Modification of the Small Generating Facility The Interconnection Customer must receive written authorization from the NYISO and Connecting Transmission Owner before making any change to the Small Generating Facility that may have a material impact on the safety or reliability of the New York State Transmission System or the Distribution System. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the Interconnection Customer makes such modification without the prior written authorization of the NYISO and Connecting Transmission Owner, the Connecting Transmission Owner shall have the right to temporarily disconnect the Small Generating Facility. If disconnected, the Small Generating Facility will not be reconnected until the unauthorized modifications are authorized or removed.
Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.
Prohibited Signage and Other Items Any signs, notices, logos, pictures, names or advertisements which are installed and that have not been separately approved by Landlord may be removed without notice by Landlord at the sole expense of Tenant. Tenant may not install any signs on the exterior or roof of the Project or the Common Areas. Any signs, window coverings, or blinds (even if the same are located behind the Landlord-approved window coverings for the Building), or other items visible from the exterior of the Premises or Building, shall be subject to the prior approval of Landlord, in its sole discretion.
Additions and Alterations After Substantial Completion of the Facility and Leased Premises, Lessee shall have the right to make, at Lessee’s sole cost and expense, additions, alterations, and changes ("Alterations"), in or to the Leased Premises or the Improvements, provided Lessee shall not then be in default in the performance of any of Lessee's covenants or agreements in this Lease, subject, however, in all cases to the following:
(1) No Alterations of any kind shall be made without the prior written consent of Lessor if the Alterations would tend to: (a) change the general character or structure of the Improvements on the Leased Premises, or (b) reduce or impair the value, rental, rental value, rentability, or usefulness of the Leased Premises or the Improvements or any part of same;
(2) No Alterations shall be undertaken until Lessee shall have procured and paid for, to the extent the same may be required from time to time, all permits and authorizations of all municipal departments and governmental subdivisions having jurisdiction, and complied with all other laws, statutes, codes, ordinances, orders, rules, regulations, permits, or licenses relating to the Alterations;
(3) Any structural Alterations involving in the aggregate an estimated cost of more than $ shall be conducted under the supervision of an architect or engineer selected by Lessee and approved in advance and in writing by Lessor (which approval shall not be unreasonably withheld or delayed). No such structural Alterations shall be made, except in accordance with detailed plans and specifications and cost estimates prepared and approved in writing by such architect or engineer and approved in advance and in writing by Lessor (which approval shall not be unreasonably withheld or delayed). In the event of Lessor's disapproval, Lessor shall give to Lessee an itemized statement of reasons for the disapproval. If Lessor does not disapprove the plans and specifications provided for in this paragraph within fifteen (15) days after they have been submitted to Lessor, the plans and specifications shall be deemed to have been approved by Lessor. Prior to commencing any work under this Section 11, Lessee shall furnish Lessor, on demand, with a good and sufficient surety bond insuring the completion of the work and the payment of all bills in connection with the work.
(4) Any Alterations shall be made promptly, subject to Force Majeure Delay, and in a good and workmanlike manner and in compliance with all applicable laws, statutes, codes, ordinances, orders, rules, regulations, permits, or licenses, and all insurance policy provisions and requirements;
(5) The cost of any such alterations shall be paid solely by Lessee in cash or its equivalent, including the cost of labor and materials supplied to the Leased Premises or the Improvements;
(6) Workers' compensation insurance covering all persons employed in connection with the Alteration work and with respect to whom death or bodily injury claims could be asserted against Lessor, Lessee, or the Leased Premises or the Improvements, and commercial general liability insurance for the mutual benefit of Lessor and Lessee with limits of not less than $ in the event of bodily injury or death to one person and not less than $ in the event of bodily injury or death to any number of persons in any one accident, and with limits of not less than $ for damages or injury to property, with not more than a $ deductible, shall be maintained by Lessee at Lessee's sole cost and expense at all times when any substantial work is in progress in connection with any Alterations. All such insurance, if readily obtainable, shall be effected under standard form policies issued by insurers of recognized responsibility, which are duly licensed to issue such insurance in the State of Oklahoma and well rated by national rating organizations. SECTION TWELVE INSPECTIONS Lessee shall permit Lessor, Lessor’s agents, employees, and contractors to enter all parts of the Leased Premises and the Improvements during Lessee's regular business hours to inspect the same and to enforce or carry out any provisions of this Lease, provided Lessee is given reasonable advance notice, which may be verbal (except in an emergency, in which case no notice shall be necessary), and Lessee's Permitted Use shall not be unreasonably interfered with by Lessor during any entry authorized in this Section 12.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Nature of the processing MailChimp provides an email service, automation and marketing platform and other related services, as described in the Agreement.
