Time Extension CONTRACTOR shall provide a time extension request on completion of Task Order for delays caused by others (Permitting Agencies, COUNTY or Contract Cities, or unforeseen conditions such as inclement weather, etc.) and at no fault by CONTRACTOR, subject to approval by COUNTY. COUNTY will review the request and determine in its sole discretion whether the situation warrant a time extension at no-cost or with costs. If CONTRACTOR completes the Task Order beyond the stipulated completion date without COUNTY’s specific written approval for time extension, CONTRACTOR will be subject to liquidated damages and may be construed as non-responsive, which may affect CONTRACTOR for considerations for future Task Orders or projects.
Trial Service Period An employee who has satisfactorily completed their probationary period and who is subsequently appointed to a position in another classification shall serve a twelve (12) month trial service period, in accordance with Section 10.1.3. 10.4.1 The trial service period shall provide the department with the opportunity to observe the employee's work and to train and aid the employee in adjustment to the position, and to revert such an employee whose work performance fails to meet required standards. 10.4.2 An employee who has been appointed from one classification to another classification within the same or different department and who fails to satisfactorily complete the trial service period shall be reverted to a vacant position within that department and classification from which the employee was appointed. 10.4.3 Where no such vacancy exists, such employee shall be given fifteen (15) calendar days' written notice prior to being placed on a Reversion Recall List for their former department and former classification and being removed from the payroll. 10.4.4 An employee’s trial service period may be extended up to three (3) additional months by written mutual agreement between the department, the employee and the Union, subject to approval by the Seattle Human Resources Director prior to expiration of the trial service period. 10.4.5 Employees who have been reverted during the trial service period shall not have the right to appeal the reversion. 10.4.6 The names of regular employees who have been reverted for purposes of re- employment in their former department shall be placed upon a Reversion Recall List for the same classification from which they were promoted or transferred for a period of one (1) year from the date of reversion. 10.4.7 If a vacancy is to be filled in a department and a valid Reversion Recall List for the classification for that vacancy contains the name(s) of eligible employees who have been removed from the payroll from that classification and from that department, such employees shall be reinstated in order of their length of service in that classification. The employee who has the most service in that classification shall be the first reinstated. 10.4.8 An employee whose name is on a Valid Reversion Recall List for a specific job classification who accepts employment with the City in that same job classification shall have their name removed from the Reversion Recall List. Refusal to accept placement from a Reversion Recall List to a position the same, or essentially the same, as that which the employee previously held shall cause an employee’s name to be removed from the Reversion Recall List, which shall terminate rights to reemployment under this Reversion Recall List provision. 10.4.9 An employee whose name is on a valid Reversion Recall List who accepts employment with the City in another class and/or department shall have their name removed from the Reversion Recall List. 10.4.10 A reverted employee shall be paid at the step of the range which the employee normally would have received had the employee not been appointed.
TRIAL SERVICE Section 1. Each employee appointed to a position in the bargaining unit shall serve a trial service period upon: • initial appointment to state service; • promotion; • lateral transfer inside his/her Agency to a different classification; • lateral transfer between agencies; • or rehire within two (2) years of separation (including reemployment). Section 2. The trial service period is recognized as an extension of the selection process and is the time immediately following appointment and shall not exceed six (6) full months. For part-time employees trial service shall be 1,040 hours. Trial service will be nine (9) months for employees hired in the classification of Child Support Case Manager (Entry) in DOJ; Client Care Surveyor and Disability Analyst (Entry). Trial service will be twelve (12) months for new employees hired as Industrial Hygienist 1 and 2, Occupational Safety Specialist 1 and 2 in DCBS, and Adult Protective Service Specialist in Department of Human Services. Section 3. The supervisor shall evaluate the employee’s work habits and ability to perform his/her duties satisfactorily and provide the employee feedback within the trial service period. Trial service may be extended in instances where a trial service employee has been on a cumulative leave without pay for fifteen (15) days or more and then only by the number of days the employee was on such leave, or when the Appointing Authority has established a professional or technical training program for positions requiring graduation from a four (4) year college or university or the satisfactory equivalent thereof in training and experience, including but not limited to the training of accountants and auditors, and which is for the purpose of developing the skills or knowledge necessary for competent job performance in the specialized work of such Authority, the employee may be required to train under such program for a period not exceeding six (6) months and the trial service period for such employee shall be the length of the approved training program plus six (6) full months. An employee’s trial service may also be extended for the purpose of developing the skills and/or knowledge necessary for competent job performance. Written notice of the extension will be provided to the employee and a copy of the extension shall be forwarded to SEIU Headquarters and the Labor Relations Unit. Section 4. When, in the judgment of the Appointing Authority, performance has been adequate to clearly demonstrate the competence and fitness of the trial service employee, the Appointing Authority may at any time appoint the employee to regular status. Section 5. Trial service employees may be removed from service when, in the judgment of the Appointing Authority, the employee is unable or unwilling to perform his/her duties satisfactorily or his/her habits and dependability do not merit continuance in the service. Section 6. An employee who is removed from trial service following a lateral transfer or a promotion shall have the right of return to the Agency and the classification or comparable salary level, which the employee previously held, unless charges are filed and he/she is discharged as provided in Article 20--
Time Extensions 2.03.1 If Contractor requests an extension of time to complete its performance, then the Director, in consultation with the CPO, may, in his or her sole discretion, extend the time so long as the extension does not exceed 90 days. The extension must be in writing but does not require amendment of this Agreement. Contractor is not entitled to damages for delay(s) regardless of the cause of the delay(s).
