Sectional Completion definition

Sectional Completion means completion of a Section per Clause 33.1;
Sample 1Sample 2Sample 3
Sectional Completion completion of a Section in accordance with the “Services Works” the installation and connection of:
Sample 1
Sectional Completion means practical completion (as certified by the relevant contract administrator in respect of a Building Contract) of a section of the Developer Works in accordance with the relevant Building Contract;
Sample 1

Examples of Sectional Completion in a sentence

  • Sectional Completion of Works If sectional completion is specified in the Special Conditions of Contract (SCC), references in the Conditions of Contract to the Works, the Completion Date, and the Intended Completion Date shall apply to any Section of the Works (other than references to the Completion Date and Intended Completion Date for the whole of the Works).

  • IfNumber of GC ClauseAmendments of, and Supplements to, Clauses in the General Conditions of Contract Sectional Completion and Damages per Section have been agreed, the latter should be specified here]GCC 48.1The Bonus for the whole of the Works is [insert percentage of final Contract Price] per day.

  • Sectional Completion of WorksIf sectional completion is specified in the Special Conditions of Contract (SCC), references in the Conditions of Contract to the Works, the Completion Date, and the Intended Completion Date shall apply to any Section of the Works (other than references to the Completion Date and Intended Completion Date for the whole of the Works).

  • If Sectional Completion and Damages per Section have been agreed, the latter should be specified here] GCC 48.1 The Bonus for the whole of the Works is [insert percentage of final Contract Price] per day.

  • The maximum amount of liquidated damages for the whole of the Works is [insert percentage] of the final Contract Price.[Usually liquidated damages are set between 0.05 percent and 0.10 percent per day, and the total amount is not to exceed between 5 percent and 10 percent of the Contract Price .lf Sectional Completion and Damages perSection have been agreed, the latter should be specified here} GCC 48.1The Bonus for the whole of the Works is [insert percentage of final Contract Price} per day.

  • If Sectional Completion and Damages per Section have been agreed, the latter should be specified here] GCC 52.1 The Bonus for the whole of the Works is [insert percentage of final Contract Price] per day.

  • X5 Sectional Completion Optional Used if the project requires sectional completion X7 Delay damages Applies Applies other than in exceptional circumstances agreed with NHSEI.

  • If Sectional Completion and Damages per Section have been agreed, the latter should be specified here]GCC 48.1The Bonus for the whole of the Works is [insert percentage of final Contract Price] per day.

  • If Sectional Completion and Damages per Section have been agreed, the latter should be specified here] GCC 56.1 The Contract Price for Phase III shall be subject to deductions for failure to meet the relevant Service Levels in the Specification during Phase III calculated in accordance with the methodology in the PCC [per incident][ per day].

  • The maximum amount of liquidated damages for the whole of the Works is [insert percentage] of the final Contract Price.[Usually liquidated damages are set between 0.05 percent and 0.10 percent per day, and the total amount is not to exceed between 5 percent and 10 percent of the Contract Price .lf Sectional Completion and Damages per Section have been agreed, the latter should be specified here}I E.


More Definitions of Sectional Completion

Sectional Completion means Practical Completion of a Section as certified by the Construction Manager;
Sample 1
Sectional Completion completion of a Section in accordance with the terms of the relevant Building Contract but excludes any landscaping works that it is not possible to complete because of the planting season in which practical completion occurs
Sample 1

Related to Sectional Completion

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Final Completion Date means the date on which Final Completion occurs.

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Practical Completion means the completion of the Project where the building is fit for occupancy and/or purpose.

  • Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Improvement completion assurance means a surety bond, letter of credit,

  • Completion Notice means a notice issued by the Developer in accordance with clause 6.1.

  • Completion of work means completion of the entire contracted work. Exhaustion of quantity of any particular item mentioned in the bid document shall not imply completion of work or any component thereof.

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Pre commencement condition means a condition imposed on the grant of permission which must be complied with: before any building/ other operation/ or use of the land comprised in the development is begun.

  • Time for Completion means the time for completing the Works as stated in the Contract Data (or as extended under Sub-Clause 7.3), calculated from the Commencement Date.

  • Target Completion Date has the meaning given such term in Section 3.3(b).