Substantial Performance This Contract shall be deemed to be substantially performed only when fully performed according to its terms and conditions and any written amendments or supplements.
Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Certification of Funds; Budget and Fiscal Provisions; Termination in the Event of Non-Appropriation This Agreement is subject to the budget and fiscal provisions of the City’s Charter. Charges will accrue only after prior written authorization certified by the Controller, and the amount of City’s obligation hereunder shall not at any time exceed the amount certified for the purpose and period stated in such advance authorization. This Agreement will terminate without penalty, liability or expense of any kind to City at the end of any fiscal year if funds are not appropriated for the next succeeding fiscal year. If funds are appropriated for a portion of the fiscal year, this Agreement will terminate, without penalty, liability or expense of any kind at the end of the term for which funds are appropriated. City has no obligation to make appropriations for this Agreement in lieu of appropriations for new or other agreements. City budget decisions are subject to the discretion of the Mayor and the Board of Supervisors. Contractor’s assumption of risk of possible non-appropriation is part of the consideration for this Agreement. THIS SECTION CONTROLS AGAINST ANY AND ALL OTHER PROVISIONS OF THIS AGREEMENT.
Upon Substantial Completion of the Work or designated portion thereof and upon application by the Contractor and certification by the Architect, the State shall make payment, reflecting adjustment in retainage, if any, for such Work or portion thereof, as provided in the Contract Documents.
CERTIFICATION OF NONSEGREGATED FACILITIES (Applicable to construction contracts exceeding $10,000) The Contractor certifies that it does not maintain or provide for its establishments, and that it does not permit employees to perform their services at any location, under its control, where segregated facilities are maintained. It certifies further that it will not maintain or provide for employees any segregated facilities at any of its establishments, and it will not permit employees to perform their services at any location under its control where segregated facilities are maintained. The Contractor agrees that a breach of this certification is a violation of the equal opportunity clause of this contract. As used in this certification, the term “segregated facilities” means any waiting rooms, work areas, rest rooms and wash rooms, restaurants and other eating areas, time clocks, locker rooms, and other storage or dressing areas, parking lots, drinking fountains, recreation or entertainment areas, transportation and housing facilities provided for employees which are segregated by explicit directive or are, in fact, segregated on the basis of race, color, religion, or national origin because of habit, local custom, or any other reason. The Contractor further agrees that (except where it has obtained for specific time periods) it will obtain identical certification from proposed subcontractors prior to the award of subcontracts exceeding $10,000 which are not exempt from the provisions of the equal opportunity clause; that it will retain such certifications in its files; and that it will forward the preceding notice to such proposed subcontractors (except where proposed subcontractors have submitted identical certifications for specific time periods).
Prevention or Delay of Performance by the Company or the Depositary Neither the Depositary nor the Company nor any of their respective directors, employees, agents or affiliates shall incur any liability to any Owner or Holder:
(i) if by reason of (A) any provision of any present or future law or regulation or other act of the government of the United States, any State of the United States or any other state or jurisdiction, or of any governmental or regulatory authority or stock exchange; (B) (in the case of the Depositary only) any provision, present or future, of the articles of association or similar document of the Company, or any provision of any securities issued or distributed by the Company, or any offering or distribution thereof; or (C) any event or circumstance, whether natural or caused by a person or persons, that is beyond the ability of the Depositary or the Company, as the case may be, to prevent or counteract by reasonable care or effort (including, but not limited to, earthquakes, floods, severe storms, fires, explosions, war, terrorism, civil unrest, labor disputes, criminal acts or outbreaks of infectious disease; interruptions or malfunctions of utility services, Internet or other communications lines or systems; unauthorized access to or attacks on computer systems or websites; or other failures or malfunctions of computer hardware or software or other systems or equipment), the Depositary or the Company is, directly or indirectly, prevented from, forbidden to or delayed in, or could be subject to any civil or criminal penalty on account of doing or performing and therefore does not do or perform, any act or thing that, by the terms of this Deposit Agreement or the Deposited Securities, it is provided shall be done or performed;
(ii) for any exercise of, or failure to exercise, any discretion provided for in this Deposit Agreement (including any determination by the Depositary to take, or not take, any action that this Deposit Agreement provides the Depositary may take);
(iii) for the inability of any Owner or Holder to benefit from any distribution, offering, right or other benefit that is made available to holders of Deposited Securities but is not, under the terms of this Deposit Agreement, made available to Owners or Holders; or
(iv) for any special, consequential or punitive damages for any breach of the terms of this Deposit Agreement. Where, by the terms of a distribution to which Section 4.1, 4.2 or 4.3 applies, or an offering to which Section 4.4 applies, or for any other reason, that distribution or offering may not be made available to Owners, and the Depositary may not dispose of that distribution or offering on behalf of Owners and make the net proceeds available to Owners, then the Depositary shall not make that distribution or offering available to Owners, and shall allow any rights, if applicable, to lapse.
CERTIFICATION OF AGREEMENT In accordance with section 170LT of the Workplace Relations Act 1996, I now certify the attached written agreement. This agreement shall come into force from 16 February 2004 and shall remain in force until 31 October 2005. BY THE COMMISSION: Printed by authority of the Commonwealth Government Printer <Price code 70> TABLE OF CONTENTS Subject Matter Clause No. Page No. Accident Pay 29 32 All-In Payments 34 34 Alpine Areas 14.1.(b) 15 Altona Area Allowance 14.2.(a) 16 Amenities 37 35 Apprentices 22.(a) 23 Australian Materials 41 37 Casual Labour 12.2 13 Classification Structure & Rates of Pay, Allowances 13 14 Clothing Issue & Safety Footwear 40 36 Co-Invest (Long Service Leave) 27 31 Commitments 3 5 Consultation 8 7 Demolition Work 14.1.(d) 16 Dispute Settlement Procedure 9 8 Drugs & Alcohol 38 35 Employment & Termination 12 12 Fares & Travel Allowance 15 17 Fast Food Allowance 14.1.(a) 15 Further Flexibilities 23 24 Geelong, Altona, Portland, etc Metals Agreements 14.3 16 Geographic Area, and Sector Specific Allowances, Conditions and Exceptions 14 15 Hearing Tests 11.(2) 10 Heavy Blocks 11.(9) 12 Hours Of work, Rostered Days Off, and Protection of Leisure Time 17 17 Inclement Weather 24 24 Income Protection 28.1 31 Income Protection & Trauma Insurance 28 31 Induction Procedures 11.(4) 11 Job Stewards/Delegates 36 34 Job Xxxxxxx/Delegate Facilities 36.2 35 Journey Accidents 30 32 Latrobe Valley Allowance 14.2.(b) 16 Leisure Time Protected 17.3 18 Living Away from Home Allowance 16 17 Major Events 14.1.(c) 15 Metal Trades Labour Hire Agreement 14.4 16 Negotiation of a Subsequent Agreement 43 37 No Extra Claims 44 38 Objectives of the Agreement 2 5 Overtime 17.2 18 Parties and Persons Bound 4 6 Payment of Wages 19 21 Period of Operation 6 6 Picnic Day 31 33 Project Agreements 5.2 6 Project Pre-Commencement Conference 18 21 Protective Clothing & Equipment 11.(3) 10 Pyramid Subcontracting 35 34 Redundancy 25 30 Rehabilitation Program 39 35 Relationship to Parent Award and Victorian Building Industry Agreement 7 6 Right of Entry & Representation 33 33 Rostered Days Off 17.4 19 Safety Dispute Resolution 10 8 Scope & Application 5 6 Security & Continuity of Employment 32 33 Service Core Allowance 14.2.(c) 16 Signatories 45 39 Superannuation 26 30 Termination of Employment 12.3 13 Time & Wages Records 19.1 21 Title 1 5 Tool Storage 20 22 Toxic Substances 11(8) 11 Training & Related Matters 22 23 Trauma Insurance 28.2 32 Waste Minimisation, Recycling and Environmental Issues 42 37 Workplace Safety 11 10 Appendix A – Classification Structure 40 Appendix B – Rates of Pay 1. From 1 December 2002 2. From 1 March 2003 3. From 1 March 2004 4. From 1 March 2005 41 Appendix C – Site Allowances 51 Appendix D – Drugs & Alcohol Policy 54 Appendix E – Passenger and Material Lifts 61 Appendix F – Amenities 63 Appendix G – Shopping Centres 66 Appendix H – Trade Union Training Leave 67 Appendix I – Sector Appendix 70
Excuse from performance of obligations If the Affected Party is rendered wholly or partially unable to perform its obligations under this Agreement because of a Force Majeure Event, it shall be excused from performance of such of its obligations to the extent it is unable to perform on account of such Force Majeure Event; provided that:
(a) the suspension of performance shall be of no greater scope and of no longer duration than is reasonably required by the Force Majeure Event;
(b) the Affected Party shall make all reasonable efforts to mitigate or limit damage to the other Party arising out of or as a result of the existence or occurrence of such Force Majeure Event and to cure the same with due diligence; and
(c) when the Affected Party is able to resume performance of its obligations under this Agreement, it shall give to the other Party notice to that effect and shall promptly resume performance of its obligations hereunder.
Certification Regarding Termination of Contract for Non-Compliance (Tex Gov. Code 552.374)
Notification of Breach / Compliance Reports The Adviser shall notify the Trust immediately upon detection of (i) any material failure to manage any Fund in accordance with its investment objectives and policies or any applicable law; or (ii) any material breach of any of the Funds’ or the Adviser’s policies, guidelines or procedures. In addition, the Adviser shall provide a quarterly report regarding each Fund’s compliance with its investment objectives and policies, applicable law, including, but not limited to the 1940 Act and Subchapter M of the Code, as applicable, and the Fund’s policies, guidelines or procedures as applicable to the Adviser’s obligations under this Agreement. The Adviser agrees to correct any such failure promptly and to take any action that the Board may reasonably request in connection with any such breach. Upon request, the Adviser shall also provide the officers of the Trust with supporting certifications in connection with such certifications of Fund financial statements and disclosure controls pursuant to the Xxxxxxxx-Xxxxx Act. The Adviser will promptly notify the Trust in the event (i) the Adviser is served or otherwise receives notice of any action, suit, proceeding, inquiry or investigation, at law or in equity, before or by any court, public board, or body, involving the affairs of the Trust (excluding class action suits in which a Fund is a member of the plaintiff class by reason of the Fund’s ownership of shares in the defendant) or the compliance by the Adviser with the federal or state securities laws or (ii) an actual change in control of the Adviser resulting in an “assignment” (as defined in the 0000 Xxx) has occurred or is otherwise proposed to occur.
