ADJUSTMENTS FOR CHANGE IN SCOPE Sample Clauses

ADJUSTMENTS FOR CHANGE IN SCOPE. APS may order changes in the Work within the general scope of the Work consisting of additions, deletions or other revisions. No claim may be made by the Contractor that the scope of the Work or of the Contractor's services has been changed requiring adjustments to the amount of compensation due the Contractor unless such adjustments have been made by a written amendment to the Contract signed by APS and the Contractor. If the Contractor believes that any particular work is not within the scope of the Work or is a material change or otherwise will call for more compensation to the Contractor, the Contractor must immediately notify the Project Officer after the change or event occurs and within ten (10) calendar days thereafter must provide written notice to the Project Officer. The Contractor’s notice must provide to the Project Officer the amount of additional compensation claimed, together with the basis therefore and supportive documentation for the amount. The Contractor will not be compensated for performing any work unless a Proposal complying with this subSection has been submitted in the time specified above and a written amendment has been signed by APS and the Contractor and an APS Purchase Order is issued covering the cost of the services to be provided under the amendment.
Sample 1Sample 2Sample 3See All (21)
AutoNDA by SimpleDocs
ADJUSTMENTS FOR CHANGE IN SCOPE. The County may order additions, deletions and other revisions in the Work within the general scope of the project. If the Contractor believes that any change is not within the scope of the project or warrants additional compensation or additional time, the Contractor must notify the Project Officer as soon as the County requests the change; and the Contractor must then provide written notice of its position to the Project Officer within ten calendar days. The Contractor’s notice must detail and document the basis for the claimed amount of additional compensation or time. The Contractor will not receive any additional compensation or time pursuant to this paragraph unless the parties execute a written Contract amendment and the County issues a purchase order consistent with the amendment. This provision is applicable to all contracts. ACCESS TO RECORDS AND REPORTS DHS Standard Terms and Conditions v.3.0 (2013) Access to Records - The following access to records requirements apply to this Contract:
Sample 1Sample 2Sample 3See All (7)
ADJUSTMENTS FOR CHANGE IN SCOPE. The City may order changes in the Work within the general scope of the Work consisting of additions, deletions or other revisions. No claims may be made by the Contractor that the scope of the work or that Contractor’s services have been changed required adjustments in the amount of compensation due to the Contractor unless such adjustments have been made by a written amendment to the Contract signed by the City and the Contractor. If the Contractor believes that any particular work is not within the scope of the Work or is a material change or otherwise will call for more compensation to the Contractor, the Contractor must immediately notify the Project Officer after the change or event occurs and within ten (10) calendar days thereafter must provide written notice to the Project Officer. The Contractor must provide to the Project Officer the amount of additional compensation claimed, together with the basis therefor and documentation supporting the claimed amount. The Contractor will not be compensated for performing any work unless a proposal complying with this paragraph has been submitted in the time specified above and a written contract amendment has been signed by the City and the Contractor and the City has issued a Purchase Order covering the expected cost of such goods or services.
Sample 1Sample 2Sample 3See All (7)
ADJUSTMENTS FOR CHANGE IN SCOPE. APS may order changes in the Work within the general scope of the Work consisting of additions, deletions, or other revisions. No claim may be made by the CMA that the scope of the Work or of the CMA's services has been changed requiring adjustments to the amount of compensation due the CMA unless such adjustments have been made by a written amendment to the Contract signed by APS and the CMA. If the CMA believes that any particular work is not within the scope of the Work or is a material change or otherwise will call for more compensation to the CMA, the CMA must immediately notify the Project Officer after the change or event occurs and within ten (10) calendar days thereafter must provide written notice to the Project Officer. The CMA’s notice must provide to the Project Officer the amount of additional compensation claimed, together with the basis therefore and supportive documentation for the amount. The CMA will not be compensated for performing any work unless a Proposal complying with this subsection has been submitted in the time specified above and a written amendment has been signed by APS and the CMA and a Purchase Order is issued covering the cost of the services to be provided under the amendment.
Sample 1Sample 2Sample 3See All (4)
ADJUSTMENTS FOR CHANGE IN SCOPE. The County may order additions, deletions and other revisions in the Work within the general scope of the project. If the Contractor believes that any change is not within the scope of the project or warrants additional compensation, the Contractor must notify the Project Officer as soon as the County requests the change; and the Contractor must then provide written notice of its position to the Project Officer within ten calendar days. The Contractor’s notice must detail and document the basis for the claimed amount of additional compensation. The Contractor will not receive any additional compensation pursuant to this paragraph unless the parties execute a written Contract amendment, and the County issues a purchase order consistent with the amendment.
Sample 1Sample 2Sample 3See All (4)
ADJUSTMENTS FOR CHANGE IN SCOPE. APS may order changes in the Work within the general scope of the Work consisting of additions, deletions or other revisions. No claim may be made by the Contractor that the scope of the Work or of the Contractor's services has been changed requiring adjustments to the amount of compensation due the Contractor unless such adjustments have been made by a written amendment to the Contract signed by APS and the Contractor. If the Contractor believes that any particular work is not within the scope of the Work or is a material change or otherwise will call for more compensation to the Contractor, the Contractor must immediately notify the Project Officer after the change or event occurs and within ten
Sample 1
ADJUSTMENTS FOR CHANGE IN SCOPE. The County may order changes in the work as long as such changes remain within the scope of the work. If the Contractor believes that any work is not within the scope of the project, is a material change, or will otherwise call for additional compensation, then the Contractor must immediately notify the Project Officer in writing of this belief. If the County agrees with such belief, an adjustment will be made to the Contract by formal written Amendment. The Contractor shall not receive additional compensation until this written amendment has been signed by both Parties and a County purchase order covering the additional cost is issued. If it is determined that the work in question is within the scope of the Contract, then the Contractor shall continue work.
Sample 1
AutoNDA by SimpleDocs

