TOTAL OR PARTIAL FAILURE TO PERFORM 20.1 In the case of Goods to be specially manufactured for it, if Transnet at any time ascertains that: a) no manufacturing of the Goods specified in a Purchase Order has commenced and there is little or no prospect, in Transnet’s opinion, that manufacturing will commence within a reasonable time; or b) delivery of any of the Goods is being or is likely to be delayed beyond the promised delivery date(s), and there is little or no prospect of the Purchase Order(s) being carried out within reasonable adherence to the promised delivery rate(s) or time(s), then Transnet may, irrespective of the cause of the delay, by notice to the Supplier, cancel as from a future date specified in such notice the whole or any part of this Agreement or Purchase Order in respect of which the Goods to be supplied have not been completed by that date, without incurring any liability by reason of such cancellation except as provided in this clause. 20.2 The Supplier/Service Provider shall thereupon, as soon as possible after such date, deliver to Transnet the Goods/Services [if any] already completed, and payment for the part performance shall be made on a pro rata basis, provided the uncompleted part is not an integral or essential part of the completed Goods/Services. Where an integral or essential part of the work has not been completed, the amount to be paid to the Supplier/Service Provider will be calculated on the basis of Transnet’s enrichment. The Supplier/Service Provider shall, wherever practicable, supply Transnet with the necessary drawings and/or specifications to enable it to complete the work. 20.3 Whenever, in any case not covered by clause 20.1 above, the Supplier fails or neglects to execute the work or to deliver any portion of the Goods/Services as required by the terms of this Agreement or Purchase Order, or if any Goods/Services are rejected on any of the grounds mentioned in clause Error! Reference source not found. [Defective Goods], Transnet may cancel this Agreement or Purchase Order in so far as it relates to the unexecuted work or the undelivered or rejected portion of the Goods/Services, and in such event, the supply of the remaining portion shall remain subject in all respects to these conditions.
TOTAL OR PARTIAL TAKING If all or a material portion of the Premises is taken by any lawful authority by exercise of the right of eminent domain, or sold to prevent a taking, either Tenant or Landlord may terminate this Lease effective as of the date possession is required to be surrendered to the authority. In the event title to a portion of the Building or Project, other than the Premises, is taken or sold in lieu of taking, and if Landlord elects to restore the Building in such a way as to alter the Premises materially, either party may terminate this Lease, by written notice to the other party, effective on the date of vesting of title. In the event neither party has elected to terminate this Lease as provided above, then Landlord shall promptly, after receipt of a sufficient condemnation award, proceed to restore the Premises to substantially their condition prior to the taking, and a proportionate allowance shall be made to Tenant for the rent corresponding to the time during which, and to the part of the Premises of which, Tenant is deprived on account of the taking and restoration. In the event of a taking, Landlord shall be entitled to the entire amount of the condemnation award without deduction for any estate or interest of Tenant; provided that nothing in this Section shall be deemed to give Landlord any interest in, or prevent Tenant from seeking any award against the taking authority for, the taking of personal property and fixtures belonging to Tenant or for relocation or business interruption expenses recoverable from the taking authority.
No Other Employment; Minimum Time Commitment During the Period of Employment, the Executive shall (i) devote substantially all of the Executive’s business time, energy and skill to the performance of the Executive’s duties for the Company, (ii) perform such duties in a faithful, effective and efficient manner to the best of his abilities, and (iii) hold no other employment without the express written approval of the Board. The Executive’s service on the boards of directors (or similar body) of other business entities is subject to the approval of the Board. The Company shall have the right to require the Executive to resign from any board or similar body (including, without limitation, any association, corporate, civic or charitable board or similar body) which he may then serve if the Board reasonably determines that the Executive’s service on such board or body interferes with the effective discharge of the Executive’s duties and responsibilities to the Company or that any business related to such service is then in competition with any business of the Company or any of its Affiliates, successors or assigns.
Dismissal or Suspension Grievance (a) In the case of a dispute arising from an employee's dismissal, the grievance may be filed directly at arbitration within thirty (30) days of the date on which the dismissal occurred, or within thirty (30) days of the employee receiving notice of dismissal. (b) In the case of a dispute arising from an employee's suspension, the grievance may commence at Step 2 of the grievance procedure within thirty (30) days of the date on which the suspension occurred, or within thirty (30) days of the employee receiving notice of suspension.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”): (i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord; (ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed; (iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord; (iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed; (v) Construction of any Change Requests; (vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible); (vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein; (viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord; (ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or (x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Time Commitment The Advisor shall, and shall cause its Affiliates and their respective employees, officers and agents to, devote to the Company such time as shall be reasonably necessary to conduct the business and affairs of the Company in an appropriate manner consistent with the terms of this Agreement. The Company acknowledges that the Advisor and its Affiliates and their respective employees, officers and agents may also engage in activities unrelated to the Company and may provide services to Persons other than the Company or any of its Affiliates.
Dismissal or Suspension Grievances (a) In the case of a dispute arising from an employee’s dismissal, the grievance may be filed directly at Step 3, within thirty (30) days of the date on which the dismissal occurred, or within thirty (30) days of the employee receiving notice of dismissal. (b) In the case of a dispute arising from an employee’s suspension, the grievance may commence at Step 2 of the grievance procedure within thirty (30) days of the date on which the suspension occurred, or within (30) days of the employee receiving notice of suspension.
Sunday Work Employees required to work overtime on Sundays shall be paid for a minimum of three hours work at double time. The double time is to be paid until the employee is relieved from duty.
Extended Leave of Absence Professional employees who have attained renewable contract status may request extended leaves of absence for one (1) year without pay under any one of the circumstances listed in this section. All requests for such extended leave of absence will be applied for and granted or rejected in writing. Such application will be reviewed by the principal and superintendent. If the latter approves, he/she will recommend that the leave be granted by the Board. An employee returning from an extended leave will be assigned to the same position as that which he/she held before assuming the leave, providing that position still exists. By mutual agreement between the employer and the employees, he/she may be given a different assignment. Extended leaves of absence may be requested under, but not limited to, the following: 1. To serve in a county, state, or national public office. 2. To care for a sick member of the immediate family. 3. To serve as an exchange teacher or an overseas teacher. 4. To accept a sabbatical leave.