Acceptance Period For all Services provided under this Agreement, Vendor grants to Citizens a thirty (30) calendar day acceptance period ("Acceptance Period") commencing on the date completed Services are delivered to Citizens. Citizens shall have the right to reject the Services, in whole or in part, during the Acceptance Period for Vendor’s failure to meet the specifications associated with the delivered Services, with such determination to be made in Citizens’ reasonable judgment. At the end of the Acceptance Period, if Citizens has not rejected the Services, the Services shall be deemed to be accepted by Citizens; provided, however, that Citizens’ acceptance of the Services shall not be deemed a waiver of any of Citizens’ warranty rights as expressly provided in this Agreement.
Acceptance Date The date the Department accepts a Deliverable or System in accordance with Section 7 below shall be deemed the Acceptance Date for each Deliverable or System.
Acceptance Tests 11.1 If the Contract provides acceptance tests for Goods and/or the result of Services after their completion and/or delivery to the Purchaser, the acceptance shall only be considered as definitive when such tests have demonstrated the compliance of the Goods and/or the result of the Services to the requirements in the Contract.
11.2 Where the Contract provides for an acceptance procedure in the presence of both parties, at the successful completion of such procedure, the Purchaser shall issue the Supplier with an acceptance certificate which shall authorise the Supplier to invoice the Purchaser for any payment due on such acceptance.
11.3 The Purchaser shall at its discretion be entitled to issue and acceptancecertificate with reserves. The Supplier shall be obliged to remedy any non-conformities within the period set out in the acceptance certificate. Any payment which would otherwise have been due on acceptance may be withheld by the Purchaser in whole or part until the non- conformities underlying the reserves have been remedied.
Acceptance Testing At the time of installation of a LIS trunk group, and at no additional charge, acceptance tests will be performed to ensure that the service is operational and meets the applicable technical parameters.
Acceptance; Rejection A holder of Notes may accept the offer to prepay made pursuant to this Section 8.3 by causing a notice of such acceptance to be delivered to the Company not later than 15 days after receipt by such holder of the most recent offer of prepayment. A failure by a holder of Notes to respond to an offer to prepay made pursuant to this Section 8.3 shall be deemed to constitute a rejection of such offer by such holder.
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 45 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, and if so terminated by Tenant: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenant Delays” and “Substantially Completed” shall have the meanings set forth for such terms in the Work Letter. If Tenant does not elect to void this Lease within 10 business days of the lapse of such 45 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Notwithstanding anything to the contrary contained herein, if Tenant does not terminate this Lease pursuant to the immediately preceding sentence, Base Rent shall be abated 1 day for each day after such 45 day period (as extended by Force Majeure delays and Tenant Delays) that the Premises are not Delivered to Tenant.
Payment Does Not Imply Acceptance of Work The granting of any payment by City, or the receipt thereof by Contractor, shall in no way lessen the liability of Contractor to replace unsatisfactory work, equipment, or materials, although the unsatisfactory character of such work, equipment or materials may not have been apparent or detected at the time such payment was made. Materials, equipment, components, or workmanship that do not conform to the requirements of this Agreement may be rejected by City and in such case must be replaced by Contractor without delay.
Acceptance Procedure Lessor hereby authorizes one or more employees of the related Lessee, to be designated by such Lessee, as the authorized representative or representatives of Lessor to accept delivery on behalf of Lessor of that Leased Property identified on the applicable Funding Request. Each Lessee hereby agrees that such acceptance of delivery by such authorized representative or representatives and the execution and delivery by such Lessee on each Closing Date for property to be leased hereunder of a Lease Supplement in substantially the form of Exhibit A hereto (appropriately completed) shall, without further act, constitute the irrevocable acceptance by such Lessee of that Leased Property which is the subject thereof for all purposes of this Lease and the other Operative Documents on the terms set forth therein and herein, and that such Leased Property, together with, in the case of Land, any Building or other improvements thereon or to be constructed thereon pursuant to the Construction Agency Agreement, shall be deemed to be included in the leasehold estate of this Lease and shall be subject to the terms and conditions of this Lease as of such Closing Date. The demise and lease of each Building pursuant to this Section 2.2 shall include any additional right, title or interest in such Building which may at any time be acquired by Lessor, the intent being that all right, title and interest of Lessor in and to such Building shall at all times be demised and leased to the related Lessee hereunder.
Acceptance of the Work 19.1 The Contractor shall correct any Work that fails to conform to the requirements of the Contract Documents where such failure to conform appears during the progress of the Work, and shall remedy any defects due to faulty permitting, design, materials, equipment or workmanship which appear within a period of one year from the Date of Final Settlement of the Contract or within such longer period of time as may be prescribed by law or by the terms of any applicable special guarantee required by the Contract Documents. The provisions of this Article apply to Work done by Subcontractors as well as to Work done by direct employees of the Contractor, and are in addition to any other remedies or warranties provided by law.
19.2 No act of, or failure to act by, the Owner or the Owner's Representative, either in superintending or directing the Work, or any extension of time for the completion of the Work, shall be regarded as an acceptance of such Work or any part thereof, or of materials used therein, either wholly or in part. Acceptance shall be evidenced only by the final certificate of the Owner. Before any final certificate shall issue, Contractor shall execute an affidavit on the certificate that it accepts the same in full payment and settlement of all claims on account of Work done and materials furnished under this Contract, and that all claims for materials provided or labor performed have been paid or set aside in full. No waiver of any breach of this Contract by the Owner or anyone acting on Owner's behalf shall be held as a waiver of any other subsequent breach thereof.
19.3 Contractor agrees to guarantee all work under this Contract for the periods specified in the RFP from the date of Final Settlement by the Owner. If any unsatisfactory condition or damage develops within the time of this guaranty due to permitting, design, materials or workmanship that are defective, inferior, or not in accordance with the Contract, as reasonably determined by the Owner or the Owner’s Representative, then the Contractor shall, when notified by the Owner or OR, immediately place such guaranteed Work in a condition satisfactory to the Owner or OR.
Term of Contract; Contract Extension The Contract will be in effect from the Effective Date (15 December 2016) through 31 December 2018. DAS, in its sole discretion, may extend this Contract for additional terms beyond the original term, prior to Termination or expiration, one or more times for a combined total period not to exceed the complete length of the original term.