PARTIAL OCCUPANCY OR USE 9.9.1 The Owner may occupy or use any completed or partially completed portion of the Work at any stage when such portion is designated by separate agreement with the Contractor, provided such occupancy or use is consented to by the insurer as required under Paragraph 11.3.1.5, the surety, and authorized by public authorities having jurisdiction over the Project. Such partial occupancy or use may commence whether or not the portion is substantially complete, provided the Owner and Contractor have accepted in writing the responsibilities assigned to each of them for payments, retainage, if any, security, maintenance, heat, utilities, damage to the Work and insurance, and have agreed in writing concerning the period for correction of the Work and commencement of warranties required by the Contract Documents. When the Contractor considers a portion substantially complete, the Contractor shall prepare and submit a list to the Architect as provided under Paragraph 9.8.2. Consent of the Contractor to partial occupancy or use shall not be unreasonably withheld.
9.9.2 Immediately prior to partial occupancy or use, the Owner, Contractor and Architect shall jointly inspect the area to be occupied or portion of the Work to be used in order to determine and record the condition of the Work.
9.9.3 Partial occupancy or use of a portion or portions of the Work shall not constitute acceptance of Work not complying with the requirements of the Contract Documents.
Early Occupancy If Tenant occupies the Property prior to the Commencement Date, Tenant's occupancy of the Property shall be subject to all of the provisions of this Lease. Early occupancy of the Property shall not advance the expiration date of this Lease. Tenant shall pay Base Rent and all other charges specified in this Lease for the early occupancy period.
Beneficial Occupancy A. The County may, at any time, and from time to time, during the performance of the Work, enter the structure for the purpose of installing any necessary Work by County labor of other contracts, and for any other purpose in connection with the installation of facilities. In doing so, the County shall endeavor not to interfere with the Contractor and the Contractor shall not interfere with other Work being done by or on behalf of the County.
B. If, prior to completion and Final Acceptance of all the Work under a specific Job Order, the County takes possession of any structure (whether completed or otherwise) comprising a portion of that Project with the intent of retaining possession thereof (as distinguished from temporary possession contemplating the return to the Contractor), then, while the County is in possession of the same, the Contractor, notwithstanding its normal responsibilities, shall be relieved of liability for loss or damage to structure other than that resulting from the Contractor's fault or negligence. Such taking of possession by the County shall not relieve the Contractor from any provisions of this Contract respecting such structure, other than to the extent specified in the preceding sentence, nor constitute a final acceptance of such structure.
Maximum Occupancy No more than two (2) guests per one (1) resident (who is present) are permitted in a student room/suite/apartment at any given time unless otherwise approved by the University (Residential Life).
Ready for Occupancy For purposes of Section 1.3.2 of this Agreement, the Premises shall be deemed “Ready for Occupancy” upon the substantial completion of the Tenant Improvement Work. Subject to Section 4.2 below, the Tenant Improvement Work shall be deemed to be “substantially complete” upon the completion of the Tenant Improvement Work pursuant to the Approved Construction Drawings (as reasonably determined by Landlord), with the exception of any details of construction, mechanical adjustment or any other similar matter the non-completion of which does not materially interfere with Tenant’s use of the Premises.
NUMBER OF OCCUPANTS Tenant agrees that the House shall be occupied by no more than [Total Number of Occupants] persons, including no more than [Maximum Number of Children] under the age of eighteen (18) years, without the prior written consent of Landlord.
Possession and Occupancy The Seller will deliver possession and occupancy of the Property to the Buyer at Closing. The Seller shall provide access to all locks, including keys, remote controls, and any security/access codes, necessary to operate all locks, mailboxes, and security systems.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Occupancy After Foreclosure Any sale of the Mortgaged Property or any part thereof will divest all right, title and interest of Mortgagor in and to the property sold. Subject to applicable law, any purchaser at a foreclosure sale will receive immediate possession of the property purchased. If Mortgagor retains possession of such property or any part thereof subsequent to such sale, Mortgagor will be considered a tenant at sufferance of the purchaser, and will, if Mortgagor remains in possession after demand to remove, be subject to eviction and removal, forcible or otherwise, with or without process of law.
