Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:
(a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv);
(b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13);
(c) occurrence of a Force Majeure Event;
(d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and
(e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement.
(ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder.
(iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim.
(iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension.
(v) If the event or circumstance giving rise to the notice has a continuing effect:
(a) a fully detailed claim shall be considered as interim;
(b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and
(c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof
Time for Completion The Contractor shall deliver the material and/or services called for in the specifications/proposal and within the delivery time specified and in accordance with the terms of the contract. Work shall be completed within 30 days from the Notice to Proceed issued by the City of Sparks Purchasing Division. The Contractor shall not alter or vary any terms or conditions contained or incorporated herein, including but not limited to, the quantity, price, delivery date or date designated as After Receipt of Order (ARO) or date for commencement or completion of services as mutually agreed upon, unless such alteration or variation is consented to in writing by a duly authorized representative of the City. The City reserves the right to cancel resultant Contract upon ten days written notice in the event the type and quality of the product or work performance is unsatisfactory or in default, subject to Contractor’s right to cure as outlined in termination clause. This is a non-exclusive Contract and the City reserves the right to acquire the material and/or services at its discretion, from other sources during the term of this Contract.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Time for Compliance Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurance required under this section. Failure to provide and maintain all required insurance shall be grounds for the City to terminate this Agreement for cause.
TIME OF COMMENCEMENT AND COMPLETION 2.1 The Contractor shall commence the Work upon the date established in the Notice to Proceed.
2.2 The Contractor shall achieve Final Completion, as defined in Section 105.01, Contract Time, Notice of Contract Execution and Notice to Proceed of the Loudoun County Revisions to the 0000 XXXX Xxxx & Bridge Specifications, Division I - General Provisions, within one hundred and eighty (180) calendar days from the date specified in the Notice to Proceed. This time period shall be designated the Contract Time. The Notice to proceed will be issued approximately than thirty (30) days after the execution of this agreement. The Contractor agrees that the time for completion of the Work as described in the Contract Documents shall govern unless specifically amended in writing by the County, and that no claims for early completion are allowed to be presented by the Contractor to the County.
2.3 The County specifies that time is of the essence under this Contract. Time being of the essence, it is essential to the County that Contract work will be completed within the Contract Time. The County and the Contractor agree that damages for failure to complete the work within the Contract Time are not susceptible to exact determination but that $600 per day is in proportion to the actual loss that the County would suffer from such delay. Therefore, the Contractor will pay the County on demand $600 per day for each and every day beyond the one hundred and eighty (180) calendar days, or modified date of completion, that the County determines that work is not complete, as damages caused by such delay and not as a penalty. The County shall be entitled to offset liquidated damages against any sum owed by the County to the Contractor under this Contract.
2.4 The amount of liquidated damages set forth in Articles 2.3 above shall be assessed cumulatively. This provision for liquidated damages does not bar County's right to enforce other rights and remedies against Contractor, which are otherwise legally enforceable, including but not limited to, specific performance or injunctive relief.
2.5 The Contractor hereby waives any defense as to the validity of any liquidated damages stated in this Agreement as they may appear on grounds that such liquidated damages are void as penalties or are not reasonably related to actual damages.
