Construction Standard definition

Construction Standard means construction and installation of the Improvements in a good, workmanlike and lien-free manner and in substantial conformity with the Plans (as may be modified pursuant to the terms hereof), the applicable requirements of the Approving Authorities, and the “Finished Lot Standard” set forth on Exhibit D attached hereto. The Construction Standard does not include any so-called “over excavation” or comparable preparation or mitigation of the soil (hereinafter defined as the “Overex”) on the Builder Lots and Builder has sole responsibility with respect to any Overex that the Builder determines to undertake on the Builder Lots. The terms and provision of Section 10(e) (Over Excavation) of the Contract are hereby incorporated herein by this reference. The Parties shall reasonably cooperate in coordinating the Builder’s completion of the Overex so that the Overex can be properly sequenced with Developer’s completion of the Improvements. In no event shall Developer be liable to Builder for any delay, costs or damages incurred with respect to such Overex, even if caused by any delay in installation of Improvements sequenced ahead of the Overex, and all timeframes shall be deemed extended appropriately in the event of any delay in completing such Overex in accordance with the Construction Schedule (as hereinafter defined).
Sample 1Sample 2
Construction Standard. USA PHARMACEUTICAL STANDARD: USA EQUIPMENT STANDARD: USA HEALTH PRACTICE CODE: USA
Sample 1Sample 2
Construction Standard means a quality of construction consistent with a newly-constructed regional shopping center expansion with respect to a regional shopping center of a type and quality similar to the Center, subject to the Plans and Specifications.
Sample 1

Examples of Construction Standard in a sentence

  • See Changes to the Claim Construction Standard for Interpreting Claims in Trial Proceedings Before the Patent Trial and Appeal Board, 83 Fed.

  • Binding wire for binding shall be as per REC Construction Standards No. C-5 or better thereof.Mid Span Compression Joint & Repair Sleeves: The contractor shall supply & install the Mid Span Compression Joint and Repair Sleeves as per IS: 2121 (Part II).Guy/Stay wire Clamp: The contractor shall supply & install Guy/Stay wire Clamp as per REC Construction Standard G-1 or better here of as specified..

  • At all the crossing described above the contractor shall use protective guarding as per REC Construction Standard A-1 to fulfill statutory requirements for 11 kV & 33 KV trunks & main spur line.

  • If the contractor fails to continue work, it may be declared delinquent in its work as provided by §108.08 of the South Carolina Standard Specifications for Highway Construction ("Standard Specifications").

  • Changes to the Claim Construction Standard for Interpreting Claims in Trial Proceedings Before the Patent Trial and Appeal Board, 83 Fed.

  • Fibrous ductwork may be used if constructed and installed in accordance with SMACNA Construction Standard on Fibrous Glass Ducts.

  • Construction Standard: SUDAS Specifications; Iowa DNR permit required.

  • A Statement of Probable Construction Cost, prepared in Construction Standard Index (CSI) format, to include a summary of the estimated project cost and an evaluation of funding allocation.

  • DEPARTMENT'S Construction and Materials Manual (CMM); Finals Process for Let Project Closeout; Facilities Development Manual (FDM); LRFD Bridge Manual (BM); and Standard Specifications for Highway and Structure Construction (Standard Specifications,) and materials referenced in those manuals.

  • In addition to the requirements listed in WAPA Construction Standard 1.4.3 all employees are restricted from wearing a headset, headphone, or other listening device, other than a hearing aid or instrument for the improvement of defective human hearing, hearing protection worn as the hazard exists, or for communication purposes while on a WAPA jobsite.


More Definitions of Construction Standard

Construction Standard means Construction of the Project has been Completed in a good, workmanlike manner in accordance with Local Construction Practices, the Agreement, the REPA, the Master Construction Plan and Schedule and all Applicable Laws (including Environmental Laws), free and clear of defects in design, workmanship and materials (the foregoing, collectively the “Construction Standard”), and (iii) the term “Project” as defined in the REPA shall be supplemented to include the Property Work. Attached to this Certificate in respect of the east building louver wall (in addition to all other deliverables or attachments required in connection with delivery of this Certificate) is an executed engineer’s Certificate of Completion and an “as built” set of drawings and updated exit points provided by an architect or engineer. [Signatures on following page.]
Sample 1
Construction Standard means temporary worker housing construction code as defined in RCW 70.114A.081.
Sample 1
Construction Standard. Defined in the Fee Letter.
Sample 1
Construction Standard means construction and installation of the Improvements in a good, workmanlike and lien‑free manner and in substantial conformity with the Plans (as may be modified pursuant to the terms hereof), in compliance with the terms of the SIA which corresponds to the Plat(s) containing the applicable Builder Lots, and in substantial conformity with the applicable requirements of the Approving Authorities and the “Finished Lot Standard” set forth on Exhibit D attached hereto. The Construction Standard does not include, and Developer shall have no obligation with respect to, any so-called “over excavation” or comparable preparation or mitigation of the soil (hereinafter defined as the “Overex”) on the Builder Lots, and the Developer shall have no obligation to complete any Improvement required by the SIA (or any Plat), which is not necessary to obtain building permits (or certificates of occupancy) for the Builder Lots included in the applicable Phase. Builder shall be solely and exclusively responsible with respect to any Overex that the Builder determines to undertake on the Builder Lots. The terms and provision of Section 10(e) (Over Excavation) of the Contract are hereby incorporated herein by this reference. The Parties, including as applicable any Substitute Constructing Party, shall reasonably cooperate in coordinating the Builder’s completion of the Overex so that the Overex can be properly sequenced with Developer’s completion of the Improvements. In no event shall Developer be liable to Builder for any delay, costs or damages incurred with respect to such Overex, even if caused by any delay in installation of Improvements sequenced ahead of the Overex and such any delay shall extend, on a day-for-day basis, the applicable Substantial Completion Deadline (as set forth herein).
Sample 1

Related to Construction Standard

  • Construction Start Date means the later to occur of the date on which Seller delivers to Buyer (a) a copy of the Notice to Proceed that Seller has delivered to the EPC Contractor for the Project, and (b) a written Certification substantially in the form attached hereto as Appendix IV-1.

  • construction site means a workplace where construction work is being performed;

  • Construction Work means any work in connection with⎯

  • Constructional Plant means all appliances or things whatever nature required in or about the execution, completion or maintenance of the works or temporary works (as hereinafter defined) but does not include materials or other things intended to form or forming part of the permanent work or temporary housing, hutting, office, stores, etc.,

  • Construction waste means solid waste which is produced or generated during construction, remodeling, or repair of pavements, houses, commercial buildings, and other structures. Construction wastes include, but are not limited to lumber, wire, sheetrock, broken brick, shingles, glass, pipes, concrete, paving materials, and metal and plastics if the metal or plastics are a part of the materials of construction or empty containers for such materials. Paints, coatings, solvents, asbestos, any liquid, compressed gases or semi-liquids and garbage are not construction wastes.

  • Construction sign means a sign which identifies the architect, engineers, contractors and other individuals or firms involved with the construction of a building, or announces the character of the building or enterprise, which is erected during the building construction period.

  • Constructional Plan means all appliances or things of whatsoever nature required for the execution, completion or maintenance of the works or temporary works (as hereinafter defined) but does not include materials or other things intended to form or forming part of the permanent work.

  • Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.

  • Tenant Improvements Defined in Exhibit B, if any.

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Completion Statement has the meaning given to that term in the Co-ordination Agreement; Conditions has the meaning given to that term in the Co-ordination Agreement;

  • Construction project means the same as that term is defined in Section 38-1a-102.

  • Base Building shall include the structural portions of the Building, the public restrooms and the Building mechanical, electrical and plumbing systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. Tenant shall promptly provide Landlord with copies of any notices it receives regarding an alleged violation of Law. Tenant shall comply with the rules and regulations of the Building attached as Exhibit E and such other reasonable rules and regulations adopted by Landlord from time to time, including rules and regulations for the performance of Alterations (defined in Section 9).

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Construction Drawings means the drawings showing building components and the manner in which they are assembled to form a building.

  • Construction Change Directive means a written order prepared by Owner Parties and signed by Owner directing Contractor to perform a change in the Work prior to agreeing to a change, if any, to the Contract Time, schedule of performance of the Work, Contract Sum, or Contractor’s compensation.

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

  • Plans and Specifications means the plans, drawings and specifications reasonably necessary to properly assess and review proposed Work prior to issuance of any approval that may be required under this Agreement;

  • Renovation means rehabilitation that involves costs of 75 percent or less of the value of the building before rehabilitation.

  • Standard Specifications means all applicable legal requirements pertaining to the development of the Property including, but not limited to, Master Subdivision Plan, applicable permits, and construction drawings required for all Infrastructure, including, without limitation, the Town's Unified Development Ordinance, Knightdale's Water Allocation Policy (Ordinance # 13-06- 19-001 and Ordinance # 00-00-00-000) and Standard Specifications and Construction Details Manual. The failure of this Agreement to describe any other permit, condition, or term of restriction applicable to the Property does not relieve Developer of the necessity of complying with the same.

  • Design Standards means the standards developed as a requirement of the Programmatic Agreement

  • Construction Budget means the cost of acquisition, installation, testing, constructing and developing any Property as determined by the Construction Agent in its reasonable, good faith judgment.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Construction activity means any clearing, grading or excavation associated with large construction activity or associated with small construction activity.

  • Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;

  • Construction Plans means plans, drawings, specifications and related documents, and construction schedules for the construction of the Project, together with all supplements, amendments or corrections, submitted by the Developer and approved by the City in accordance with this Agreement.