Management and Operation of Business Section 7.1 Management 47 Section 7.2 Certificate of Limited Partnership 48 Section 7.3 Restrictions on Managing General Partner’s Authority 49 Section 7.4 Reimbursement of the Managing General Partner 49 Section 7.5 Outside Activities 50 Section 7.6 Loans from the Managing General Partner; Loans or Contributions from the Partnership; Contracts with Affiliates; Certain Restrictions on the Managing General Partner 51 Section 7.7 Indemnification 53 Section 7.8 Liability of Indemnitees 54 Section 7.9 Resolution of Conflicts of Interest 55 Section 7.10 Other Matters Concerning the Managing General Partner 57 Section 7.11 Purchase or Sale of Partnership Securities 57 Section 7.12 Registration Rights of the Managing General Partner and its Affiliates 57 Section 7.13 Reliance by Third Parties 59
Termination of Tenancy Any termination of the lease must also comply with all applicable state or local laws, ordinances, regulations, or similar requirements, including as may be applicable emergency orders restricting evictions during declared emergencies or disasters; and Owner/Representative Initials: Tenant Initials:
SCOPE, WAIVER AND ALTERATION OF AGREEMENT (1) No agreement, alteration, understanding, variation, waiver or modification of any of the terms and conditions or covenants herein shall be made by any employee or group of employees with the Board unless executed in writing between the parties hereto and the same has been ratified by the Union and the Board.
(2) The waiver of any breach or condition of this Agreement by either party shall not constitute a precedent in the future enforcement of the terms and conditions herein.
(3) If any Article or Section of this Agreement or any supplement thereto should be held invalid by operation of law or by any tribunal of competent jurisdiction, or if compliance with or enforcement of any Article or Section should be restrained by such tribunal, the remainder of this Agreement and supplements shall not be affected thereby and the parties shall enter into immediate collective bargaining negotiations for the purpose of arriving at a mutually satisfactory replacement for such Article or Section.
Surrender of Premises Ownership and Removal of Trade Fixtures 23.1 No act or thing done by Landlord or any agent or employee of Landlord during the Lease Term shall be deemed to constitute an acceptance by Landlord of a surrender of the Premises unless such intent is specifically acknowledged in writing by Landlord. The delivery of keys to the Premises to Landlord or any agent or employee of Landlord shall not constitute a surrender of the Premises or effect a termination of this Lease, whether or not the keys are thereafter retained by Landlord, and notwithstanding such delivery Tenant shall be entitled to the return of such keys at any reasonable time upon request until this Lease shall have been properly terminated. The voluntary or other surrender of this Lease by Xxxxxx, whether accepted by Landlord or not, or a mutual termination hereof, shall not work a merger, and at the option of Landlord shall operate as an assignment to Landlord of all subleases or subtenancies affecting the Premises or terminate any or all such subtenants or subtenancies.
23.2 Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 23 and section 8.2 above, quit and surrender possession of the Premises to Landlord in as good order and condition as when Xxxxxx took possession, ordinary wear and tear and damage thereto by fire or other casualty excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions, voice and data cabling and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed; provided, however, that in lieu of removing certain cabling, Tenant shall, at Landlord's request, abandon and leave in place, without additional payment to Tenant or credit against rent, any cabling (including conduit) designated by Landlord and installed in the Premises or elsewhere in the Building by or on behalf of Tenant (including all connections for such cabling), in a neat and safe condition in accordance with the requirements of all applicable Legal Requirements, including the National Electric Code or any successor statute, and terminated at both ends of a connector, properly labeled at each end and in each electrical closet and junction box. Any such property not so removed by Tenant shall be deemed to be abandoned and at the option of Landlord shall either (a) become Landlord's property without any payment to Tenant or (b) remain Tenant's property, but Landlord shall have the right to sell or otherwise dispose of such personal property in any commercially reasonable manner, provided that any proceeds realized from the sale of Tenant's property shall be applied first to offset all expenses of storage and sale, then credited against Tenant's outstanding obligations under this Lease (including, without limitation, past due rent amounts and any termination damages owing by Tenant to Landlord pursuant to Article 19 hereof), and any remaining balance shall be returned to Tenant.