Related to ADJUSTMENTS FOR CHANGE IN SCOPE

  • Change in Scope For substantial modifications in authorized Project scope, and/or substantial modifications of drawings and/or specifications previously accepted by City, when requested by City and through no fault of Consulting Engineer/Architect, the Consulting Engineer/Architect shall be compensated for time and expense required to incorporate such modifications at Consulting Engineer/Architect's standard hourly rates per Exhibit B; provided, however, that any increase in contract price or contract time must be approved through a written change order. Consulting Engineer/Architect shall correct or revise any errors or deficiencies in its designs, drawings or specifications without additional compensation when due to Consulting Engineer/Architect's negligence or other actionable fault.

  • Change in Scope of Work Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition, or deletion is approved in advance and in writing by a valid change order executed by the District. Contractor specifically understands, acknowledges, and agrees that the District shall have the right to request any alterations, deviations, reductions, or additions to the Project or Work, and the cost thereof shall be added to or deducted from the amount of the Contract Price by fair and reasonable valuations. Contractor also agrees to provide the District with all information requested to substantiate the cost of the change order and to inform the District whether the Work will be done by the Contractor or a subcontractor. In addition to any other information requested, Contractor shall submit, prior to approval of the change order, its request for a time extension (if any), as well as all information necessary to substantiate its belief that such change will delay the completion of the Work. If Contractor fails to submit its request for a time extension or the necessary supporting information, it shall be deemed to have waived its right to request such extension.

  • Procedure for Change of Scope 16.2.1 In the event of the Authority determining that a Change of Scope is necessary, it shall issue to the Concessionaire a notice specifying in reasonable detail the works and services contemplated thereunder (the “Change of Scope Notice”).

  • Market Adjustments 22. Neither this Article nor any other in this Collective Agreement prevents the Employer from using other funds to increase a Member’s salary in response to offers received from other employers or to accommodate other market forces.

  • Payment for Change of Scope Payment for Change of Scope shall be made in accordance with the payment schedule specified in the Change of Scope Order.

  • Cost Adjustments Both parties agree that contracted prices shall be fixed for the first 12 months of this Contract. Contractor must submit to District any proposed cost adjustments at least 60 days before the proposed effective date of such increases with a detailed explanation for each adjustment. District alone reserves the right to reject any changes to this Contract it deems unacceptable.

  • Workforce Adjustment (a) The Parties recognize that workforce adjustment may be necessary due to the elimination of positions resulting from a reduction in the amount of work required to be done by the Commission, reorganization or program termination.

  • Minor Changes Within Sale Area, minor adjustments may be made in boundaries of cutting units or in the timber individually Marked for cutting when ac- ceptable to Purchaser and Forest Service.

  • Market Adjustment The parties to this Agreement recognize the appropriateness of market pay adjustments in rare instances for compelling reasons. To effectuate judgments in such cases, the President and AAUP Chapter President, in consultation, shall each name three (3) individuals to a university Market Evaluation Committee. Deans may submit recommendations for market pay adjustments with supporting written reasons to the Committee. Said Committee shall consult with the President concerning proposed market pay adjustments reporting its advice not later than May 15 in each year. Upon the favorable recommendation of the President and the BOR President, market pay adjustments may be approved effective at the beginning of that pay period including September 1 of the following year. Not more than one (1) market pay adjustment per one hundred (100) full-time members, or fraction thereof, may be recommended in any contract year. A member’s salary may not be increased beyond the maximum for the rank. Funding for this program shall be governed by Article 12.10.2.

  • Major Change 2. For a major change referred to in paragraph (1)(a):

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!