Practical Completion Stage definition

Practical Completion Stage means that stage of the Works in which Practical Completion will be attained in accordance with this Contract.
Sample 1Sample 2Sample 3
Practical Completion Stage means that stage of the Contract Work in which Practical Completion will be attained in accordance with this Contract.
Sample 1Sample 2Sample 3
Practical Completion Stage. , for a regulated contract, means the stage when—
Sample 1Sample 2

Examples of Practical Completion Stage in a sentence

  • Except for the Practical Completion Stage, you must pay the amount claimed by the Contractor, or any part of it with which you agree, within 5 Business Days of receipt of this progress claim.

  • For the Practical Completion Stage, you must pay the Contractor immediately after the Contractor has satisfied Condition 28.3. When form completed, Contractor to retain original and give 2 legible copies to Owner.


More Definitions of Practical Completion Stage

Practical Completion Stage means that stage when the Works are complete in accordance with this Contract and all relevant statutory requirements (apart from minor omissions or minor defects), inspections have been satisfactorily completed and the Works are reasonably suitable for habitation.
Sample 1

Related to Practical Completion Stage

  • Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):

  • Date of Practical Completion means the date certified in the QBCC Form 7 - Certificate of Practical Completion in accordance with Condition 28.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Xxxxxx Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Phase 2 means the phase of the ATP comprised of: (1) improvements to the State Street Substation to receive Rebuilt Line 972; (2) the rebuilding of NYSEG’s existing Line 972 not performed in Phase 1; (3) construction of Relocated Line 15; (4) the construction of Bused Line 5; (5) improvements to the Elbridge Substation to receive Relocated Line 15; and (6) improvements to the Elbridge Substation to receive Bused Line 5.