Uncontrollable Circumstance Relief Associated with Permitting Obligations Sample Clauses

Uncontrollable Circumstance Relief Associated with Permitting Obligations. The Company shall be entitled to seek equitable Uncontrollable Circumstance relief in accordance with and to the extent provided herein in the event that: (1) the Company is delayed in the performance of the Design/Build Work due to a third party challenge to an “agency action”, as defined in Chapter 120 of Title X of the Florida Statutes, in connection with any Governmental Approval; (2) a Governmental Authority fails to comply with Applicable Law in connection with a Governmental Approval application; (3) the imposition of arbitrary and capricious terms and conditions in connection with a Governmental Approval; or (4) (i) the Company has complied with the requirements of this Agreement, (ii) the Company has timely submitted all applications, data, studies, reports, responses and other information required under Applicable Law and the adopted administrative practice of the Governmental Authority, or requested by the Governmental Authority, in order to obtain the Governmental Approval, (iii) the Company has in all respects used its best efforts to obtain the Governmental Approvals, (iv) the Company has consistently maintained a fully responsive and engaged professional relationship with the staff and management of the Governmental Authority in a manner that, while not expressly required by Applicable Law, is generally recognized among regular practitioners in the permitting field as necessary on a practical level to secure similar permits in a timely manner in light of the discretion afforded Governmental Authorities, and (v) there has been a failure to issue a Governmental Approval by the Assumed Approval Issuance Date set forth in the approved Project Schedule and in section 6.9.8. Any price relief associated with a Governmental Authority delay under this subsection shall be limited to the Company’s reasonable daily general conditions costs, subject to Cost Substantiation by the Company, for the number of days of delay caused by the applicable Governmental Authority but only to the extent any such Governmental Authority delay actually causes a material delay in the Company’s CPM Schedule after the exercise of all commercially reasonable mitigation efforts by the Company.
Sample 1
AutoNDA by SimpleDocs

Related to Uncontrollable Circumstance Relief Associated with Permitting Obligations

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11: (a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event; (b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5; (c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party. (d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.

  • Termination Notice for Force Majeure Event If a Force Majeure Event subsists for a period of 180 (one hundred and eighty) days or more within a continuous period of 365 (three hundred and sixty five) days, either Party may in its discretion terminate this Agreement by issuing a Termination Notice to the other Party without being liable in any manner whatsoever, save as provided in this Article 34, and upon issue of such Termination Notice, this Agreement shall, notwithstanding anything to the contrary contained herein, stand terminated forthwith; provided that before issuing such Termination Notice, the Party intending to issue the Termination Notice shall inform the other Party of such intention and grant 15 (fifteen) days time to make a representation, and may after the expiry of such 15 (fifteen) days period, whether or not it is in receipt of such representation, in its sole discretion issue the Termination Notice.

  • Action if Other Event of Default If any Event of Default (other than any Event of Default described in clauses (b) through (d) of Section 8.1.5 with respect to the Borrower) shall occur for any reason, whether voluntary or involuntary, and be continuing, the Facility Agent, upon the direction of the Required Lenders, shall by notice to the Borrower declare all of the outstanding principal amount of the Loan and other Obligations to be due and payable and/or the Commitments (if not theretofore terminated) to be terminated, whereupon the full unpaid amount of the Loan and other Obligations shall be and become immediately due and payable, without further notice, demand or presentment, and/or, as the case may be, the Commitments shall terminate.

  • Individual Special Circumstance Arrangements Notwithstanding Article 2.02, the Home and the Union may agree in certain circumstances, to adjust the schedule of an individual full-time employee who normally works seventy five (75) hours bi-weekly, to enable an average bi-weekly work assignment of sixty (60) to seventy five (75) hours. (a) Such an arrangement shall be established by mutual agreement of the Home and the Union and the employee affected. The parties agree that the arrangement applies to an individual, not to a position. The parties will agree to the scheduling provisions that will apply to the employee including that no additional shifts will be scheduled for employees working Individual Special Circumstances Arrangements. (b) The parties shall determine the introduction of a special circumstance arrangement. Issues related to vacation, paid holidays and benefit coverage will be determined by the Home and the Union. The employee will retain full-time status, including but not limited to seniority and service. (c) Any party may discontinue the special circumstance arrangement with notice as determined within the agreement. In the event that the employee affected resigns, transfers, is laid off or terminated, the arrangement will be deemed to be discontinued immediately, unless the parties mutually agree otherwise. (d) It is understood and agreed that these arrangements are based on individual circumstances and each agreement is made on a without prejudice or precedent basis.

