notification at least 30 days before the expiry of the initial term or of any of the extended terms, specifying that it does not wish to extend the Contract.
Termination and Termination Pay Subject to Section 12 of this Agreement, Executive’s employment under this Agreement may be terminated in the following circumstances:
License Term and Termination Unless otherwise specified, any license granted is perpetual, provided however that if Customer fails to comply with the terms of this Agreement, HP may terminate the license upon written notice. Immediately upon termination, or in the case of a limited-term license, upon expiration, Customer will either destroy all copies of the software or return them to HP, except that Customer may retain one copy for archival purposes only.
Expiration and Termination This Agreement is for one academic year (August 1, 2018 through July 31, 2019) and will automatically renew for the following academic year unless terminated as indicated below by either party.
a. Any party may terminate this Agreement by written notice to the other at any time if that other party: (i.) commits a breach of this Agreement and, has not yet remedied the breach within 14 days of being notified of the facts and circumstances giving rise to the breach; or
Entry Into Force, Duration and Termination 1. The Contracting Parties shall notify each other when the constitutional requirements for entry into force of this Agreement have been fulfilled. The Agreement shall enter into force on the first day of the second month following the date of receipt of the last notification.
2. This Agreement shall remain in effect for a period of 20 years. Hereinafter, it shall remain in effect until the expiration of 12 months from the date on which any of the Contracting Parties gives written notice to the other Contracting Party of its decision to terminate this Agreement.
3. In respect of investments made prior to the date when the notice of termination of this Agreement becomes effective, the provisions of Articles 1 to 12 shall remain in force for the further period of twenty years from that date.
Term and Termination 10.1 Where the Inventor or any third-party nominee (“Nominee”) or legal person (‘Legal Person”) who has control of any rights over the Project Intellectual Property has been declared bankrupt, filed for bankruptcy or where a creditor has filed a claim in bankruptcy against the Inventor, Nominee or Legal Person, which results in the bankruptcy of the Inventor, Nominee or Legal Person, or where the Inventor, Nominee or Legal Person files for creditor protection or makes an arrangement with creditors which results in the bankruptcy of the Inventor, Nominee or Legal Person, then the University may terminate the present Agreement against the Inventor, or Nominee or Legal Person having control of any rights over the Project Intellectual Property as the case may be. The University may terminate the present Agreement with respect to any Nominee or Legal Person, except for the Inventor, that ceases to pursue its normal business operations, ceases to exist legally or files for creditor protection or makes an arrangement with creditors which does not result in the bankruptcy of the said Nominee or Legal Person, as the case may be. Any notice of termination shall be in writing and delivered to the Nominee or Legal Person in default under this section and the termination shall be effective on the date of receipt of the termination notice. Where the University terminates this Agreement acting under this section 10, any assignment, transfer, conveyance or licensing of the Project Intellectual Property shall be immediately null and void and of no effect as if it had never taken place. Any agreement entered into by the Inventor and any Nominee or other Legal Person involving the Project Intellectual Property shall make reference to this section 10 and include it as a binding obligation.
10.2 This Agreement may otherwise be terminated by either party in the event of default upon thirty (30) days written notice to the defaulting party. Such termination occurs where a party has defaulted or failed to comply with the terms of this Agreement and, following receipt by the defaulting party of a written notice of default, has failed to cure any such default within that period of thirty (30) days.
10.3 The provisions relating to confidentiality, dispute resolution and all waivers shall survive the expiry or termination of this Agreement.
