WORK JURISDICTION Par.
1. It is agreed by the parties to this Agreement that all work specified in Article IV shall be performed exclusively by Elevator Constructor Mechanics, Elevator Constructor Helpers, Elevator Constructor Apprentices and Elevator Constructor Assistant Mechanics in the employ of the Company.
(a) The handling and unloading of all equipment coming under the jurisdiction of the Elevator Constructor, from the time such equipment arrives at or near the building site, shall be handled and unloaded by the Elevator Constructors. Mechanical equipment such as a fork lift or truck mounted swing boom may be used by the Elevator Constructors. A xxxxxxx, xxxxx or material hoist can be used under the supervision of Elevator Constructors to handle and unload the heavy material described in Par. 5(a). Where unusual conditions are expected to exist prior to delivery of equipment at or near the building site in regard to handling and unloading of equipment in the primary or secondary jurisdiction of the local union, the Company shall contact the Local's Business Representative to make appropriate arrangements for the handling and unloading of such equipment. In areas outside the jurisdiction of the local union, the Company shall contact the Regional Director.
(b) The erecting and assembling of all elevator equipment to wit: electric, hydraulic, steam, belt, dumbwaiters, residence elevators, parking garage elevators (such as Xxxxxx, Pigeon Hole, or similar types of elevators), shuttles, compressed air and handpower, automatic people movers, monorails, airport shuttles and like-named devices used in the transportation of people for short distances of travel (less than 5 miles), as well as vertical reciprocating conveyor systems.
(c) It is understood and agreed that the preassembly of all escalators, moving stairways and link belt carriers that may be done in the factory shall include the following:
1. Truss or truss sections with tracks, drive units, machines, handrail drive sheaves, drive chains, skirts on the incline sections but not curved sections, step chains and steps installed and permanently aligned.
2. Balustrade brackets may be shipped attached but not aligned.
3. Setting of all controllers and all wiring and conduit from the controller. All other work on escalators, moving stairways and link belt carriers shall be performed in the field by Elevator Constructor Mechanics, Helpers, Apprentices and Assistant Mechanics either before or after the truss or truss sections are joined and/or hoisted and placed in permanent position. This includes any and all work not done in the factory. The erecting and assembly of all theater stage and curtain elevator equipment and guides and rigging thereto, organ consoles and orchestra elevators shall be performed by Elevator Constructor Mechanics, Helpers, Apprentices and Assistant Mechanics.
(d) All wiring, conduit, and raceways from main line feeder terminals on the controller to other elevator apparatus and operating circuits. Controllers are not to be shipped from the factory with extended wiring attached thereto.
(e) The erecting of all guide rails.
(f) The installation of all grating under the control of the Company. The installation of all counterweight screens, overhead work, either wood or iron, and all material used for mounting of elevator apparatus in machine room, overhead or below.
(g) The drilling of overhead beams for attaching machines, sheaves, kick angles, and all other elevator equipment.
(h) The setting of all templates.
(i) All foundations, either of wood or metal, that should take the place of masonry.
(j) The assembly of all cabs complete.
(k) The installation of all indicators.
(1) The erecting of all electrical or mechanical automatic or semi-automatic gates complete.
Litigation; Jurisdiction; Other Matters; Waivers (a) EACH PARTY HERETO ACKNOWLEDGES THAT ANY DISPUTE OR CONTROVERSY BETWEEN OR AMONG THE BORROWER, THE AGENT OR ANY OF THE LENDERS WOULD BE BASED ON DIFFICULT AND COMPLEX ISSUES OF LAW AND FACT AND WOULD RESULT IN DELAY AND EXPENSE TO THE PARTIES. ACCORDINGLY, TO THE EXTENT PERMITTED BY APPLICABLE LAW, EACH OF THE LENDERS, THE AGENT AND THE BORROWER HEREBY WAIVES ITS RIGHT TO A TRIAL BY JURY IN ANY ACTION OR PROCEEDING OF ANY KIND OR NATURE IN ANY COURT OR TRIBUNAL IN WHICH AN ACTION MAY BE COMMENCED BY OR AGAINST ANY PARTY HERETO ARISING OUT OF THIS AGREEMENT, THE NOTES, OR ANY OTHER LOAN DOCUMENT OR BY REASON OF ANY OTHER SUIT, CAUSE OF ACTION OR DISPUTE WHATSOEVER BETWEEN OR AMONG THE BORROWER, THE AGENT OR ANY OF THE LENDERS OF ANY KIND OR NATURE.
