Changes to Scope of Work The City of Nashua may, at any time, by written order, make changes to the general scope, character, or cost of this contract and in the services or work to be performed, either increasing or decreasing the scope, character, or cost of Independent Contractor's performance under the contract. Independent Contractor shall provide to the City of Nashua within 10 calendar days, a written proposal for accomplishing the change. The proposal for a change shall provide enough detail, including personnel hours for each sub-task and cost breakdowns of tasks, for the City of Nashua to be able to adequately analyze the proposal. The City of Nashua will then determine in writing if Independent Contractor should proceed with any or all of the proposed change. If the change causes an increase or a decrease in Independent Contractor's cost or time required for performance of the contract as a whole, an equitable adjustment shall be made and the contract accordingly modified in writing. Any claim of Independent Contractor for adjustment under this clause shall be asserted in writing within 30 days of the date the City of Nashua notified Independent Contractor of the change. When Independent Contractor seeks changes, Independent Contractor shall, before any work commences, estimate their effect on the cost of the contract and on its schedule and notify the City of Nashua in writing of the estimate. The proposal for a change shall provide enough detail, including personnel hours for each sub-task and cost breakdowns of tasks, for the City of Nashua to be able to adequately analyze the proposal. The City of Nashua will then determine in writing if Independent Contractor should proceed with any or all of the proposed change. Except as provided in this paragraph, Independent Contractor shall implement no change unless the City of Nashua in writing approves the change. Unless otherwise agreed to in writing, the provisions of this contract shall apply to all changes. The City of Nashua may provide verbal approval of a change when the City of Nashua, in its sole discretion, determines that time is critical or public health and safety are of concern. Any verbal approval shall be confirmed in writing as soon as practicable. Any change undertaken without prior City of Nashua approval shall not be compensated and is, at the City of Nashua's election, sufficient reason for contract termination.
Attachment A, Scope of Services The scope of services is amended as follows:
HOOSIER HEALTHWISE SCOPE OF WORK Requirements for Reinsurance Companies The Contractor shall submit documentation that the reinsurer follows the National Association of Insurance Commissioners' (NAIC) Reinsurance Accounting Standards. The Contractor shall be required to obtain reinsurance from insurance organizations that have Standard and Poor's claims- paying ability ratings of "AA" or higher and a Xxxxx’x bond rating of “A1” or higher, unless otherwise approved by OMPP. Subcontractors Subcontractors’ reinsurance coverage requirements must be clearly defined in the reinsurance agreement. Subcontractors should be encouraged to obtain their own stop-loss coverage with the above-mentioned terms. If subcontractors do not obtain reinsurance on their own, the Contractor is required to forward appropriate recoveries from stop- loss coverage to applicable subcontractors.
Detailed Scope of Work The complete description of services to be provided by the Contractor under an individual Job Order. Developed by the Contractor, after the Joint Scope Meeting and submitted for approval to the County Project Manager.
000 SCOPE OF WORK 5.100 The scope of this Agreement covers all work of a maintenance, repair and renovation nature, assigned by the Owner to the Company and performed by the employees of the Company covered by this Agreement, within the limits of the Owner's plant site.
Scope of Work The Contractor has overall responsibility for and shall provide and furnish all materials, equipment, tools and labor as necessary or reasonably inferable to complete the Work, or any phase of the Work, in accordance with the Owner’s requirements and the terms of the Contract Documents.
Scope of Grievances A. A grievance may be filed if a management interpretation or application of the provisions of this Memorandum of Understanding adversely affects an employee's wages, hours or conditions of employment.
Salary Schedule Progression Employees shall progress from step to step in salary grade on the basis of satisfactory job performance based upon established standards of performance. Seasonal employee's initial anniversary date shall be established after being in pay status for two thousand eighty (2,080) hours. Such date shall then be used for annual performance evaluation and step progression consideration. When an employee's anniversary date falls on any day from the first day of a pay week through Wednesday of the pay week, the employee's merit increase shall be effective as of the first day of the pay week within which the anniversary date falls. Otherwise, the merit increase shall be effective on the first day of the next pay week. Grievances arising from the denial of merit increases shall not be arbitrable under this Agreement but shall be processed as follows:
Change in Scope of Work Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition, or deletion is approved in advance and in writing by a valid change order executed by the District. Contractor specifically understands, acknowledges, and agrees that the District shall have the right to request any alterations, deviations, reductions, or additions to the Project or Work, and the cost thereof shall be added to or deducted from the amount of the Contract Price by fair and reasonable valuations. Contractor also agrees to provide the District with all information requested to substantiate the cost of the change order and to inform the District whether the Work will be done by the Contractor or a subcontractor. In addition to any other information requested, Contractor shall submit, prior to approval of the change order, its request for a time extension (if any), as well as all information necessary to substantiate its belief that such change will delay the completion of the Work. If Contractor fails to submit its request for a time extension or the necessary supporting information, it shall be deemed to have waived its right to request such extension.
Description of Goods or Services and Additional Terms and Conditions The Contractor shall perform as set forth in Exhibit A. For purposes of this Contract, to perform and the performance in Exhibit A is referred to as “Perform” and the “Performance.”
