Governmental Force Majeure definition

Governmental Force Majeure has the meaning given to that expression in Clause 25.1(b).
Sample 1Sample 2
Governmental Force Majeure means occurrence of any of the following which, in respect of each party affected by it, is beyond the reasonable control of that party and which it could not by the exercise of reasonable diligence avoid or mitigate: (i) acts or omissions of princes or rulers or acts or omissions of any governmental Authority, including any change in Law, requisition of the FSRU&M by a Governmental Authority and any failure by any Governmental Authority to issue, amend, or renew, any Consent; or (ii) any of the events specified in paragraph (i) that prevent performance of: (A) the EPCIC Agreement, GSA, or any LNG SPA, Terminal Use Agreement, LNGC Charterparty, or Tug charter; or (B) the Building Contract or Mooring Contract;
Sample 1Sample 2
Governmental Force Majeure has the meaning assigned to Fuerza Mayor Gubernamental in the Public Works Contract.
Sample 1Sample 2

Examples of Governmental Force Majeure in a sentence

  • M is the cost (as reasonably estimated by the Independent Expert) to be incurred in overcoming the effects of the Extended Non- Governmental Force Majeure Event and to bring the Facility to operate at Minimum Performance Standards (to the extent that operations falling below Minimum Performance Standards was caused by the Non-Governmental Force Majeure Event).

  • M is the cost (as reasonably estimated by the Independent Expert) to be incurred in overcoming the effects of the Extended Non- Governmental Force Majeure Event with respect to the First Unit or the Facility, as applicable.

  • For the purposes of determining the date such Availability Payments shall commence, the Scheduled Commercial Operation Date of the Unit (i) shall be extended by one day for each day by which the occurrence of the Commercial Operation Date of the Unit is delayed due to causes attributable to the Generator, but (ii) shall not be extended pursuant to Section 10.5.1 for such Governmental Force Majeure.

  • Notwithstanding the above, if the event constituting a Non-Governmental Force Majeure Event results in a breakdown of communications rendering it not reasonably practicable to give notice within the applicable time limit specified herein, then the Party affected by the Non- Governmental Force Majeure Event shall give such notice as soon as reasonably practicable after the reinstatement of communications, but not later than one (1) Business Day after such reinstatement.

  • Single stranded RNA RT viruses- Retroviruses- Human Immunodeficiency Virus2L 5.

  • EGAT shall not share the Minimum Take Liability if such a failure (i) occurs before the Commercial Operation Date of the Second Unit, or (ii) is due to any causes other than Dispatch Instructions by EGAT, Force Majeure affecting EGAT or Governmental Force Majeure.

  • Without otherwise limiting the payment rights and obligations under Section 14.4, during any period of Force Majeure or Governmental Force Majeure, EGAT shall continue to make Availability Payments in accordance with Schedule 2 for any Availability provided by the Generator that EGAT remains capable of Dispatching.

  • In the event that the BOT Contract is terminated (regardless of whether such termination is due to a BOT Company Event of Default, a MOIT Event of Default or an Extended Non- Governmental Force Majeure Event thereunder), this Agreement shall automatically terminate and the sole and exclusive remedies available shall be those set out in Articles 4.7 and 4.8 above and Article 21 of the BOT Contract.

  • These will be sent to your online vault for electronic documents.In summary, FundsNetwork’s re-registration service is an online process designed to make moving client accounts from external platforms to FundsNetwork as efficient as possible.

  • The Party affected by a Non- Governmental Force Majeure Event shall give the other Party regular reports on the progress of those remedial measures and such other information as the other Party may reasonably request.


More Definitions of Governmental Force Majeure

Governmental Force Majeure means the reduction by Seller of Maya deliveries under Seller's contractual commitments to its export customers in general as the result of a direction from the federal government of Mexico to curtail crude oil exports despite the availability of Maya for export.
Sample 1
Governmental Force Majeure has the meaning given to that expression in Clause 22.1(b);“HSE" means health, safety and environment.
Sample 1
Governmental Force Majeure means occurrence, in respect of each Party affected by it, is beyond the reasonable control of that Party and which it could not by the exercise of reasonable diligence avoid
Sample 1

Related to Governmental Force Majeure

  • Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.

  • Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.