(b) THE BORROWER, THE AGENT AND EACH LENDER HEREBY AGREES THAT THE UNITED STATES DISTRICT COURT FOR THE NORTHERN DISTRICT OF GEORGIA, ATLANTA DIVISION OR, AT THE OPTION OF THE AGENT, ANY STATE COURT LOCATED IN ATLANTA, GEORGIA, SHALL HAVE JURISDICTION TO HEAR AND DETERMINE ANY CLAIMS OR DISPUTES BETWEEN OR AMONG THE BORROWER, THE AGENT OR ANY OF THE LENDERS, PERTAINING DIRECTLY OR INDIRECTLY TO THIS AGREEMENT, THE LOANS AND LETTERS OF CREDIT, THE NOTES OR ANY OTHER LOAN DOCUMENT OR TO ANY MATTER ARISING HEREFROM OR THEREFROM. THE BORROWER AND EACH OF THE LENDERS EXPRESSLY SUBMITS AND CONSENTS IN ADVANCE TO SUCH JURISDICTION IN ANY ACTION OR PROCEEDING COMMENCED IN SUCH COURTS. EACH PARTY FURTHER WAIVES ANY OBJECTION THAT IT MAY NOW OR HEREAFTER HAVE TO THE VENUE OF ANY SUCH ACTION OR PROCEEDING IN ANY SUCH COURT OR THAT SUCH ACTION OR PROCEEDING WAS BROUGHT IN AN INCONVENIENT FORUM AND EACH AGREES NOT TO PLEAD OR CLAIM THE SAME. THE CHOICE OF FORUM SET FORTH IN THIS SECTION SHALL NOT BE DEEMED TO PRECLUDE THE BRINGING OF ANY ACTION BY THE AGENT OR ANY LENDER OR THE ENFORCEMENT BY THE AGENT OR ANY LENDER OF ANY JUDGMENT OBTAINED IN SUCH FORUM IN ANY OTHER APPROPRIATE JURISDICTION.
(c) THE PROVISIONS OF THIS SECTION HAVE BEEN CONSIDERED BY EACH PARTY WITH THE ADVICE OF COUNSEL AND WITH A FULL UNDERSTANDING OF THE LEGAL CONSEQUENCES THEREOF, AND SHALL SURVIVE THE PAYMENT OF THE LOANS AND ALL OTHER AMOUNTS PAYABLE HEREUNDER OR UNDER THE OTHER LOAN DOCUMENTS, THE TERMINATION OR EXPIRATION OF ALL LETTERS OF CREDIT AND THE TERMINATION OF THIS AGREEMENT.
Venue; Jurisdiction (a) Any action or proceeding brought by either party seeking to enforce any provision of, or based on any right arising out of, this Agreement must be brought against any of the parties in the courts of the State of New York. Each party (i) hereby irrevocably submits to the jurisdiction of the state courts of the State of New York and to the jurisdiction of any United States District Court in the State of New York, for the purpose of any suit, action, or other proceeding arising out of or based upon this Agreement or the subject matter hereof brought by any party or its successors or assigns, (ii) hereby waives, and agrees not to assert, by way of motion, as a defense, or otherwise, in any such suit, action, or proceeding, any claim that it is not subject personally to the jurisdiction of the above-named courts, that its property is exempt or immune from attachment or execution, that the suit, action or proceeding is brought in an inconvenient forum, that the venue of the suit, action, or proceeding is improper or that this Agreement or the subject matter hereof may not be enforced in or by such court, and (iii) hereby waives and agrees not to seek any review by any court of any other jurisdiction that may be called upon to grant an enforcement of the judgment of any such New York state or federal court.
(b) Process in any action or proceeding seeking to enforce any provision of, or based on any right arising out of, this Agreement may be served on any party anywhere in the world. Each party consents to service of process by registered mail at the address to which notices are to be given and further consent that any service of process, writ, judgment or other notice of legal process shall be deemed and held in every respect to be effectively served upon it in connection with proceedings in the State of New York, if delivered to CT Corporation System, whose current address is 000 Xxxxxx Xxxxxx, 00xx Xxxxx, Xxx Xxxx, Xxx Xxxx 00000, which each party irrevocably designates and appoints as its authorized agent for the service of process in the courts in the State of New York. Nothing herein shall affect the right of a party to serve process in any other manner permitted by applicable law. Each party further agrees that final judgment against it in any such action or proceeding arising out of or relating to this Agreement shall be conclusive and may be enforced in any other jurisdiction within or outside the United States of America by suit on the judgment, a certified or exemplified copy of which shall be conclusive evidence of the fact and of the amount of its liability.