USE AND OCCUPANCY Tenant shall use and occupy the Demised Premises for the commercial purpose of ____________________________________________________________ [Description of commercial purpose] and related activities. The Demised Premises shall be used for no other purpose without the advance written consent of Landlord. Tenant shall operate the Demised Premises in a clean and dignified manner and in compliance with all applicable laws, regulations, rules, and ordinances. Janitorial Services (Check one) ☐ Tenant shall provide its own janitorial services. ☐ As agreed by both parties, Landlord shall provide janitorial services and shared costs will be included in the Operating Cost. Tenant shall use the Demised Premises for no unlawful purpose or act; shall commit or permit no waste or damage to the Demised Premises; shall, at Tenant’s expense, comply with and obey all applicable laws, regulations, or orders of any governmental authority or agency; shall not do or permit anything to be done in or about the Demised Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Real Property; and shall comply with all the rules and requirements promulgated by Landlord with respect to the Real Property, as the same may be amended from time to time. Tenant agrees as follows: (Check all that apply)
☐ I. All loading and unloading, delivery and shipping of goods shall be conducted in such areas and through the entrances designated by Landlord.
☐ II. No window coverings, such as curtains, blinds or shades, shall be placed on the windows of Demised Premises unless approved by Landlord.
☐ III. No smoking in the Demised Premises or within __________ feet or any doorway.
☐ IV. All garbage and refuse shall be kept in the size and kind of container, and in a location approved by Landlord. Tenant shall not burn any trash or garbage in or about the Real Property.
☐ V. No aerial, loudspeaker, satellite dish, sound amplifier, equipment, displays, or advertising shall be erected on the roof or exterior walls of the Demised Premises, or on other areas of the Real Property without the prior written consent of Landlord.
☐ VI. No loudspeaker, television, phonograph, juke-box, radio, or other device shall be used in a manner so as to be heard other than by persons who are within the Demised Premises without the prior written consent of Landlord.
☐ VII. No activity will take place on the Demised Premises or common areas which shall cause any odor which can be smelled other than by persons who are within the Demised Premises.
☐ VIII. Tenant shall keep the Demised Premises at a temperature sufficiently high to prevent freezing of water in pipes and fixtures.
☐ IX. Tenant shall not permit or place any obstructions or merchandise in any common areas, including but not limited to, corridors, all sidewalks in front of, on the side of, or in the back of the Demised Premises.
☐ X. The plumbing facilities in the Demised Premises shall not be used for any purpose other than that for which they are constructed, and no foreign substance of any kind shall be thrown therein, and the expense of any breakage, stoppage, or damage resulting from a violation of this provision shall be borne by Tenant. Tenant shall be responsible for the proper and lawful disposal of all cooking grease used within the Demised Premises.
☐ XI. Tenant shall keep all windows, window xxxxx, window frames and exterior signs of the Demised Premises clean.
☐ XII. No merchandise shall be stored in the Demised Premises except that which Tenant is selling in the normal course of business in, at, or from the Demised Premises.
☐ XIII. No auctions or tent sales shall be held within the Demised Premises or on or within any portion of the Real Property, except with the prior written consent of Landlord.
☐ XIV. Landlord shall have the right to prohibit the continued use by Tenant of any unethical or unfair method of business operation, advertising or interior display if, in Landlord’s opinion, the continued use thereof would impair the reputation of the Real Property as a first class facility or is otherwise out of harmony with the general character thereof, and upon notice from Landlord shall forthwith refrain from or discontinue such activities.
☐ XV. Tenant shall keep the Demised Premises (including without limitation, exterior and interior portions of all windows, doors and all other glass) in a neat, clean and sanitary condition, free of all insects, rodents, vermin and pests of every type and kind.
☐ XVI. Tenant shall not use the Demised Premises for any purpose or business which is noxious or unreasonably offensive because of the emission of noise, smoke, dust or odors.
☐ XVII. Tenant shall keep the entry ways and sidewalk/walkway in front of the Demised Premise clear of all debris, trash and litter, and shall keep the same swept, maintained and snow and ice removed therefrom.