Annual Compliance Statements The Master Servicer, the Special Servicer, the Certificate Administrator, the Custodian and, if it has made an Advance during the applicable calendar year, the Trustee shall furnish (and each of the Master Servicer, the Special Servicer, the Custodian and the Certificate Administrator (i) with respect to any Additional Servicer of such party that is a Mortgage Loan Seller Sub-Servicer, shall use commercially reasonable efforts to cause such Additional Servicer to furnish, and (ii) with respect to any other Additional Servicer of such party (other than any party to this Agreement), shall cause such Additional Servicer to furnish) (each such Additional Servicer and each of the Master Servicer, the Special Servicer, the Custodian, the Certificate Administrator and the Trustee (if applicable), a “Certifying Servicer”) to the Certificate Administrator, the Serviced Companion Loan Holders (or, in the case of a Serviced Companion Loan that is part of an Other Securitization Trust, the applicable Other Depositor and Other Exchange Act Reporting Party), the Operating Advisor (only in the case of an Officer’s Certificate furnished by the Special Servicer and after the occurrence and during the continuance of a Control Termination Event) and the Depositor on or before March 1 of each year, commencing in March 2017, an Officer’s Certificate (together with a copy thereof in XXXXX compatible format, or in such other format as otherwise agreed upon by the Depositor, the Certificate Administrator, the applicable Other Depositor, the applicable Other Exchange Act Reporting Party and the applicable Certifying Servicer) stating, as to the signer thereof, that (A) a review of such Certifying Servicer’s activities during the preceding calendar year or portion thereof and of such Certifying Servicer’s performance under this Agreement, or the applicable Sub-Servicing Agreement or primary servicing agreement in the case of an Additional Servicer, has been made under such officer’s supervision and (B) to the best of such officer’s knowledge, based on such review, such Certifying Servicer has fulfilled all its obligations under this Agreement, or the applicable Sub-Servicing Agreement or primary servicing agreement in the case of an Additional Servicer, in all material respects throughout such year or portion thereof, or, if there has been a failure to fulfill any such obligation in any material respect, specifying each such failure known to such officer and the nature and status thereof. The Master Servicer and the Special Servicer shall, and the Master Servicer and the Special Servicer shall cause (or, in the case of an Additional Servicer that is a Mortgage Loan Seller Sub-Servicer, shall use its commercially reasonable efforts to cause) each Additional Servicer hired by it to, forward a copy of each such statement to, prior to the occurrence and continuance of a Consultation Termination Event, the Controlling Class Representative and, for posting to the Rule 17g-5 Information Provider’s Website pursuant to Section 12.13, the Rule 17g-5 Information Provider. Promptly after receipt of each such Officer’s Certificate, the Depositor (and, in the case of a Serviced Companion Loan that is part of an Other Securitization Trust, the applicable Other Depositor and Other Exchange Act Reporting Party) may review each such Officer’s Certificate and, if applicable, consult with the Certifying Servicer, as applicable, as to the nature of any failures by such Certifying Servicer, respectively, or any related Additional Servicer with which the Master Servicer or the Special Servicer, as applicable, has entered into a servicing relationship with respect to the Mortgage Loans or the Companion Loans in the fulfillment of any Certifying Servicer’s obligations hereunder or under the applicable sub-servicing or primary servicing agreement. The obligations of each Certifying Servicer under this Section apply to each Certifying Servicer that serviced a Mortgage Loan or Companion Loan during the applicable period, whether or not the Certifying Servicer is acting in such capacity at the time such Officer’s Certificate is required to be delivered. With respect to each Outside Serviced Mortgage Loan serviced under the applicable Outside Servicing Agreement, the Certificate Administrator shall request, and upon receipt deliver to the Depositor, from a “Servicing Officer” or “Responsible Officer” (as such terms are defined in the applicable Outside Servicing Agreement), as applicable, of the related Outside Servicer, Outside Special Servicer, Outside Custodian, Outside Trustee and Outside Paying Agent or Outside Certificate Administrator an Officer’s Certificate in form and substance similar to the Officer’s Certificate described in this Section or such other form as is set forth in the Outside Servicing Agreement.
DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION § 3.1 The date of commencement of the Work shall be:
§ 3.2 The Contract Time shall be measured from the date of commencement of the Work.
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
Certification of Meeting or Exceeding Tobacco-Free Workplace Policy Minimum Standards A. Grantee certifies that it has adopted and enforces a Tobacco-Free Workplace Policy that meets or exceeds all of the following minimum standards of:
i. Prohibiting the use of all forms of tobacco products, including but not limited to cigarettes, cigars, pipes, water pipes (hookah), bidis, kreteks, electronic cigarettes, smokeless tobacco, snuff and chewing tobacco;
ii. Designating the property to which this Policy applies as a "designated area,” which must at least comprise all buildings and structures where activities funded under this Grant Agreement are taking place, as well as Grantee owned, leased, or controlled sidewalks, parking lots, walkways, and attached parking structures immediately adjacent to this designated area;
iii. Applying to all employees and visitors in this designated area; and
iv. Providing for or referring its employees to tobacco use cessation services.
B. If Grantee cannot meet these minimum standards, it must obtain a waiver from the System Agency.
Additional Compliance If any Proposed Key Holder Transfer is not consummated within forty-five (45) days after receipt of the Proposed Transfer Notice by the Company, the Key Holders proposing the Proposed Key Holder Transfer may not sell any Transfer Stock unless they first comply in full with each provision of this Section 2. The exercise or election not to exercise any right by any Investor hereunder shall not adversely affect its right to participate in any other sales of Transfer Stock subject to this Section 2.2.