(c) Each party agrees that it shall not, and that it shall instruct those in its control not to, take any action to frustrate or prevent the enforcement of any writ, decree, final judgment, award (arbitral or otherwise) or order entered against it with respect to this Agreement or the XOMA Patent Rights and shall agree to be bound thereby as if issued or executed by a competent judicial tribunal having personal jurisdiction situated in its country of residence or domicile.
Arbitrator's Jurisdiction The arbitrator shall take such evidence as in his judgment is appropriate for resolution of the dispute; however, he shall confine himself to the issues for arbitration and shall have no authority to determine any other issue not so submitted which is not directly essential to reaching a determination on the dispute at hand. The arbitrator shall have no power to recommend any right or relief for any period of time prior to the effective date of the Agreement under which the grievance was initiated. In those issues wherein the grievant’s relief sought involves back pay or lost wages covering a period of an Employee’s payroll separation due to suspension or discharge, the amount of the award shall be less any unemployment compensation or interim earnings, received by the aggrieved Employee. Second jobs or sources of income which the Employee received while under employment will not be considered interim income and will not be deducted when awarding lost wages or back pay. The decision of the arbitrator shall be submitted in writing to the parties within thirty (30) calendar days of the hearing’s conclusion unless the deadline is mutually extended by the parties. The decision and award of the arbitrator shall be final and binding on the Union, its members, the aggrieved Employee(s) and the CITY. With respect to grievances involving misapplication or misinterpretation of this Agreement, the grievance and arbitration procedure contained in this Article shall be the sole and exclusive remedy available to employees, and the parties hereto as this procedure is intended to supersede all conflicting provisions of the Ohio Revised Code regarding any and all matters subject to the grievance procedures of this Contract or otherwise made subject to this Agreement. With respect to grievances involving disciplinary suspensions, demotions or dismissals the election of remedies, as set forth above, shall be mutually exclusive. Choice of binding arbitration shall thereafter preclude appeal to Civil Service or to Court. Appeal to Civil Service shall preclude access to binding arbitration. With respect to cases of suspension, demotion and discharge, the arbitrator shall decide:
Exclusive English jurisdiction Subject to Clause 30.3, the courts of England shall have exclusive jurisdiction to settle any disputes which may arise out of or in connection with this Agreement.
Jurisdictional Disputes 17.01 A xxxx-up meeting will be held with each Contractor not later than the commencement of the Contractor's work on all projects and no assignments shall be made before this xxxx- up. Xxxx-up assignments shall also apply to all sub-contractors. If a jurisdictional dispute arises once the work has commenced, assignments will be made in accordance with procedures, rules and regulations of the National Joint Board Building Trades Department, A.F.L. & C.I.O. The work assignment shall not be completed until a meeting on site has been convened with all Parties involved and until a subsequent meeting (not later than twenty-four (24) hours) has taken place, at which the Contractor shall present the work assignment on paper to all Parties.
17.02 In the event such jurisdictional dispute cannot be settled on a Local basis by the Unions involved, such dispute shall be submitted to the International Unions involved for settlement without permitting it to interfere in any way with the progress of the work at any time. In the event the dispute is not settled by the International Unions involved, it shall then be submitted to the National Joint Board for resolution. It is understood and agreed, however, that if the dispute causes any delay in the progress of the work or gives rise to an apprehended delay, any of the Parties hereto may apply to the Labour Relations Board (Nova Scotia) Construction Panel for an Interim Order under Section 50 of the Trade Union Act, Chapter 311, R.S.N.S. 1967, amended.
Litigation; Claims Any rights (including indemnification) and claims and recoveries under litigation of Seller against third parties arising out of or relating to events prior to the Closing Date;
Court of Jurisdiction Both DBS and the Member agree that the Tokyo District Court will be the exclusive court of jurisdiction in the first instance in any dispute and/ or legal action relating to the rights and obligations under this Agreement or an Individual Contract.
