Settlement or Compromise Any settlement or compromise made or caused to be made by the Indemnified Person (unless the Indemnifying Person has the exclusive right to settle or compromise under Section 8.6) or the Indemnifying Person, as the case may be, of any such claim, suit, action or proceeding of the kind referred to in Section 8.6 shall also be binding upon the Indemnifying Person or the Indemnified Person, as the case may be, in the same manner as if a final judgment or decree had been entered by a court of competent jurisdiction in the amount of such settlement or compromise; provided, that (a) no obligation, restriction or Loss shall be imposed on the Indemnified Person as a result of any settlement or compromise without its prior written consent, which consent shall not be unreasonably withheld or delayed, (b) if the Indemnifying Person has assumed the defense of a claim, suit, action or proceeding pursuant to Section 8.6, the Indemnified Person shall not compromise or settle such claim, suit, action or proceeding without the prior written consent of the Indemnifying Person, which consent shall not be unreasonably withheld or delayed, and (c) such settlement shall not contain any finding or admission of any violation of Law or any fault on the part of the Indemnified Person, and shall not have any effect on any other claims that may be made by the Indemnified Person against the third party bringing the claim, suit, action or proceeding.
Compromise To compromise, arbitrate or otherwise adjust claims in favor of or against the Trust or any matter in controversy, including but not limited to claims for taxes;
Disallowance If the Contractor claims or receives payment for a service or reimbursement that is later disallowed by the Judicial Council, the Contractor shall promptly refund the disallowed amount upon the Judicial Council's request. At its option, the Judicial Council may offset the amount disallowed from any payment due or that may become due to the Contractor under this Agreement or any other agreement.
Misconduct Notwithstanding anything to the contrary in this Agreement, the Options shall terminate in their entirety, regardless of whether the Options are vested, immediately upon Optionee’s discharge of employment or other service relationship for Cause or upon Optionee’s commission of any of the following acts during any period following the cessation of Optionee’s employment or other service relationship during which the Options otherwise would be exercisable: (i) fraud on or misappropriation of any funds or property of the Corporation, or (ii) breach by Optionee of any provision of any employment, non-disclosure, non-competition, non-solicitation, assignment of inventions, or other similar agreement executed by Optionee for the benefit of the Company, as determined by the Administrator, which determination will be conclusive.
Concealment Or Fraud We do not provide coverage to an "insured" who, whether before or after a loss, has: 1. Intentionally concealed or misrepresented any material fact or circumstance; 2. Engaged in fraudulent conduct; or 3. Made false statements; relating to this insurance.
Fraud In this Agreement, Fraud means dishonestly obtaining a benefit, or causing a loss, by deception or other means, and includes alleged, attempted, suspected or detected fraud.
Adjudication Where operational requirements permit, the Council will grant leave with pay to an employee who is: (a) a party to an adjudication, or (b) the representative of an employee who is a party to an adjudication, or (c) a witness called by an employee who is party to an adjudication.
Dishonesty Drinking alcoholic beverages on the job, or reporting for work while intoxicated.
TOTAL OR PARTIAL FAILURE TO PERFORM 20.1 In the case of Goods to be specially manufactured for it, if Transnet at any time ascertains that: a) no manufacturing of the Goods specified in a Purchase Order has commenced and there is little or no prospect, in Transnet’s opinion, that manufacturing will commence within a reasonable time; or b) delivery of any of the Goods is being or is likely to be delayed beyond the promised delivery date(s), and there is little or no prospect of the Purchase Order(s) being carried out within reasonable adherence to the promised delivery rate(s) or time(s), then Transnet may, irrespective of the cause of the delay, by notice to the Supplier, cancel as from a future date specified in such notice the whole or any part of this Agreement or Purchase Order in respect of which the Goods to be supplied have not been completed by that date, without incurring any liability by reason of such cancellation except as provided in this clause. 20.2 The Supplier/Service Provider shall thereupon, as soon as possible after such date, deliver to Transnet the Goods/Services [if any] already completed, and payment for the part performance shall be made on a pro rata basis, provided the uncompleted part is not an integral or essential part of the completed Goods/Services. Where an integral or essential part of the work has not been completed, the amount to be paid to the Supplier/Service Provider will be calculated on the basis of Transnet’s enrichment. The Supplier/Service Provider shall, wherever practicable, supply Transnet with the necessary drawings and/or specifications to enable it to complete the work. 20.3 Whenever, in any case not covered by clause 20.1 above, the Supplier fails or neglects to execute the work or to deliver any portion of the Goods/Services as required by the terms of this Agreement or Purchase Order, or if any Goods/Services are rejected on any of the grounds mentioned in clause Error! Reference source not found. [Defective Goods], Transnet may cancel this Agreement or Purchase Order in so far as it relates to the unexecuted work or the undelivered or rejected portion of the Goods/Services, and in such event, the supply of the remaining portion shall remain subject in all respects to these conditions.
Insubordination Bringing intoxicants or illegal drugs into or consuming intoxicants or illegal drugs on any school property or reporting to work under the influence of intoxicants or illegal drugs of any kind in any degree whatsoever;