  • Force Majeure Event means an event beyond the reasonable control of any party including an outbreak of a serious disease or epidemic, or quarantine or other public health emergencies, fire, flood, earthquake, explosion or other casualty or accident or act of God, or war or other violence, strike, lock-out, labour dispute, acts of any governmental body, war, insurrection, sabotage, embargo, interruption of or delay in transportation, unavailability of or interruption or delay in telecommunications or inability to obtain raw materials, supplies or power.

  • Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and

  • Force Majeure Exception means any failure or delay in the performance of the Fund’s reporting obligation pursuant to Section 2.3 arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including, without limitation, acts of God; earthquakes; flood; terrorism; wars and other military disturbances; sabotage; epidemics; riots; loss or malfunctions of utilities, computer (hardware or software) or communication services; accidents; acts of civil or military authority and governmental action. The Fund shall use commercially reasonable efforts to commence performance of its obligations during any of the foregoing circumstances.

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Governmental Action means all authorizations, consents, approvals, waivers, exceptions, variances, orders, licenses, exemptions, publications, filings, notices to and declarations of or with any Governmental Authority (other than requirements the failure to comply with which will not affect the validity or enforceability of any Loan Document or have a material adverse effect on the transactions contemplated by any Loan Document or any material rights, power or remedy of any Person thereunder or any other action in respect of any Governmental Authority).

  • Event of Force Majeure means one of the following events:

  • Governmental Actions means any and all consents, approvals, permits, orders, authorizations, waivers, exceptions, variances, exemptions or licenses of, or registrations, declarations or filings with, any Governmental Authority required under any Governmental Rules.

  • Force Majeure Period has the meaning specified in Section 13.1.

  • Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Environmental Activity means any activity, event or circumstance in respect of a Contaminant, including, without limitation, its storage, use, holding, collection, purchase, accumulation, assessment, generation, manufacture, construction, processing, treatment, stabilization, disposition, handling or transportation, or its Release, escape, leaching, dispersal or migration into the natural environment, including the movement through or in the air, soil (land surface or subsurface strata), surface water or groundwater;

  • Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;

  • Governmental Requirement means any law, statute, code, ordinance, order, determination, rule, regulation, judgment, decree, injunction, franchise, permit, certificate, license, rules of common law, authorization or other directive or requirement, whether now or hereinafter in effect, of any Governmental Authority.

  • Environmental Violation means any activity, occurrence or condition that violates or results in non-compliance with any Environmental Law in any Material respect.

  • Environmental Activities means the use, generation, transportation, handling, discharge, production, treatment, storage, release or disposal of any Hazardous Materials at any time to or from any portion of the Premises or located on or present on or under any portion of the Premises.

  • Environmental Authorization Any license, permit, order, approval, consent, notice, registration, filing or other form of permission or authorization required under any Environmental Law.

  • Environmental Authorizations means all licenses, permits, orders, approvals, notices, registrations or other legal prerequisites for conducting the business of the Borrower or any Subsidiary required by any Environmental Requirement.

  • Environmental Approvals means any permit, license, approval, ruling, variance, exemption or other authorization required under applicable Environmental Laws.

  • Governmental Acts means any act or omission, whether rightful or wrongful, of any present or future de jure or de facto government or Governmental Authority.

  • Environmental Actions means any complaint, summons, citation, notice, directive, order, claim, litigation, investigation, judicial or administrative proceeding, judgment, letter, or other communication from any Governmental Authority, or any third party involving violations of Environmental Laws or releases of Hazardous Materials from (a) any assets, properties, or businesses of any Borrower or any predecessor in interest, (b) from adjoining properties or businesses, or (c) from or onto any facilities which received Hazardous Materials generated by any Borrower or any predecessor in interest.

  • Environmental Action means any action, suit, demand, demand letter, claim, notice of non-compliance or violation, notice of liability or potential liability, investigation, proceeding, consent order or consent agreement relating in any way to any Environmental Law, Environmental Permit or Hazardous Materials or arising from alleged injury or threat of injury to health, safety or the environment, including, without limitation, (a) by any governmental or regulatory authority for enforcement, cleanup, removal, response, remedial or other actions or damages and (b) by any governmental or regulatory authority or any third party for damages, contribution, indemnification, cost recovery, compensation or injunctive relief.

  • Environmental Authority means any foreign, federal, state, local or regional government that exercises any form of jurisdiction or authority under any Environmental Requirement.