Territorial Extension At the time of signature of this Agreement, or at any time thereafter, the provisions of this Agreement may be extended to such territories for whose international relations the Government of the United Kingdom are responsible as may be agreed between the Contracting Parties in an Exchange of Notes.
Lease Extension Lessee may request Lessor to extend the original Scheduled Expiration Date of each Lease Agreement for an additional period of three (3) years by appropriately completing, executing and delivering to Agent a written request in the form of Exhibit G(2), together with an attachment thereto setting forth the terms upon which Lessee would propose for the requested extension (a "Lease Extension Request"). Lessee shall deliver each Lease Extension Request to Agent not more than twelve (12) months and not less than nine (9) months before the original Scheduled Expiration Date. Agent shall promptly deliver to Lessor and each Participant three (3) copies of each Lease Extension Request received by Agent. If Lessor or a Participant, in its sole and absolute discretion, consents to a Lease Extension Request, such Person shall evidence such consent by executing and returning two (2) copies of such Lease Extension Request to Agent not later than the last Business Day which is not less than seven (7) months prior to the original Scheduled Expiration Date for the applicable Lease Agreement. Any failure by Lessor or any Participant so to execute and return a Lease Extension Request shall be deemed a denial thereof. If Lessee shall deliver a Lease Extension Request to Lessor pursuant to the first sentence of this Subparagraph 2.09(b), then not later than the last Business Day which is not less than six (6) months prior to the original Scheduled Expiration Date for the applicable Lease Agreement, Agent shall notify Lessee, Lessor and the Participants in writing whether (i) Agent has received a copy of the Lease Extension Request executed by Lessor and each Participant, in which case the definition of "Scheduled Expiration Date" set forth in Subparagraph 2.02(a) of the applicable Lease Agreement shall be deemed extended to the date which is three (3) years after the original Scheduled Expiration Date (subject to the receipt by Agent of any amounts payable by Lessee in connection with such extension), or (ii) Agent has not received a copy of the Lease Extension Request executed by Lessor and each Participant, in which case such Lease Extension Request shall be deemed denied. Lessee acknowledges that neither Lessor nor any Participant has promised (either expressly or implicitly), or has any obligation or commitment, to extend or consent to the extension of the Scheduled Expiration Date for either Lease Agreement at any time.
Contract Extension The City may, in its sole discretion, unilaterally exercise an option to extend the Contract as described in the Contract Documents. In addition, the City may, in its sole discretion, unilaterally extend the Contract on a month-to-month basis following contract expiration if authorized under Charter section 99 and the Contract Documents. Contractor shall not increase its pricing in excess of the percentage increase described in the Contract.
Renewal, Extension The renewal or extension of any Letter of Credit shall, for purposes hereof, be treated in all respects the same as the issuance of a new Letter of Credit hereunder.
Term of Contract; Contract Extension The Contract will be in effect from the Effective Date (15 December 2016) through 31 December 2018. DAS, in its sole discretion, may extend this Contract for additional terms beyond the original term, prior to Termination or expiration, one or more times for a combined total period not to exceed the complete length of the original term.
Patent Extensions Subject to the remainder of this Section 6.6, if any election for patent term restoration or extension, supplemental protection certificate or any of their equivalents may be made with respect to any Patent within the Licensed IP, after consultation with Celgene, the Parties will discuss and seek to reach mutual agreement whether or not to take such action. If the Parties are not able to reach mutual agreement, (a) Celgene will have the sole right to make the final decision whether or not to seek such patent term restoration or extension, supplemental protection certificate or any of their equivalents with respect to Specific Patents and Patents within the Collaboration IP licensed to Celgene hereunder and (b) Bluebird will have the sole right to make the final decision whether or not to seek such patent term restoration or extension, supplemental protection certificate or any of their equivalents with respect to all other Patents within the Licensed IP.