Applicable Law; Forum, Venue and Jurisdiction (a) This Agreement shall be construed in accordance with and governed by the laws of the State of Delaware, without regard to the principles of conflicts of law.
(b) Each of the Partners and each Person holding any beneficial interest in the Partnership (whether through a broker, dealer, bank, trust company or clearing corporation or an agent of any of the foregoing or otherwise):
(i) irrevocably agrees that any claims, suits, actions or proceedings (A) arising out of or relating in any way to this Agreement (including any claims, suits or actions to interpret, apply or enforce the provisions of this Agreement or the duties, obligations or liabilities among Partners or of Partners to the Partnership, or the rights or powers of, or restrictions on, the Partners or the Partnership), (B) brought in a derivative manner on behalf of the Partnership, (C) asserting a claim of breach of a fiduciary duty owed by any director, officer, or other employee of the Partnership or the General Partner, or owed by the General Partner, to the Partnership or the Partners, (D) asserting a claim arising pursuant to any provision of the Delaware Act or (E) asserting a claim governed by the internal affairs doctrine shall be exclusively brought in the Court of Chancery of the State of Delaware, in each case regardless of whether such claims, suits, actions or proceedings sound in contract, tort, fraud or otherwise, are based on common law, statutory, equitable, legal or other grounds, or are derivative or direct claims;
(ii) irrevocably submits to the exclusive jurisdiction of the Court of Chancery of the State of Delaware in connection with any such claim, suit, action or proceeding;
(iii) agrees not to, and waives any right to, assert in any such claim, suit, action or proceeding that (A) it is not personally subject to the jurisdiction of the Court of Chancery of the State of Delaware or of any other court to which proceedings in the Court of Chancery of the State of Delaware may be appealed, (B) such claim, suit, action or proceeding is brought in an inconvenient forum, or (C) the venue of such claim, suit, action or proceeding is improper;
(iv) expressly waives any requirement for the posting of a bond by a party bringing such claim, suit, action or proceeding; and
(v) consents to process being served in any such claim, suit, action or proceeding by mailing, certified mail, return receipt requested, a copy thereof to such party at the address in effect for notices hereunder, and agrees that such services shall constitute good and sufficient service of process and notice thereof; provided, nothing in clause (v) hereof shall affect or limit any right to serve process in any other manner permitted by law.
Specific Performance; Jurisdiction Notwithstanding any other provision of this Agreement, the parties hereto agree that irreparable damage would occur, damages would be difficult to determine and would be an insufficient remedy and no other adequate remedy would exist at law or in equity, in each case in the event that any of the provisions of this Agreement were not performed in accordance with their specific terms or were otherwise breached (or any party hereto threatens such a breach). It is accordingly agreed that in the event of a breach or threatened breach of this Agreement, the other parties hereto shall be entitled to an injunction or injunctions to prevent breaches of this Agreement and to enforce specifically the terms and provisions of this Agreement in the Court of Chancery of the State of Delaware or, if under applicable law exclusive jurisdiction over such matter is vested in the federal courts, any court of the United States located in the State of Delaware, this being in addition to any other remedy to which they are entitled at law or in equity. Each party hereto irrevocably waives any defenses based on adequacy of any other remedy, whether at law or in equity, that might be asserted as a bar to the remedy of specific performance of any of the terms or provisions hereof or injunctive relief in any action brought therefor by any other party hereto. In addition, each of the parties hereto (i) irrevocably submits itself to the personal jurisdiction of the Court of Chancery of the State of Delaware or any court of the United States located in the State of Delaware in the event any dispute arises out of this Agreement or any of the transactions contemplated by this Agreement, (ii) agrees that it will not attempt to deny or defeat such personal jurisdiction by motion or other request for leave from any such court, (iii) agrees that it will not bring any action relating to this Agreement or any of the transactions contemplated by this Agreement in any court other than the Court of Chancery of the State of Delaware or, if under applicable law exclusive jurisdiction over such matter is vested in the federal courts, any court of the United States located in the State of Delaware and (iv) consents to service being made through the notice procedures set forth in Section 9.2. Each of the Company, Parent and Merger Sub hereby agrees that service of any process, summons, notice or document by U.S. registered mail to the respective addresses set forth in Section 9.2 shall be effective service of process for any Proceeding in connection with this Agreement or the transactions contemplated hereby.
