RFI Date definition

RFI Date means the date on which the Representative certifies in writing that the Works have been completed (and the expressions "Ready for Installation" or "RFI" will be construed accordingly);
Sample 1Sample 2Sample 3
RFI Date means the date on which the Representative certifies in writing that the Works have been completed in accordance with the specification (and the expressions "Ready for Installation" or "RFI" shall be construed accordingly;
Sample 1Sample 2Sample 3
RFI Date means the date on which the Representative certifies in writing that the Works have been completed in
Sample 1

Examples of RFI Date in a sentence

  • LeaseWeb may delay the RFI Date, in its sole discretion, by written notice to Customer; provided, however, that if LeaseWeb delays the RFI Date by more than thirty (30) days after the initial RFI Date, Customer may terminate the relevant Order Form upon written notice to LeaseWeb.

  • In view hereof, Customer shall prior to the RFI Date or the RFS Date (whichever is earlier) provide credit information to LeaseWeb for approval by LeaseWeb.

  • If LeaseWeb and Customer cannot agree upon a new RFI Date within seven (7) business days after the initial RFI Date, then either party shall be entitled to terminate the relevant Order Form upon written notice to the other party without further liability.

  • LeaseWeb shall have no liability to Customer if the Rackspace is not available for the installation of Customer’s Equipment on or before the RFI Date; or, if the installation is to be performed by LeaseWeb, the installation is not completed by the RFI Date.

  • In the event Customer fails to commence the initial installation of Customer’s Equipment on or before the fifth calendar day following the RFI Date, LeaseWeb shall work with Customer in good faith to establish a new RFI Date.

  • We ask that you compile any clarification questions (RFI) into one single electronic submission to be communicated to the Primary RFP Contact by the RFI Date listed in section XI.

  • LeaseWeb shall have no liability to Customer if the SHL is not available for the installation of Customer’s Equipment on or before the RFI Date; or, if the installation is to be performed by LeaseWeb, the installation is not completed by the RFI Date.

  • Public notice of RFI Date: Friday, June 10, 2022Deadline for questions/inquiries Date: Friday, June 17, 2022 at 4:30pm Response to questions/inquiries Date: Wednesday, June 22, 2022 at 4:30pm Deadline for receipt of response to RFI Date: Monday, June 27, 2022 at 4:30pm NOTE: LDH reserves the right to deviate from this Schedule of Events at any time and without notice.

Related to RFI Date

  • Inception Date means in respect of a Fund, the first date on which the Fund issued shares.

  • Execution Date means the date on which the parties execute and enter into this Agreement.

  • ZERO DATE means the date of issue of LETTER OF INTENT (LOI) or issue of WORK ORDER, whichever is earlier.

  • Transition Date means the date on which this contract comes into effect for all purposes.

  • Start Date for Term Calculation Purposes Only: Regardless of actual award/effective date of Contract, for Agreement “term” calculation purposes only, the Agreement “start date” is the last day of the month that Award Notifications are anticipated as published in the Solicitation. Example: If the anticipated award date published in the Solicitation is August 27, 2020 but extended negotiations delay award until September 24, 2020 the end date of the resulting initial “two-year” term Agreement, (which is subject to an extension(s)) will still be August 31, 2022 in this example

  • Formation Date has the meaning set forth in the Recitals hereof.

  • Hire Date has the meaning given to it in Section 2.6(a).

  • Date The Effective Date (as defined in the Funding Agreement)

  • Offer Commencement Date means the date on which Purchaser commences the Offer, within the meaning of Rule 14d-2 under the Exchange Act.

  • Go-Live Date means the date on which the City, acting reasonably, confirms in writing that the Services satisfy the functional, technical and security requirements as set out in this Agreement;

  • Base Date means a date 30 day prior to the submission of tenders.

  • Anticipated Closing Date means the anticipated closing date of any proposed Qualified Sale Transaction, as determined in good faith by the Board of Directors on the Applicable Date.

  • Offering Commencement Date means the first day of each Offering Period.

  • Origination Date means, with respect to each Mortgage Loan, the date of the Mortgage Note relating to such Mortgage Loan, unless such information is not provided by the Borrower with respect to such Mortgage Loan, in which case the Origination Date shall be deemed to be the date that is 40 days prior to the date of the first payment under the Mortgage Note relating to such Mortgage Loan.

  • Initial Date means the date of the closing of the Initial Offering of the Company.

  • Ending Date means the calendar date specified in the Notice of Intent as the date upon which lead - based paint abatement activities are completed.

  • Offer Closing Date has the meaning set forth in Section 1.01(f).

  • Service Date or "SD" means the date service is made available to the End User Customer. This also is referred to as the "Due Date."

  • Purchase Termination Date means the date upon which the Transferor shall cease, for any reason whatsoever, to make purchases of Receivables from the Seller under the Receivables Purchase Agreement or the Receivables Purchase Agreement shall terminate for any reason whatsoever.

  • Contract Effective Date means the date agreed upon by the parties for beginning the period of performance under the contract. In no case shall the effective date precede the date on which the contracting officer or designated higher approval authority signs the document.

  • Evaluation Date shall have the meaning ascribed to such term in Section 3.1(s).

  • Auction Date means the first Business Day preceding the first day of a Dividend Period.

  • Handover Date means the date on which access to the Tower and Associated Tower Site is given to the Access Seeker for installation of the Equipment at that Site as stated in Clause 9(c) hereof. “Handover” shall be construed accordingly.

  • Initiation Date means the date on which a financial creditor, corporate applicant or operational creditor, as the case may be, makes an application to the Adjudicating Authority for initiating corporate insolvency resolution process;

  • Contract Date means the date set for bid opening or, if this is a negotiated contract or a modification, the effective date of this contract or modification.

  • Billing Commencement Date means the earlier of: