Project Cost a. The estimated cost of the Project is $ 97,740.00. This amount is based upon the Schedule of Financial Assistance in Exhibit "B", attached to and incorporated in this Agreement. Exhibit “B” may be modified by mutual execution of an amendment as provided for in paragraph 5.i.
Construction Cost Estimate At 50% completion of the contract documents, the design team will present and submit copies of the project plans and manual. The Construction Administrator will prepare and issue the fourth of five construction cost estimates. The estimate shall be derived from actual takeoffs, subcontractor and vendor input, and material and labor cost data. All quantitative systems information shall be provided in detail.
Construction Cost 3.1. Construction Cost does not include the fees of the ARCHITECT/ENGINEER and consultants, the cost of the land, rights- of-way, or other costs, which is the responsibility of the State as provided in Paragraphs 2.2 through 2.3. or any of the contingencies available for the project unless specifically stated otherwise.
Construction Cost Budget The total cost to District of all elements of the Project designed or specified by the Architect, as adjusted during and at the end of the design phase in accordance with this Agreement and the Agreement for Architectural Services. The Construction Cost Budget does not include the compensation of the Project Design Team, the Program Manager (if any), the Construction Manager and any subconsultants, the cost of the land, rights-of-way, or financing which are the responsibility of the District.
DIRECT CONSTRUCTION COST Direct Construction Cost means the sum of the amounts that Contractor actually and necessarily incurs constructing the Project in strict compliance with the Construction Documents. Direct Construction Cost includes only the cost categories set forth in this Article and does not include the Pre-Construction Phase Fees or the Construction Phase Fees unless specifically noted. References in the UGSC to adjustments in “cost” or “costs” mean the Direct Construction Cost.
Preliminary Cost Estimate Consulting Engineer/Architect shall furnish City an estimate of probable Construction Cost based on the preliminary design. Consulting Engineer/Architect's estimate of probable Construction Cost is to be made on the basis of Consulting Engineer/Architect's experience and qualifications and represent Consulting Engineer/Architect's best judgment as an experienced and qualified design professional, familiar with the construction industry.
EQUIPMENT TAX ASSESSMENT 17.1 Any bid for public improvement shall comply with Nebraska Revised Statutes Section 77-1323 and 77-1324. Indicating; every person, partnership, limited liability company, association or corporation furnishing labor or material in the repair, alteration, improvement, erection, or construction of any public improvement shall sign a certified statement which will accompany the contract. The certified statement shall state that all equipment to be used on the project, except that acquired since the assessment date, has been assessed for taxation for the current year, giving the county where assessed.
Total Project Cost The total cost of the Project is $36,378,683, of which (i) a match is being contributed in the amount of $21,000,000 shall be Matching Funds, and (ii) $15,378,683 shall be provided by the Grant. The total estimated cost of the Project is based upon the Budget. To the extent that the actual cost of the Project exceeds $36,378,683, Grantee shall be solely responsible for such excess. Grantee shall monitor the Budget and submit an amended Budget to Triumph in the event that (a) the total cost of the Project increases or decreases by greater than five percent (5%), (b) total the Budget increases or decreases by greater than five percent (5%), (c) the Budget increases or decreases by greater than five percent (5%) within a particular Budget category, and/or (d) Grantee’s portion of the Matching funds decreases by greater than five percent (5%). If Grantee proposes an increase or decrease by greater than five percent (5%) as described above as compared to the most recently approved Budget, such proposal shall be submitted to Triumph in writing along with a proposed amended Budget, and Triumph shall have the right to approve or disapprove both the proposed Budget category increase or decrease and the proposed amended Budget. If Grantee fails to obtain Triumph's approval, that failure shall be sufficient cause for nonpayment by Triumph as provided in Section 4.2(f). Using the Grant, its own funds, and funds from other sources (including, but not limited to, the Matching Funds), Grantee agrees to bear the entire cost and expense of the Project, including but not limited to, all costs and all expenses in excess of the total estimated cost of the Project, it being expressly understood and agreed that the Grant shall operate only to pay, on and subject to the terms and conditions set forth herein, a portion of the costs and expenses of the Project. Furthermore, Grantee agrees to spend all of the Matching Funds as contemplated in the Budget, and agrees that its failure to do so shall be deemed a material breach of this Agreement.
Cost 5.2.1.2. Ability to meet completion dates in proposed project schedule
Indirect Cost Except as otherwise authorized by this contract, no indirect costs shall be reimbursed.