  • BUSINESS CONTINUITY/DISASTER RECOVERY In the event of equipment failure, work stoppage, governmental action, communication disruption or other impossibility of performance beyond State Street’s control, State Street shall take reasonable steps to minimize service interruptions. Specifically, State Street shall implement reasonable procedures to prevent the loss of data and to recover from service interruptions caused by equipment failure or other circumstances with resumption of all substantial elements of services in a timeframe sufficient to meet business requirements. State Street shall enter into and shall maintain in effect at all times during the term of this Agreement with appropriate parties one or more agreements making reasonable provision for (i) periodic back-up of the computer files and data with respect to the Trusts; and (ii) emergency use of electronic data processing equipment to provide services under this Agreement. State Street shall test the ability to recover to alternate data processing equipment in accordance with State Street program standards, and provide a high level summary of business continuity test results to the Trusts upon request. State Street will remedy any material deficiencies in accordance with State Street program standards. Upon reasonable advance notice, and at no cost to State Street, the Trusts retain the right to review State Street’s business continuity, crisis management, disaster recovery, and third-party vendor management processes and programs (including discussions with the relevant subject matter experts and an on-site review of the production facilities used) related to delivery of the service no more frequently than an annual basis. Upon reasonable request, the State Street also shall discuss with senior management of the Trusts any business continuity/disaster recovery plan of the State Street and/or provide a high-level presentation summarizing such plan.”

  • Contract Renegotiation, Suspension, or Termination Due to Change in Funding If the funds DSHS relied upon to establish this Contract or Program Agreement are withdrawn, reduced or limited, or if additional or modified conditions are placed on such funding, after the effective date of this contract but prior to the normal completion of this Contract or Program Agreement: a. At DSHS’s discretion, the Contract or Program Agreement may be renegotiated under the revised funding conditions. b. At DSHS’s discretion, DSHS may give notice to Contractor to suspend performance when DSHS determines that there is reasonable likelihood that the funding insufficiency may be resolved in a timeframe that would allow Contractor’s performance to be resumed prior to the normal completion date of this contract. (1) During the period of suspension of performance, each party will inform the other of any conditions that may reasonably affect the potential for resumption of performance. (2) When DSHS determines that the funding insufficiency is resolved, it will give Contractor written notice to resume performance. Upon the receipt of this notice, Contractor will provide written notice to DSHS informing DSHS whether it can resume performance and, if so, the date of resumption. For purposes of this subsubsection, “written notice” may include email. (3) If the Contractor’s proposed resumption date is not acceptable to DSHS and an acceptable date cannot be negotiated, DSHS may terminate the contract by giving written notice to Contractor. The parties agree that the Contract will be terminated retroactive to the date of the notice of suspension. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the retroactive date of termination. c. DSHS may immediately terminate this Contract by providing written notice to the Contractor. The termination shall be effective on the date specified in the termination notice. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the effective date of termination. No penalty shall accrue to DSHS in the event the termination option in this section is exercised.

  • Termination Payment for Force Majeure Event 30.9.1 If Termination is on account of a Non-Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to 55% (fifty five per cent) of the Debt Due less Insurance Cover. 30.9.2 If Termination is on account of an Indirect Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to: (a) 55% of the Debt Due less Insurance Cover; provided that if any insurance claims forming part of the Insurance Cover are not admitted and paid, then 80% (eighty per cent) of such unpaid claims shall be included in the computation of Debt Due; (b) 60.5% (sixty point five per cent) of the Adjusted Equity; and 30.9.3 If Termination is on account of a Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount that would be payable under Clause 33.3.2 as if it were Authority’s Default.

  • T ermination In the event that either party seeks to terminate this DPA, they may do so by mutual written consent and as long as any service agreement or terms of service, to the extent one exists, has lapsed or has been terminated. The LEA may terminate this DPA and any service agreement or contract with the Provider if the Provider breaches any terms of this DPA.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!